Guidance For Standard Form Contract - Sri Lanka PDF
Guidance For Standard Form Contract - Sri Lanka PDF
Guidance For Standard Form Contract - Sri Lanka PDF
INFRASTRUCTURE DEVELOPMENT
PROJECTS (Works)
IMPLEMENTED BY THE
February 2017
ii
PREFACE
Insufficient capacity in project management and contract management skills, including skills
in dispute resolution processes within Project Management Units have been identified as a
key contributory factors. Therefore, the Asian Development Bank approved a Technical
Assistance Program (TA-8562 SRI) for the government of Sri Lanka on “Capacity
Development in Project Implementation for the Government of Sri Lanka” in order to remedy
the situation in December 2013 to enhance project and contract management capacity of the
staff engaged in the implementation and execution of national infrastructure projects. The
development of a Guide to Project Management and Contract Management (hereinafter
referred to as the “GPMCM”) has been identified as one of the key TA outputs to impart
knowledge on use of conditions of contracts using FIDIC and ICTAD forms of contracts in
the implementation of civil works contracts.
The introduction of the GPMCM is timely, responding to a long felt need. In preparation of
the GPMCM, the input of the relevant stakeholders with particular emphasis on the water
sector has been considered by the consultants at the initial review. The GPMCM particularly
intends to provide guidance to staff involved in the implementation and monitoring of
infrastructure development projects, using FIDIC Multi-Lateral Development Banks
harmonised version (FIDIC Pink Book) and financed by ADB. The Guide will also be of
interest to members of Procurement Committees and Technical Evaluation Committees
other staff in project management units. GPMCM has 3 three broader sections; (i)
Introduction, Principles and Concepts of Contract Management; (ii) Contract Management
Procedures; and (iii) forms, templates and specimen letters for each contract management
action. Additionally the forms, templates and specimen letters described in item (iii) has been
customised to projects needs and added as templates to the IT based project management
tools developed on MS Share Point software platform, to facilitate Project and/or Contract
Management.The Guide is intended to serve as a first reference point to project staff to
manage projects effectively and efficiently. It is important to mention that the rights and
obligations of the parties to a contract are not governed by this Guide but by the relevant
contract signed by such parties.
i
The draft GPMCM was presented to various professional organizations and groups
representing the construction industry and related government agencies including CIDA and
their observations and suggestions for improvements have been incorporated into the
preparation of the Guide. Users of the Guide are also invited for a half day workshop in
November 2016 to provide their observations and/or suggestions for improvements for
revisions and modifications.
I acknowledge the valuable contributions made by ADB staff in preparing this Guide
especially Mr. Sarath Muthugala, Senior Procurement Specialist for structuring, peer
reviewing and providing valuable comments to complete this Guide. Also appreciate the
input provided by the team of consultants engaged under the TA specially Mr. Wijitha
Fernando and Mr. T.M. Jayasekara who provided the technical inputs and the team of other
consultants with diverse background. I also wish to thank the Country Director of ADB
Ms. Sri Widowati and her staff while extending my gratitude to all others who contributed in
numerous ways in making the publication of this GPMCM a reality.
In the end, I appreciate the invaluable guidance provided by Mr. P.Algama Director General
Department of Public Finance and wish to mention that without his support publication of this
GPMCM would be a difficult task.
R.H.S Samarathunga
Secretary to the Treasury
Ministry of Finance
ii
LIST OF ACRONYMS & ABBREVIATIONS
iii
SLRM Sri Lanka Resident Mission
TA Technical Assistance
WB World Bank
iv
TABLE OF CONTENTS
SECTION 1 - INTRODUCTION, PRINCIPLES AND CONCEPTS
1 SCOPE AND PURPOSE OF CONTRACT MANAGEMENT VOLUME OF 2
THE PROJECT MANAGEMENT AND CONTRACT MANAGEMENT GUIDE
1.1 Purpose 2
2 PROFESSIONAL STANDARDS OF CONDUCT 2
2.1 Doctrine of Public Trust 3
2.2 The Establishment Code 3
2.3 Code of Best Practices 3
2.4 The Bribery Act No. 11 Of 1954 3
2.5 Declaration of Assets and Liabilities Law 4
2.6 International Agreements 4
2.7 National Procurement Guidelines 4
2.8 Conflict of Interest 4
2.9 Code of Best Practices In Corporate Governance 5
2.10 Public Contracts Act No. 3 Of 1997 5
3 DIFFERENT FORMS OF CONTRACTS APPLICABLE 5
4 CONTRACT MANAGEMENT 6
4.1 Contract Management Procedures 7
4.2 Key Principles of Contract Management 7
5 CONTRACT MANAGEMENT ACTIVITIES 8
5.1 Letter of Acceptance/Award 8
5.2 Contract Agreement 8
5.3 Documents Constituting a Contract 9
5.4 Commencement of Contract 9
5.5 Employer’s Financial Arrangements 10
5.6 Appointment of The Engineer 10
5.7 Defect Notification Period 11
6 CONTRACT PERFORMANCE 11
6.1 Contractor’s Responsibilities 11
6.2 Employer’s Rights 12
6.3 Performance Certificate 12
7 CLOSURE OF CONTRACT 13
8 CONTRACT ADMINISTRATION 13
8.1 Key Contract Administration Functions to be Performed by the Engineer 13
8.2 Other Tasks to be Performed by the Engineer 17
8.3 Main Responsibilities of the Engineer 18
8.3.1 Monitoring Performance 18
8.3.2 Payment Certification 18
8.3.3 Withholding Payments 19
8.3.4 Contract Variation Management 19
8.3.5 Dispute Resolution 19
8.3.6 Maintaining Contract Administration Files 20
8.3.7 Construction Supervision, Quality Control and Quality Assurance 21
8.4 Limitations to the Engineer’s Functions 21
9 TERMINATION OF CONTRACT 21
9.1 Termination for Convenience 21
9.2 Termination for Default 22
9.3 Force Majeure Clauses 23
9.4 Failure to Comply with Notice to Correct 23
9.5 Notice of Termination 23
10 CONTRACT CLOSING PROCESS 23
10.1 General 23
v
ANNEXE 1 – CONCEPTS OF CONTRACT 25
A1 General Legal Principles 25
A1.2 Definition of Contract 25
A1.3 Offer and Acceptance 25
A1.4 Factors vitiating agreement/consent of parties 26
A1.5 Discharge of Contracts 27
A1.6 Breach of Contract 27
A1.7 Damages for Breach of Contract 27
A1.8 Interpretation of a Contract 28
vi
ANNEXE 4 – REQUIREMENTS OF FUNDING AGENCIES 50
SECTION 2 - PROCEDURES TO BE FOLLOWED 52
PART ONE - MOBILIZATION STAGE 54
Content of Procedures 54
CA01 Letter of Acceptance/Award 55
CA02 Formation of Project/Contract Management Team 58
CA03 Handing Over of Documents/Information Relevant to the Contract to CM 59
Team
CA04 Reviewing of Draft Contract Agreement and Other Documents Constituting 61
the Contract
CA05 Drafting and Signing of Contract Agreement 62
CA06 Orientation Training on Contract Management to Project Staff 64
CA07 Contract Commencement 66
