Nothing Special   »   [go: up one dir, main page]
Scribd Logo
Upload

Welcome to Scribd!

  • 479 views

    KTG Engineering PLC: Contract Agreement For The Welding of Hdpe Pipe

    Uploaded by

    ARSE
    This contract agreement is between Jafar General Contractor and KTG Engineering PLC for welding HDPE pipe in the Somali Region. KTG Engineering will be responsible for welding the pipes according to specifications within a set timeframe. Jafar will pay KTG Engineering a total of 333,200 birr, with advance payments of 249,900 birr made upon completion of milestones. The contract outlines obligations of both parties, provisions for termination, warranties, dispute resolution, and effective date.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd

    KTG Engineering PLC: Contract Agreement For The Welding of Hdpe Pipe

    Uploaded by

    ARSE
    479 views6 pages
    This contract agreement is between Jafar General Contractor and KTG Engineering PLC for welding HDPE pipe in the Somali Region. KTG Engineering will be responsible for welding the pipes according to specifications within a set timeframe. Jafar will pay KTG Engineering a total of 333,200 birr, with advance payments of 249,900 birr made upon completion of milestones. The contract outlines obligations of both parties, provisions for termination, warranties, dispute resolution, and effective date.

    Original Description:

    Original Title

    Ktg Eng.bike

    Copyright

    © © All Rights Reserved

    Available Formats

    DOC, PDF, TXT or read online from Scribd

    Did you find this document useful?

    Is this content inappropriate?

    This contract agreement is between Jafar General Contractor and KTG Engineering PLC for welding HDPE pipe in the Somali Region. KTG Engineering will be responsible for welding the pipes according to specifications within a set timeframe. Jafar will pay KTG Engineering a total of 333,200 birr, with advance payments of 249,900 birr made upon completion of milestones. The contract outlines obligations of both parties, provisions for termination, warranties, dispute resolution, and effective date.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd
    Download as doc, pdf, or txt
    479 views6 pages

    KTG Engineering PLC: Contract Agreement For The Welding of Hdpe Pipe

    Uploaded by

    ARSE
    This contract agreement is between Jafar General Contractor and KTG Engineering PLC for welding HDPE pipe in the Somali Region. KTG Engineering will be responsible for welding the pipes according to specifications within a set timeframe. Jafar will pay KTG Engineering a total of 333,200 birr, with advance payments of 249,900 birr made upon completion of milestones. The contract outlines obligations of both parties, provisions for termination, warranties, dispute resolution, and effective date.

    Copyright:

    © All Rights Reserved
    Download as DOC, PDF, TXT or read online from Scribd
    Download as doc, pdf, or txt
    of 6

    KTG ENGINEERING PLC

    Contract agreement for the welding of hdpe pipe

    This contract is made and entered into this 08 /07/2013 of ………… ………….by and between
    JAFAR GENERAL CONTRACTOR whose address is DIRE DAWA town House no. …………...
    telephone 0973228282 and hereinafter referred to as ‘client ' or " contractor " and KTG
    Engineering PLC ( GENERAL CONTRACTOR) whose address is at ADDIS ABABA kolfe
    keraniyo sub city wired 05 house number new and p.o.box………..telephone 0912-14-08-
    71/0924-391083/0910-19-55-12 and hereinafter referred to as ‘’ Sub-contractor’’

    Article 1

    Scope of the contract

    the client has resolved to give contract to a competent contract the welding of HDPE services
    at the SOMALI REGIONAL STATE SITY ZONE BIKE TOWN sites,

    KTG Engineering PLC has been selected as competent contract to undertake the welding of
    HDPE services as detailed in this agreement and the attached Proforma invoice

    Article 2
    Contract documents
    The following documents constitute the entire contract documents which are part and
    parecels of the agreement

    proforma invoice of contractor ,dates 08 /08/2013

    Article 3
    Sub- Contractor’s obligations

    3.1 the sub-contractor shall hand-over the works conforming to the attached bill of quantities.
    3.2 the SUB-CONTRACTOR shall be responsible for the works and the safety of all man power
    daily labor (skilled or welding technician ) at the project site and hand-over the final works
    according to the specification to the satisfaction of the CLIENT in ……….. Calendar day