CA08 Evidence of the Employer’s Financial Arrangement 69
CA09 Appointment of the Engineer 70
CA10 Delegation of Engineer’s Authority to Engineer’s Representative / Assistants 71
CA11 Establishment of the Document/ Correspondence Management System 73
CA12 Handing over of Site Possession 77
CA13 Handing over of Survey Control Points and Bench Marks 79
CA14 Kick-off Meeting 80
CA15 Establishment of Communication Modes and Addresses 82
CA16 Authority Approvals 83
CA17 Review of Work Program 84
CA18 Review of Cash Flow Forecast 86
CA19 Delegation of Authority 87
CA20 Performance Bond 88
CA21 Review of Insurance 91
CA22 Establishment of Payment Procedure 92
CA23 Advance Payment Guarantee 93
CA24 Advance Payment 95
CA25 Arrangement for Establishing Dispute Board 96
CA26 Approval Procedure for Contractor’s Site Establishment 98
CA27 Approval for Sub-Contractors 99
CA28 Appointment of Nominated Sub-Contractors 100
CA29 Review of Method Statements 102
CA30 Approval for Materials Including Samples 103
CA31 Handing of Employer’s Free Issue Materials 104
CA32 Acceptance of Daily Report Format 105
CA33 Acceptance of Contractor’s Monthly Statement Format 106
CA34 Acceptance of Monthly Progress Report Format 107
CA35 Issuing of Drawings and Instructions 108
CA36 Acceptance of Formats for Returns of Labour/Equipment 109
CA37 Review of Quality Assurance System and Quality Plans 110
PART TWO - EXECUTING STAGE 112
Content of Procedures 113
CA38 Conducting of Monthly Progress Meetings 114
CA39 Preparation of Monthly Progress Reports 115
CA40 Preparation of Quarterly Progress Reports 116
CA41 Preparation of Annual Progress Reports 117
CA42 Steering Committee Meetings 118
CA43 Monitoring of Progress 120
CA44 Monitoring of Critical Issues 122
CA45 Updating of Work Program 123
CA46 Updating of Contract Amount and Forecast Cost 124
vii
CA47 Use of Provisional Sums 125
CA48 Managing Design Changes Including Control of Drawings 127
CA49 Managing Variations 129
CA50 Approval for New Rates 131
CA51 Managing Claims 133
CA52 Managing Extensions of Time 138
CA53 Employer’s Claims 141
CA54 Suspensions 143
CA55 Certification of Interim and Final Payment Certificates 145
CA55A Determination of Estimated Contract Value 148
CA56 Engineer’s Determinations 150
CA57 Deduction and Release of Retention Money 152
CA58 Day-works 154
PART THREE - COMPLETION STAGE 155
Content of Procedures 156
CA59 Termination of Contract 157
CA60 Force Majeure 160
CA61 Taking Over of Works 162
CA62 Management of as-Built Drawings 164
CA63 Defect Notification Period 165
CA64 Issuing of the Performance Certificate 168
CA65 Close Out of the Contract 169
CA66 Handing Over of Completed Works and Documents/Information Including as 170
Built Information to the Operation/Maintenance Team
PART FOUR - DISPUTE RESOLUTION 171
Content of Procedures 172
CA67 Adjudication 173
CA68 Amicable Settlement 176
CA69 Arbitration 178
SECTION 3 - FORMS AND FORMATS 182
Attachments to Procedures
CA 01 Pre-award Checklist 184
CA 02 Identification of Key Staff 187
CA 03 Checklist for Taking Over of Documents/Information 189
CA 04 Memo to Staff on Specific Provisions and Ambiguities in Contract Documents 192
CA 05 Pre-Contract Checklist 193
CA 06 Checklist to Assign Scope of Self Reading for Orientation Training 196
CA 07 Pre-Commencement Checklist 198
CA 08 Checklist for Employer’s Financial Arrangements 200
CA 09 Letter Appointing the Engineer 201
CA 10 Letter of Appointment of Engineer’s Representative 204
CA 11 Outgoing Correspondence Register 207
CA 12 Checklist for Handing Over of Possession of the Site to the Contractor 208
CA 13 Letter to the Contractor for Handing Over of Survey Control Points and Bench 209
Marks
CA 14 Kick-Off Meeting Checklist 210
CA 15 Communication Details 213
CA16 Checklist for Obtaining Authority Approvals 213
CA 17 Checklist for Reviewing of Work Program 214
CA 18 Submission of Cash Flow Forecast 216
CA 19 Letter Notifying the Appointment of the Employer’s Representative 216
CA 20 Performance Security Acceptance Checklist 217
CA 21 Checklist for Acceptance of Insurance 223
CA 22 Letter to the Contractor Requesting Account Details 223
CA 23 Advance Payment Guarantee Acceptance Checklist 224
viii
CA 24 Advance Payment Checklist 229
CA 25 Appointment of DB Members 230
CA 26 Approval for Site Installations 230
CA 27 Approval for Sub Contractors 231
CA 28 Appointment of Nominated Subcontractors 232
CA 29 Checklist for Method Statements 232
CA 30 Approval of Materials 233
CA 31 Handing Over of Free-Issue Materials 234
CA 32 Format for Daily Report 234
CA 33 Format for Contractor’s Monthly Statements 236
CA 34 Format for Contractor’s Monthly Progress Report 237
CA 35 Engineer’s Instruction 237
CA 36 Format for Contractor’s Labour/Equipment Returns 239
CA 37 Review Contractor’s Quality Assurance System & Quality Plans 239
CA 38 Minutes of Progress Review Meeting 243
CA 39 Monthly Progress Report 245
CA 40 Quarterly Progress Report Format 245
CA 41 Annual Progress Report Format 246
CA 42 Agenda for the Steering Committee Meeting 247
CA 43 Recording Format for Progress Monitoring 249
CA 44 Register for Critical Issues 249
CA/45 Attachments for Procedure 250
CA 46 Updating of Contract Amount & Forecast Cost 250
CA 47 Request for Evidence to Substantiate Provisional Sum Payments 251
CA 48 Drawing Register 251
CA 49 Variation Order Register 252
CA 50 Letter to Inform New Rates Determined by the Engineer 254
CA 51 Register of Contractor’s Claims 254
CA 52 Letter to Inform Extension of time For Completion Determined By The 255
Engineer
CA 53 Register of Employer’s Claims 256
CA 54 Instruction to Suspend Works 257
CA 55 Format for Interim Payment Certificate 257
CA/56 Procedure 258
CA/57 Procedure 258
CA 58 Format for Day-work Order 258
CA 59 Termination By Employer 259
CA 60 Notice of Termination Upon Force Majeure 260
CA 61 Rejection of Application for Taking-Over Certificate 262
CA 62 Register of As Built Drawings 264
CA 63 Notification of Defects During DNP 264
CA 64 Performance Certificate 265
CA 65 Check List for Contract Closure 266
CA 66 Check List of Items to be Handed Over to O & M Division 266
CA 67 Response to ADB Referral by the Contractor 267
CA 68 Letter to Attorney General Seeking His Opinion 272
CA 69 Notice of Arbitration 276
ix
x
1
Section 1
Section 3 Forms, Templates and Formats including sample letters and checklists.
1.1 Purpose
Public Officers engaged in the task of project management and implementation need to
abide by several statutory provisions and codes of conduct that regulate and govern
their conduct in respective professional capacities, such as the Establishment Code,
Financial Regulations, the Bribery Act, National Procurement Guidelines etc. more fully
described hereinafter.1
1
In addition public officers must ensure that they comply with the anti-corruption and integrity principles and guidelines of the
respective multi-lateral and bi-lateral donors.
2
2.1 Doctrine of Public Trust
Public officers must ensure that public resources are used in a manner that protects the
interest of the public.2 This concept is an application of the Public Trust Doctrine (that the
state is the trustee for the protection of natural and national resources, the public are the
beneficiaries and that the powers conferred on public officials and bodies are held in trust
for the public) which has been recognized by the Sri Lankans courts in several leading
judgments.3
All Public officials are thus required to act honestly and impartially particularly those
involved in Procurement and Contract Management, must therefore, avoid acts which are
improper and ensure adherence to the highest level of professionalism in discharging
their duties.4
The Establishment Code (E code) sets forth the standard of conduct of public officials. A
breach of the provisions of the E Code warrants disciplinary inquiry of such officer.
The provisions of the E Code, prohibits public officers and families from receiving certain
types of gifts, whether in a direct or indirect form, and whether in the shape of money,
goods, free passages, services, unusual discounts on the cost of goods supplied or
services rendered. Furthermore the officer is responsible for the acts of the members of
the family.
The Code of Best Practices for Public Enterprises issued by the Ministry of Finance
states that “as investor on behalf of the public, the Government has a duty to ensure that
a Public Enterprise delivers value for money and maximum financial returns, subject to
the social considerations prescribed in policy objectives” which is reflective of the
doctrine of public trust.
2.4 The Bribery Act No: 11 of 1954 & amending Act No: 40 of 1958 (Bribery Act)
The Bribery Act was enacted with the idea of containing bribery and corruption within the
public sector.6
The amending Act permits the offence of bribery to be established through circumstantial
evidence even if there is no direct evidence to prove acceptance of gratification.
If any public servant (as defined therein) uses any information coming to his knowledge
by virtue of his office as a public servant or participates in the making of any decision by
2
Also refer “The Offences against Public Property Act No: 12 of 1992” amended by Act No: 28 of 1999.
3
In Premchandra v Jayawickreme, [1994] 2 SLR 90, Supreme Court held that “There is no absolute or unfettered discretion in
public law; discretions are conferred on public functionaries in trust for the public, to be used for the public good, and the
propriety of the exercise of such discretions is to be judged by reference to the purposes for which they were so entrusted.”
In WatteGederaWijebanda case (2009) 1 SLR 337, Tilakawardana J held that upon accepting public office public officers are
vested with the trust of the people (who have committed the care and preservation of resources to the state as the guardian of
such resources)hence must exercise those powers in public interest.
4
Also refer Samararathne, D Public Trust Doctrine: The Sri Lanka Version ICES (Colombo, 2010)
5
First Schedule E Code.(Volume11).
6
Also refer “Bribery and Corruption in Sri Lanka: Strengthening the Institutional Framework” (White Paper) August 2007, USAID
and the website of Transparency International - www.tisrilanka.org.
3
virtue of his office as a public servant with the intent or the knowledge that a wrongful
benefit or loss will be caused to the Government is liable to be charged with corruption.
It is an offence under the Bribery Act, if any public servant, solicits or accepts any
gratification as an inducement or a reward for his giving assistance or using influence in
the promotion of the procuring of any contract, or its execution or in the payment of the
price or consideration in respect thereof.
2.5 Declaration of Assets and Liabilities Law consisting of Acts No: 1of 1975, No: 29 of
1985 and Act No: 74 of 1988
The objective of the Declaration of Assets and Liabilities Law consisting of Acts No: 1of
1975, No: 29 of 1985 and Act No: 74 of 1988 is to monitor the acquisition of wealth by
public servants politicians and others (vide section 2) through an act of bribery and
corruption.
Sri Lanka is a signatory to the United Nations Convention against Corruption and the
United Nations Convention against Transnational Organized Crime. Sri Lankan courts
have held that statutes may be interpreted in the context of country’s obligations under
International Law and Covenants.
National Procurement Guidelines 2006 as amended from time to time which apply to the
procurement of goods, service and works with public funds or any other source of
including projects funded by bi-lateral or multi-lateral funding agencies sets forth ethical
standards that must be adopted by government ministries, provincial councils, local
authorities, government corporations, government owned companies etc. as defined
therein. The guidelines prohibit an officer engaged in a procurement action to abuse their
powers to derive benefits for one’s self, family or business associates and to derive
personal gain from such a procurement action. Such officers are prohibited from
accepting gifts or inducement which may impact or influence their decision making in an
objective manner.
A conflict of interest situation may arise when a public officer exploits his position in office
for his personal benefit (often pecuniary) and thereby undermines his duty to act for the
benefit of the public or in the public interest.
The E code contains provisions which prohibit public officers from acting in a manner that
compromises his office and may bring his personal interest into conflict with his public
duty7.
4
Directors and senior management) who have directly or indirectly a material interest on
any matter or where there is a conflict of interest.
The Ministry of Finance has issued a Code of Best Practice in Corporate Governance for
Public Enterprises in Sri Lanka which is applicable to Public Enterprises and Statutory
Boards. One of its main objectives is to achieve “greater accountability and
transparency”.
The Code dictates that the Board of Directors of these entities have a “fiduciary duty” to
perform their duties in good faith and in a manner that they believe to be in the best
interests of the enterprise, shareholders, other stakeholders and the public.
In addition, certain State agencies have special conflict of interest provisions that apply to
their employees. These laws, rules, or policies should be reviewed and followed by
agency staff.8
2.10.1 The Provisions of the Act applies to every public contract10 where the cost of contract
exceeds five million rupees.11 The Act also applies to public contracts which have not
reached finality.
2.10.2 The Act prohibits any person form offering inducements, gratifications, scholarships or
rewards or any other form of benefit and making misrepresentations, transferring any
movable or immovable property, whether in Sri Lanka or elsewhere to obtain benefits in
the award of tenders and public contracts.12
The GPMCM is based on the FIDIC Multilateral Development Bank Harmonized Edition
June 2010, hereinafter referred to as Pink Book.
There are other forms of contracts that have been used in projects recently awarded by
the GOSL, such as;
8
Refer Section 4.For example, the National Water Supply and Drainage Board Law No: 2 of 1974 as amended and the Ceylon
Electricity Board Act No: 17 of 1969 as amended stipulate that a Board member is required to disclose the nature of his interest
in any contract made or proposed to be made by the NWSDB or CEB as the case may be.
9
Refer Section 2(2) of the preamble Act for categories of contract excluded from application of the provisions of this Act.
10
Refer Section 2(2) of the Preamble to the Act for categories of contract excluded from application of the provisions of this Act.
11
The Act requires any person who acts as an agent or sub agent, representative or nominee for or on behalf of any tenderer to
register himself and such public contract. (Vide sections 8 & 10).
12
Refer section 17.
5
- FIDIC Conditions of Contract for Plant and Design-Built - 1999 (Yellow Book
1999);
- Design & Build form of contract (ICTAD/SBD/4 – First Edition – May 2003) which
has been published by ICTAD (rarely used for GOSL projects); and
FIDIC Red Book, Pink Book and ICTAD/SBD/2 forms of contracts usually require re-
measurement of completed works for payment. However FIDIC Yellow Book and ENAA
forms of contracts usually stipulate lump sum payments linked with milestone completion.
FIDIC and ICTAD forms of contracts for Employer designed works have a provision for
allocating limited design responsibility to the contractor. FIDIC and ICTAD forms of
contract for design and build for the works designed by the contractor, allocate limited
design responsibility to the Employer.