    3.3 The sub-contractor must carefully and maintain the machines and generators received from
    the client.

    3.4 The sub-contractor shall supply all labor needed for accomplishment of the work for
    delivering pipe up to the trench and mounting on the machine ( not pipes insert the trench)

    Article 4

    Clint’s obligation

    4.1 The client shall pay to the sub-contractor a total sum of 30%( not including vat ) on the
    baises of excluded and measured quantity of work

    4.1.1 The client shall pay to the sub-contractor a total sum of In approximate calculation of
    40% is 333,200 ETB only ( three hundred thirty three thousand two hundred Birr
    only )

    4.1.2 Client The first payment 30% 249,900 birr ( two hundred forty nine thousand nine
    hundred birr only ) is Advance payment must be made as soon as work is done. and the
    second payment 30% 249,900 ( two hundred forty nine thousand nine hundred birr only)the
    first payment must be made as soon as work is done,

    4.2 The payment shall be made progressively upon each take-off and written approval of the
    clint representative.

    4.3 All excavation work shall be accomplished by the clint before the contractor mobilize his
    work force to the site, And Client offers car for pipe Distribute,

    4.4 after welding done by the contractor, covering the trench shall be done by the clint

    4.5 any delayed due to preparation of the trench, or other unseen situation, which is forced to
    bring down time on the contractor machinery and labor shall be compensated by the client
    calculating daily production point of large diametr pipe in the contract by down
    time

    4.6 The clint shall provide transport for mobilization of machines and personel to site and from
    the site to addis ababa .
    Articles 5

    Termination of contract

    5.1 The clint, by a written notice to the sub-contractor and without stating cause, may
    terminate the contract if;

    5.1.1 the sub-contractor fails to construct and hand over all the works within the period
    specified in the contract.

    5.1.2 the contractor fails to perform any other obligation(s) under the contract.

    Articles 6

    Warranty

    6.1 the contractor shall perform according to the technical specification and instructions given
    time to time by the clint representative.

    6.2 the contractor further agrees to replace all defective application if so requested by the clint
    representative at no cost to the clint.

    Article 7

    Force majeure
    If a force majeure situation arises, the clint shall promptly notify the contractor in writing of
    such condition and the cause there of. Neither party shall be liable to pay damages for non
    performance of this contract as a result of force majeure as specified in the 1960 civil code of
    Ethiopia. The contractor and its guarantor shall however refund the advance payment .

    Article 8

    Miscellaneous provisions
    8.1 to the extent not inconsistent herewith, the provisions of the 1960 civil code of Ethiopia
    shall govern the relationship between the parties hereunder.

    8.2 the languages of the contractor documents shall be English or Amharic.

    8.3 the final cost of the work is subject to change due to the actual quantity or the work to be
    welded by the contractor and such a change shall be approved by a written consent of the
    contractor’s representative.
    Article 9

    Resolution of disputes
    Any dispute arising under this contract shall be settled amicably by both parties. If a dispute
    cannot be settled amicably, it shall be submitted to the court of appropriate jurisdiction in
    Ethiopia .

    Article 10

    Effective date
    This contract agreement shall come into force upon the date of its signature by the duly
    authorized representative of the parties.

    In witness whereof the authorized representatives of the parties hereto have signed the
    contract on the day, month and year first above written.

    For the contractor for the clint

    Name………………................. Name……………………….............

    Title ……………………............ Title………………………………......

    Sign………………………….. Sign…………………………………..

    Witnesses

    Name SIGNATUR

    1 ………………………….. ………………………………

    2…………………………… ………………………………
    ..
    KTG ENGINEERING PLC
    GENERAL CONSTRUCTION

    Date :- 15/ 08/ 2013 E.C


    Proforma
    Ref :- no KTK 0060/2013

    TIN no 0059224041

    To :- JAFAR General Contractor

    S/N Description of diameter Unit Quantity Unit price Total price

    1 Diameter OD 250 PN 16 Per point 1666 500. birr 833,000


    KTG ENGINEERING

    CONTRACT AGREEMENT OF
    HDPE WELDING WORK

    DIRE DAWA town


    miyazia 2013

    You might also like