Despite the availability of several forms of contract, ADB, JICA and WB prefer the use of
FIDIC Pink Book for construction contracts designed by the Employer.
The FIDIC Pink Book is based on the FIDIC Red Book which has been customized to
suit the requirements of funding agencies. Since there is no MDB harmonized version for
design, supply and installation contracts,13 ADB, JICA and WB prefer the use of ENAA
forms of contract for plant design, supply installation contracts. ENAA forms of contracts
demonstrate good contracting practices, fair sharing of risk and responsibilities and have
been largely tested in developed nations. Under ENAA conditions contracts, contractor
assumes major part of design, supply and installation responsibility and associated risks.
FIDIC also has recommended using the Yellow Book for plant, design and build contracts
with customized Particular Conditions of Contract to make the contracts compatible with
changes applied in the Pink Book to suit requirements of MDB’s. This facilitates the
EAs/IAs to use internationally recognized standard conditions of contract and forms
acceptable to such funding agencies.
4 CONTRACT MANAGEMENT
13
JICA is currently in the process of developing such MDB harmonized version for design and build contracts.
6
The terms “Contract Management” and “Contract Administration” are often used
interchangeably. In the GPMCM, the term “Contract Administration” is used to denote
contractual functions which are to be performed by an Engineer to the Contract upon the
issuance of the Letter of Acceptance continuing through and ending upon the issuance of
the Performance Certificate. Contract Management with respect to an Employer should
be carried out by the Project Director/Manger representing the EA/IA. FIDIC and most
other forms of contracts require an Engineer to perform certain contractual functions
which are usually termed as Contract Administration.
i. Mobilization;
ii. Execution;
i. Parties meet targets within key dates or periods specified in the contract;
iii. Parties fulfill their contractual, legal and regulatory obligations, including notification
requirements and making payments;
iv. Identify risks of cost overruns and prolongation of contract period are identified
through proper monitoring and their effects minimized by providing on time
information and alerts to take adequate and timely actions;
v. Manage claims for additional cost and time in an efficient and effective manner and
prompt action is taken to determine entitlement;
vi. Maintain contractual records including bonds and guarantees, insurance policies,
contractual correspondences, and records of resources utilized and reports with
regard to quality, progress and other aspects which are connected to performance
of the contract;
vii. Establish dispute resolution mechanisms and resolution of disputes, through multi-
tiered dispute resolution processes in accordance with the contract;
7
x. Carry out contract close-out after all payments have been made under the contract
and the works executed and completed under the contract are taken over; and
xi. Maintain open and effective communication between all parties using appropriate
channels and means, and providing feedback to enhance contract performance.
These could be in the form of meetings, discussions, site visits, and
correspondences.
Letter of Acceptance also referred to as the “Letter of Award”, is legally considered as the
Employer’s formal acceptance of an offer (bid/tender) made by the Contractor, thus
forming a valid and binding contract between parties when acknowledged its receipt by
the Contractor.
The FIDIC MDB Pink Book expressly states that if there is no such Letter of Acceptance,
then the expression “Letter of Acceptance” must be construed to read as the Contract
Agreement and the date of the Letter of Acceptance must be construed to read as the
date on which the “Contract Agreement” was signed. The Letter of Acceptance is ranked
second in priority amongst the documents constituting the Contract.
Contract Agreement is the document with highest priority amongst the documents
constituting the Contract. Contract Agreement specifies terms and conditions of the
contract. The purpose of the terms and Conditions of a contract is to identify and allocate
risks and responsibilities between the parties to the Contract.
Construction Contracts provide for the remedies for breach of its terms/conditions or
liabilities arising out of occurrence of specified events. Construction contracts usually
include terms and conditions to appoint and authorize a third party designated as the
Engineer to carry out certain functions and administer a contract on behalf of the
Employer. Under certain forms of contract, a party/person carrying out the duties of the
Engineer is designated as the Contract Administrator, Project Manager or Architect.
The General Conditions of Contract which should be read with Particular Conditions of
Contract constitute the Conditions of Contract. Particular Conditions which is higher in
priority than General Conditions, may vary, amend or add in to the General Conditions of
Contract to the extent detailed in the Particular Conditions. Hence, care must be taken to
draft the Particular Conditions so as not to create any ambiguity or inconsistency.
Unless the Particular Conditions state otherwise FIDIC and ICTAD form of Contracts
require the parties to enter into a Contract Agreement within 28 days after the receipt of
the Letter of Acceptance by the Contractor. Parties however have the liberty to agree
otherwise.
Stamp Duty and other statutory charges if any related to contract execution has to be
borne by the Employer, unless otherwise specified in a contract.In ICTAD/SBD/02, the
8
Contract Agreement specifically states that the preparation of the Contract Agreement is
the responsibility of the Employer.
General principles applicable to contract law in Sri Lanka (offer and acceptance, legality,
breach of contract, types of damages, and interpretation of contract) are described in
detail in Annex 1 for further reference.
Contract documents which constitute the contract between parties shall comprise the
following documents (as per FIDIC Pink Book) and their order of priority shall be in
descending order in the list, i.e. the documents listed in the top of the list have highest
priority for the purpose of interpretation:
i. Contract Agreement.
ii. The Letter of Acceptance.
iii. Memorandum of Understanding (if any).
iv. The Letter of Tender.
v. The Addenda.
vi. The Particular Conditions of Contract. [– Part A]
vii. [The Particular Conditions of Contract. [– Part B]
viii. The General Conditions of Contract.
ix. The Specifications/[Employer’s Requirements].
x. The Drawings.
xi. The completed Bill of Quantities/ Schedules.
xii. The Contractor's Proposal and any other documents forming part of the Contract.
xiii. Supplementary Information.
Different forms of Contract give different definitions for the Commencement Date.
The Pink Book defines the Commencement Date14 as the date specified in the Particular
Conditions of Contract or the date that the Engineer instructs the Contractor to
commence the Works upon the satisfaction of the conditions precedent stipulated in
Section 8.1(a) to (d) of the Pink Book.
14
Refer Section 8.1of the Pink Book.
9
If the Engineer’s instruction to commence the Works and the notification are not received
by the Contractor within 180 days from his receipt of the Letter of Acceptance, the
Contractor is entitled to terminate the Contract.15
The FIDIC Red Book and Yellow Book stipulate that the Commencement Date shall be
the date notified to the Contractor by the Engineer and that date shall be within 42 days
upon the receipt of the Letter of Acceptance by the Contractor, unless otherwise stated in
the Particular Conditions of Contract. The Engineer shall give the Contractor not less
than 7 days’ notice of the Commencement Date.
The ICTAD/SBD/02 stipulates that the Commencement Date shall be the date notified to
the Contractor by the Engineer. The commencement date must be within 14 days upon
the receipt of the Letter of Acceptance by the Contractor and notice of commencement
must not be less than 7 days, unless otherwise stated in the Particular Conditions of
Contract.
The ICTAD Conditions of Contract for Design & Build 2003 (ICTAD/SBD/04) stipulates
that the Start (Commencement) Date shall be 14 days after the Letter of Acceptance.
Loan/grant agreements entered into between the GOSL and the funding agency,
budgetary allocations and/or an assurance from the GOSL are examples of such financial
arrangements. If any notice of suspension of disbursement of funds has been received
the Employer from such funding agencies, it is required to give notice of same to the
Contractor forthwith.
In the FIDIC Red Book and the Yellow Book, the Employer is only obliged to provide
such evidence of financial arrangements within 28 days of receipt of any such request
from the Contractor.
ICTAD contract documents do not stipulate any obligation on the Employer to provide
evidence of his financial arrangements to the Contractor.17
The Employer shall appoint a person to act as the Engineer. The Engineer must be
named in the Contract Data (as per FIDIC, MDB version and ICTAD conditions of
contracts) or Appendix to Tender (FIDIC Red and Yellow books 1999 versions) or be
subsequently appointed in writing by the Employer after the award of Contract.
The Engineer is responsible for administering the Contract and supervision of the
15
Refer Section 16.2 (h) of the Pink Book.
16
Refer Section 2.4 of the Pink Book
17
Refer item i of the subparagraph A3.8.2
10
execution of the Works. The Engineer is not a party to the contract. The Engineer may be
either appointed as an individual or as a company which will in turn appoint an individual
to carry out the duties of the Engineer in the name of the company. 18
The Engineer does not have the authority to amend the Contract nor has authority to
relieve either party of any duties, obligations or responsibilities under the Contract.
FIDIC Pink Book imposes more stringent conditions on the Engineer’s scope of authority.
The Engineer is mandatorily required to obtain the specific approval of the Employer
under certain circumstances as defined in the Contract which include instructing
variations, agreeing or determining extension of time and additional costs under the Sub-
Clause 4.12 [Unforeseeable Physical Conditions] and approving a proposal for Variation
submitted by the Contractor. However, if an emergency occur affecting safety of life or
the works or of adjoining property the Engineer is permitted to instruct the Contractor to
do such things as may be required under the circumstances to abate or reduce such
risks.
In the FIDIC Red Book and Yellow Book the Engineer is required to obtain the approval
of the Employer only for any matter and to the extent as may be specified in the
Particular Conditions.
In ICTAD/SBD/02 the matters for which the Engineer must obtain the Employer’s
approval must be specified in Contract Data. There is also a responsibility cast upon the
Employer not to impose any other constraints on the Engineer’s authority unless agreed
to with the Contractor.
Defect Notification Period is defined in FIDIC forms of contracts as the period for notifying
defects in the Works or a Section of the Works (as the case may be) calculated from the
date on which the Taking-Over Certificate is issued for the Works or a Section of the
Works. FIDIC Conditions of Contract imposes a time restriction for the Defect Notification
Period to a maximum of two years. Similar provisions are incorporated in ICTAD/SBD/02.
During the Defects Notification Period, the Engineer may request the Contractor to
identify the cause of a defect. In such event, the Contractor is required to investigate the
cause, using design verification, investigation and/or testing, under the direction of the
Engineer. The cost of such search/investigation shall be at the cost of the Contractor if
the cause of such defect is attributable to the Contractor. Similar provisions are included
in ICTAD/SBD/02.
6 CONTRACT PERFORMANCE
The Contractor is required to design (if specified), execute and complete the Works in
accordance with the quality standard prescribed in the Specifications/Employer’s
Requirements, within the Time for Completion specified in the Contract or as extended
under the terms of the Contract and within the Contract Price stated in the Contract or
agree/determine by the Engineer subject to making adjustments in accordance with the
Contract.
18
For an example, in most of the projects where the NWSDB is the Implementing Agency, the General Manager/NWSDB is
named as the Engineer to the Contract while for other Contracts a Consultancy company is either named in the Contract as the
Engineer or is subsequently appointed as the Engineer.
11
The Contractor is required to complete any work which is outstanding on the date of a
Taking-Over Certificate, within such reasonable time as is instructed by the Engineer.
The Contractor is also required to complete any remedying of defects or damage, which
may be notified by the Employer or the Engineer on or before the expiry date of the
Defects Notification Period for the Works or Section of the Works (as the case may be).
Where the defect or damage is attributable to the Contractor,( i.e. any design for which
the Contractor is responsible, plant, materials, workmanship not being in accordance with
the Contract or failure by the Contractor to comply with any other obligation) the defect
or damage must be remedied at the risk and cost of the Contractor.
FIDIC and ICTAD forms of Contract permits the Contractor to remove from the site with
Employer’s consent, defective or damaged plant which cannot be repaired expeditiously
on Site, subject to the enhancement of the Performance Security or by providing other
appropriate security.
The Contractor is required to comply with any other contractual requirements, applicable
laws and regulations in performing the Contract.
The Employer is entitled to extend the Defects Notification Period for the Works or a
Section of the Works. The Employer may also give notice for Employer’s Claims, if and
to the extent that the Works, Section of the Works or a major item of Plant (as the case
may be, and after taking over) cannot be used for the purposes for which they are
intended because of a defect or damage attributable to the Contractor.
If the Contractor fails to remedy any defect or damage within a reasonable time or by
the date notified by the Employer, the Employer may:
i. Carry out the work himself or by others and recover the costs reasonably incurred
by the Employer from the Contractor;
iii. if the defect or damage deprives the Employer of substantially the whole of the
Works or any major part of the works, the Employer is entitled to terminate the
entire Contract as a whole, or in respect of such major part which cannot be put to
the intended use due to such defect or damage. In these circumstances the
Employer is entitled to recover all sums paid for the works or four such part. In
addition the Employer is entitled to financing costs, dismantling costs and site
clearing costs.
The Engineer shall issue the Performance Certificate to the Contractor with a copy to the
Employer, within a stipulated period after the latest of the expiry dates of the Defects
Notification Periods, or as soon thereafter.
The Engineer may withhold the Performance Certificate if the Contractor has failed to
12
submit all the Contractor’s Documents and complete and test all the Works, including
remedying any defects and damages.
In ICTAD/SBD/02, the Performance Certificate must be issued within 28 days after the
expiry of the Defects Notification Period or soon thereafter subject to the fulfilment of the
Contractor’s obligations under the contract.
7 CLOSURE OF A CONTRACT
8 CONTRACT ADMINISTRATION
ii. Notify the Employer and the Contractor of assignment of duties and delegation of
authority to a Resident Engineer and other Engineer’s Assistants;
iii. Notify the Employer and the Contractor of revocation of assignment of duties and
delegation of authority, if required;
iv. Review the Contractor’s work Program and if necessary notify the contractor of
the extent to which it does not comply with the Contract;
v. Monitor the progress of the works using the current work Program;
vi. Notify the Contractor if the Program fails to comply with the Contract, actual
progress is too slow to complete within the Time for Completion or actual
progress has fallen (or will fall) behind the current Program due to an event for
which the Contractor is responsible and ensure that the Contractor submits a
revised Program;
vii. Issue necessary clarification or instruction to the Contractor when there is any
ambiguity or discrepancy in the documents;
19
Refer Article 9.3.
13
viii. Issue the Contractor instructions and additional/modified Drawings which are
necessary for the proper execution of the Works and the remedying of any
defects;
ix. Review Contractor’s Documents and make comments if they are not complying
with the Contract;
x. Give notice and particulars to the Contractor of Employer’s claims for any
payments or for extension of the Defect Notification Period within the time
stipulated;
xi. Effect consultation with the Parties to reach agreement on certain matters in
accordance with the Contract and if agreement is not achieved, to make a fair
determination. Notifying Parties of any agreement reached or determination
made;
xiii. Effect certification of Payments including advance, Interim and Final Payment
Certificates within the periods stipulated in the Contract;
xvi. Grant prior consent for appointment of or revoking of the appointment of the
Contractor’s Representative;
xvii. Notify the Contractor of the locations, coordinates of grid points and levels of
benchmarks for reference if they are not specified in the Contract;
xix. Monitor the Contractor’s resources including Equipment, Materials and personnel.
Granting consent for removing any major item of equipment from the site when
not required;
xx. Ensure that the Contractor takes all reasonable steps to protect the environment
and to mitigate damage and nuisance to people and property. Also ensure that
emissions, surface discharges and effluent from the Contractor’s activities shall
not exceed the values stated in the Specification or prescribed by applicable
Laws;
xxi. Review Monthly Progress Reports submitted by the Contractor and make
comments if not complying with the requirements stipulated in the Contract.
xxiii. Issue instructions for dealing with fossils, coins, articles of value or antiquity, and
structures and other remains or items of geological or archaeological interest
found on the Site;
14
xxv. Ensure that the Contractor takes all reasonable steps to maintain the health and
safety of the Contractor’s Personnel;
xxvi. Ensure that the Contractor provide all necessary superintendence to plan,
arrange, direct, manage, inspect and test the work;
xxvii. Ensure that the Contractor’s Personnel are appropriately qualified, skilled and
experienced in their respective trades or occupations. Also ensure that the
Contractor’s Personnel who are incompetent, negligent or prejudicial to safety,
health, or the protection of the environment;
xxviii. Accept, review, verify and maintain, returns for deployment of the Contractor’s
Personnel and Equipment;
xxix. Ensure that the Contractor executes the Works and provide materials and plants
in compliance with the Contract and in accordance with recognized good
practices;
xxx. Grant prior consent for materials which are to be used in the Works;
xxxi. Ensure the quality of Works by carrying out examination, inspection or testing of
any works and reject any Plant, Materials or workmanship which is defective or
otherwise not complying with the Contract;
xxxii. Instruct the Contractor to remove and replace/re-execute any Plant, Materials or
works which is not in accordance with the Contract;
xxxiii. Grant extension of time for completion upon evaluation of a claim for delays
suffered due to an event for which the Contractor is not responsible, subject to the
Contractor’s timely notification and prior approval of the Employer if specified
under the Contract;
xxxvi. Instruct the Contractor of the date or dates on which Tests on Completion to be
carried out;
xxxvii. Review the results of the Tests on Completion and instruct retesting if the Works,
or a Section, fail to pass the Tests on Completion;
xxxviii. Issue Taking-Over Certificate to the Contractor, stating the date on which the
Works/Section were completed in accordance with the Contract, except for
certain minor outstanding works and defects which will not substantially affect the
use of the Works/Section for their intended purpose or reject the Issuing of
Taking-Over Certificate, giving reasons and specifying the work required to be
done by the Contractor to enable the Taking-Over Certificate to be issued;
xxxix. Instruct the Contractor to complete any outstanding work remaining at the time of
issuing the Taking-Over Certificate, within a reasonable time;
xl. Notify the Contractor, on behalf of the Employer to remedy any defect or damage
within the Defects Notification Period;
15
xli. Notify the Contractor promptly, on behalf of the Employer if remedying of any
defect or damage is not attributable to the Contractor;
xlii. Agree or determine a reasonable reduction in the Contract Price when the
Contractor fails to remedy any defect or damage by the notified date;
xliii. Notify the Contractor within 28 days after the defect or damage is remedied, to
repeat of any tests described in the Contract, if there is any doubt regarding the
performance of the Works;
xliv. Direct the Contractor to search for the cause of any defect;
xlv. Issue the Performance Certificate to the Contractor within 28 days after the latest
of the expiry dates of the Defects Notification Periods when the Contractor fulfills
all his obligations in accordance with the Contract;
xlvi. Notify the Contractor when any part of the Works are to be measured;
xlvii. Agree or determine the Contract Price by evaluating each item of work;
xlviii. Derive new rates or prices in accordance with the Contract; and
xlix. Instruct the Contractor to execute any works and/or purchase any Plant, Materials
or services under Provisional Sums:
b) Review the Day Work records/statements submitted by the Contractor and certify
if they are correct;
c) Certify for payment to the Contractor the first half of the Retention Money, when
the Taking-Over Certificate is issued for the Works;
d) Certify for payment to the Contractor the second half of the Retention Money,
after the latest of the expiry dates of the Defects Notification Periods;
g) Agree or determine the value at termination when the Employer terminates the
Contract due to default of the Contractor;
h) Determine the value of the work done and issue a Payment Certificate when the
Contract is terminated due to a Force Majeure event;
16
i) Manage Claims, including accepting claim notifications submitted by the
Contractor within the time stipulated in the Contract, ensuring proper and
adequate contemporary records are maintained by the Contractor and
reviewing/evaluating the detailed claim and supporting particulars of the basis of
the claim;
j) Respond to the Contractor’s claim with approval, or with disapproval and detailed
comments on the principles of the claim within the time period stipulated in the
Contract;
k) Agree or determine any extension of the Time for Completion and/or any
additional payment for which the Contractor is entitled in accordance with the
Contract;
In addition to above functions the Engineer is required to carry out following tasks to
facilitate the smooth execution of the contract:
iii. Arrange and chair any ad hoc meetings with other entities such as authorities or
utility agencies whenever required;
vii. Identify any critical issues which may affect the performance of the Contract
including progress, quality or price of the Contract and propose remedial action
to mitigate such issues and follow up the implementation of such action to
ensure effectiveness;
viii. Maintain daily site records and quality records including inspection records and
test reports;
ix. Assist Employer in reviewing the guarantees, securities bond and insurance
policies to ensure that they are complying with the Contract and remain effective
x. Assist the Employer in reviewing the financial status of the Contract and ensure
that sufficient funds are available for contract payment in both foreign and local
currencies;
17
xi. Communicate with funding agencies to discuss all the relevant matters of the
project;
xiv. Liaise with the local authorities and other government institutions to facilitate
obtaining of licenses and permits required to carry out certain activities;
xv. Advise the Employer in performing certain functions for which the Employer is
responsible;
xviii. Carry out design changes as required and issue necessary instructions/drawings
to effect such design changes.
Usually a contract is monitored based on time, cost and quality using the Contractor’s
works program, contract price and contract specification as baselines respectively.
The Contractor should submit his Statements in accordance with the contract stating the
amount he is entitled for based on the works completed during the period for which the
statement is made. The amount the Contractor is entitled for should be evaluated based
on rates or prices stated in the BOQ/Schedules for each item or rates/prices agreed or
determined by the Engineer and actual quantity of work carried out. The Engineer should
review such Statements to verify whether quantities given for each item is correctly
representing work actually completed on site.
However, it is not mandatory for the Engineer to certify interim payments, value of which
is less than the minimum payment amount specified in the Contract Data or Appendix to
the Tender/Bid.
Public entities have the responsibility to protect the interests of the Employer and under
appropriate circumstances, it may be necessary to withhold payments from Contractors,
strictly in accordance with the terms of the contract. Circumstances where it may be
necessary to withhold payment include, but are not limited to:
18
i. Upon termination of the Contract by the Employer;
iv. The cost of rectification or replacement of any defective works, until rectification or
replacement is completed; and
v. Value of work or obligation which the Contractor fails to perform, until the work or
obligation is performed.
During the term of a contract it may become necessary to make changes to the Works.
These changes should be instructed as a variation to the contract and the variation
should be managed in accordance with the provisions in the contract.
Changes to the scope of the Contract should not be instructed as variations but should
be affected through an amendment to the contract, which will require the agreement of
both parties to a revised contract price and time for completion of the Works. Contract
amendments require approval of relevant authorities depending on the value of the
contract.
The goal of the multi-tiered dispute resolution process is to resolve disputes before they
escalate to the next level. It is imperative therefore, that Employer personnel respond
promptly to all contractor inquiries, requests, notifications and claims. The initial steps to
be taken are:
ii. Research facts – the Employer should obtain all the information regarding the
dispute from all relevant sources, including the Engineer and the Contractor; and
iii. Evaluation – the Employer should review all of the facts in conjunction with the
requirements and terms of the Contract. The Employer should then determine the
appropriate course of action.
19
iii. Amicable Settlement; and
iv. Arbitration.
Parties to a construction contract who are unable to resolve their disputes in an amicable
manner through negotiations or by alternative dispute resolution mechanisms such as
adjudication are able to refer such disputes for settlement by way of arbitration.
Arbitration in Sri Lanka is governed by the Arbitration Act No: 11 of 1995, hereinafter
referred to as the “Arbitration Act”.
Please refer “Annex 2” for a detailed note on the salient provisions of the Arbitration Act.
Maintaining one set of complete master contract administration files with EA/IA is
essential. The files will provide a basis for settling claims and disputes, should they arise
in administrative, alternative dispute resolution process or court actions. Throughout the
life cycle of the contract, the contract administration files should contain:
ii. Copies of all specifications, standards, drawings or Guides incorporated into the
contract by reference;
viii. The originals of the Contractor’s records, returns, data or report submittals;
ix. Copies of all routine reports required by the contract such as approval requests,
and inspection reports;
xi. Copies of all letters of approval pertaining to such matters as materials, the
Contractor’s quality control program, method statements and work schedules;
xii. The records/minutes of all meetings, both internal and external. Including sign-in
sheets and/or agendas; and
xiii. A copy of all contractor statements and payment certificates with supporting
documents.
The Employer should maintain originals of all contracts in a central repository. This
allows project staff to reference past or current contracts for useful information relating to
a current project.
20
8.3.7 Construction Supervision, Quality Control and Quality Assurance
Engineer is responsible for supervision of construction works, to ensure the Works meet
the required standards stipulated in the Specifications/Employer’s Requirements. Usually
this is achieved through establishment of Quality Control and Quality Assurance
procedures to monitor the quality of Works, Materials, Plants and workmanship. The
Engineer shall ensure quality of Works through tests, inspections, investigations and
quality audits.
ii. To relieve either Party of any duties, obligations or responsibilities under the
Contract;
iii. Instructing Variations unless under emergency conditions or when the value of
the variation is less than the amount specified in the Contract;
v. Taking action under the certain Sub-Clauses which are constrained without
obtaining prior specific approval of the Employer in accordance with the Particular
Conditions of Contract;
vi. Agreeing or determining an extension of time and/or additional cost in the event of
encountering unforeseeable physical conditions; and
vii. Instructing a variation for a work which is not within the scope of the Contract.
9 TERMINATION OF CONTRACT
When a contract is terminated, the parties are relieved from further unperformed
obligations in accordance with the agreed terms and conditions. A contract may be
terminated under two distinct situations namely; termination for convenience or
termination for default.
A termination for convenience, also known as no-fault termination, allows the Employer
to terminate any contract, in whole or in part, at any time at its sole discretion, if it is
determined that such termination is in the best interest of the Employer.
i. Accordingly, the Employer shall provide the Contractor with written notice
specifying whether it is terminating all or part of the contract. The notice of
termination shall give the date of termination. If the contract is being selectively
terminated, the Employer should specify which part(s) of the contract are being
terminated.
a. Keep adequate records of compliance with this notice, including the extent
21
of completion on the date of termination;
c. Notify the Engineer, of any and all matters that may be adversely affected
by this Termination; and
iii. The Contractor will generally be paid for allowable costs incurred up to the
termination of the Contract. The Employer will not be liable for payment to the
Contractor for the terminated portion of the work or any work performed or costs
incurred after the effective date of termination.
iv. Upon receipt of any invoice from the Contractor for work performed prior to the
Notice of Termination, the Employer should thoroughly review the invoice to
ensure that no excessive costs are included.
A Contract may be terminated for default or breach of conditions that permit termination.
An Employer is not required to terminate a Contract even though the breach may permit
termination. Agencies may determine that it is in their best interest to pursue other
alternatives. Examples of such alternatives include extending the completion date,
allowing the Contractor to continue working or working to complete the outstanding work.
Termination for default should be used as a last resort and not as punishment. The
purpose of a termination for default is essentially to protect the interests of the Employer
while taking action to complete the work by another Contractor.
a. Whether the Employer has done everything as reasonably possible to assist the
Contractor and to complete the outstanding work;
c. The specific contractual failure(s) and the explanation provided for such failures;
d. The urgency of the need for the contracted Works. The Employer may need to
weigh the respective benefits and/or disadvantages of allowing a defaulted
Contractor to continue performance or engaging a new contractor;
e. The availability of the other Contractors and the time required to engage them
(compared to the additional time the current Contractor needs to complete the
work); and
f. Availability of funds and/or resources to re-contract in the event such costs cannot
be recovered from the defaulted contractor. Under a termination for default, the
Employer is within its rights to demand re-procurement costs from the
defaulting Contractor. Nevertheless, the Contractor may not be financially
capable of financing the re-procurement, or such demand may result in
protracted dispute resolution.
22
ii. If a Contractor is terminated for default, the contractor is liable for actual damages
and costs incurred by the Employer unless the contract states otherwise.
A Contract may not be terminated for default when the failure to perform is due to
reasons beyond the control of either party.
When an extraordinary event or circumstance beyond the control of the parties, or which
could not have been reasonably foreseen at the time of entering into contract such as
war, strike, riot, embargoes, or an event described as an act of God (such as hurricane,
flooding, earthquake, volcanic eruption, etc)prevents one or both parties from fulfilling
their obligations under the contract, a contract cannot be terminated for default. 20
When the Contractor fails fulfill any obligation under the Contract, the Engineer may
notify the Contractor through a Notice to Correct, specifying a reasonable period of time
for him to remedy such failure, However if the Contractor fails to comply with such Notice
to correct within the specified period, the Employer is entitled to terminate the Contract
for Contractor’s default.
iii. Reference to the clause under which the contract is being terminated;
iv. A concise, accurate statement of the facts justifying the termination; and
v. A statement that the contract being terminated may be re-procured and that the
contractor will be held liable for any additional costs incurred due to such re-
procurement. Before including this statement, the contract should be reviewed to
determine whether the provisions are available under the contract.
10.1 General
The contract closing process is usually a simple but detailed administrative procedure.
The purpose is to verify that both parties to the contract have fulfilled their contractual
obligations and there are no responsibilities and unfilled obligations remaining. In
addition, contract close-out is the time to assess the success of the contract and
determine if there are any lessons learned for future contracting.
20
The term “Force Majeure” is generally defined in the Contract Agreement.
23
A contract is completed when all works have been completed; all reports have been
delivered and accepted; all administrative actions have been accomplished; all Employer
furnished equipment and material have been returned; and final payment has been made
to the Contractor upon obtaining Contractor’s Discharge.
10.2 To initiate the close-out process, the Employer should first determine that the Contractor
has satisfactorily performed all required contractual obligations. A contract is ready for
closing when:
i. All Works have been completed, defects remedied, deliverables, including reports,
as built documents and operation/maintenance Guides have been delivered and
accepted by the Employer. Contract managers should compare actual performance
against performance measures, goals and objectives to determine whether all
required work has been completed; and
iv. All property inventory and ownership issues are resolved, including disposition of
any equipment or licenses purchased under the contract;
v. Final acceptance from the Engineer has been received (if applicable);
vi. Contractor is aware of and is in compliance with records retention requirements and
a plan has been developed for contract file maintenance; and
Any
vii. Any deficiencies found as part of the close-out process are documented and
communicated to all appropriate parties.
24
ANNEX 1
Sri Lankan Contract Law is primarily governed by Roman Dutch Law. However there are
some contracts such as bills of exchange and other negotiable instruments such as
promissory notes and cheques which are governed by English Law.
Under Roman Dutch Law “justa causa” or just reason was deemed adequate to satisfy
the requirement to have a legally valid contract. This differed from the English Law
requirement to have valuable consideration (which can be assessed/valued in pecuniary
terms) to give effect to a legally valid contract.
In contrast the concept of ”just reason” under our common law has a more wider
meaning than consideration and has been recognized as being applicable to contracts
other than those specifically governed by English Law in a number of cases. 21
The elements of a contract are "offer" and "acceptance”. “An offer is a proposal made by
one person to another of certain terms of performance with the intention that it be
accepted by such other person”22. Thus a Notice of Tender is merely an invitation to treat
and does not tantamount to an offer.
The Offeror is the person making the offer and the Offeree is the person to whom the
offer is made. An offer must be definite and must be communicated. An offer can only be
revoked before acceptance by the Offeree. After acceptance a binding contract comes in
to effect and thereafter it cannot be withdrawn. Acceptance must be made before the
offer is revoked, lapsed or rejected.
21
In the case of Lipton v Buchanan (1904) 8 NLR 49 it was held that a promise made to discharge an existing moral obligation
or to perform an act of benevolence or generosity is adequate to satisfy justa causa. In Public Trustee vs Udurawana 51 NLR
193 it was recognized that a promise was legally enforceable under Roman Dutch Law.
22
Vide Weeramanthri C.G, Law of Contracts, page110.
25
ii. Actual or presumed intention of the parties to create a legal obligation;
The following factors will vitiate agreement/consent of parties thus making the contract
invalid:
i. Error/Mistake
A mistake can be one that prevents agreement or which nullifies and agreement
or which renders a contract voidable. A mere error of judgment does not give rise
to a mistake to invalidate a contract, but must be such that demonstrates there
never was any real agreement amongst the parties.
iii. Duress
The parties must enter in to a contract willingly if it is to be enforceable. However
there can be situations where this may be in question. This occurs when a person
acts in fear or perceived danger/threat. “Economic Duress” or legitimate threat to
financial interests is another category of duress recognized by English and
Australian courts.
v. Illegality
Contracts which are illegal by statute (for instance, prohibitions under the excise
Ordinance, Gaming Ordinance etc), by common law (contracts to commit crimes
or civil wrongs, to defraud revenue, promotes corruption etc) or contracts
contrary to public policy cannot be enforced.
26
vi. Misrepresentation or fraud
i. Completeness of Performance;
When either party to the Contract breach the Contract, the other party can seek relief in
the form of the following legal remedies:
The main principle on which damages for breach of contract are awarded in Sri Lanka is
that the sum to be awarded should, as nearly possible be a sum which will put the
wronged party in the position which he would have enjoyed if the wrong had not
occurred. The amount of damages should include compensation to the party for actual
losses well as loss of profit.
i. General (direct loss suffered by a plaintiff /gain not obtained as any other person in
similar circumstances); and
If liquidated damages come under the guise of a penalty Courts will not enforce penalties
as damages. The Courts will thus examine the contract to ascertain whether what is
termed as liquidated damages are in fact penalties.
27
A1.6 Interpretation of a Contract
A contract should be interpreted as a whole and words should be interpreted in line with
everyday usage and given their natural and ordinary meaning. Generally, the meaning of
a contract is determined by looking at the intentions of the parties at the time of the
contract’s creation. When the intention of the parties is unclear, courts look to any
custom and usage in a particular business and in a particular locale that might help
determine the intention. Courts will generally give effect to the manifested intention of
the parties as laid down in a Contract Agreement. 23
The contract will, in many instances, comprise multiple documents which may at times
conflict with each other. The contract should set forth the order of priority or precedence
in the event of conflicts between documents.
ii. Where multiple documents deal with the same issue, the priority should be in
order of time, with the last document agreed in time having the highest priority;
iii. Where multiple formats deal with the same subject matter, such as drawings and
specifications, project staff would normally want the written word (such as the
specifications) to have priority as they would provide the more detailed description
of what was intended;
iv. Documents that are made part of another document are considered to be
complimentary in nature, so they have to be read and interpreted as a whole; and
The contra proferentem rule is a legal rule of interpretation which requires that any
ambiguities in the language in a clause are to be construed against the party who drafted
the clause. Such interpretation must however, be consistent with the language of the
whole contract and the intention of the parties.
23
Upon assuming the Contract Management function it is important that project staff familiarize themselves with the details of
the contract. This is important so that project staff will have a general understanding of the roles and responsibilities that are
identified in the contract enabling them to interpret the contract for manage performance, especially when issues arise.
28
ANNEX 2
ANNEXE 2 – ARBITRATION ACT NO: 11 of 1995 (ARBITRATION ACT)
Section 3(1) of the Arbitration Act sets out that an arbitration Agreement can either be an
arbitration clause in a contract or in the form of a separate Agreement. The most vital
element is that in order to constitute a valid agreement it must be in writing. The Section
further states that an agreement shall be considered to be in “writing” if it is contained in
an exchange of letters, telegrams or other means of telecommunication which provides a
record of such Agreement. Thus, if the Contract which contains the arbitration clause is
not duly executed or signed, parties are prevented from invoking the arbitration clause.
The freedom of contractual parties to determine the manner in which they wish to resolve
their disputes is a reflection of the consensual nature of arbitration. This is reflected in
number of provisions of the Act where the parties are at liberty to decide and agree on
the number of arbitrators (Sec 6(1), procedure for appointing arbitrators Sec 16(1), the
Rules of Procedure (Sec 17) and the law applicable to the substance of the dispute (Sec
24(1).
25
Further reading: Arbitration Law in Sri Lanka, Edited by KanagIsvaran K,PC &Wijerathene S.S., published by ICLP, 3rd edition
2011.
26
Amarasinghe J in Merchant Bank of Sri Lanka vs Tillekaratne D.V.D.A. (S.C Appeal No: 43/2001. 2001 (B.L.R.) held that
“Party Autonomy is a fundamental principle of Arbitration law and this is given effect by the legislature in Section 7(1) of the
Act”.
29
iv. Section 13-interim measures of protection;
v. Section 20-summons for appearance;
vi. Section 21-refusal/failure to attend before the tribunal for examination; and
vii. Section 30-delay in prosecuting claims.
Section 6 of the Arbitration Act states that the parties are at liberty to determine the
number of arbitrators. If they appoint an even number, the arbitrators so appointed must
appoint an additional arbitrator who will function as chairman of the arbitral tribunal.
The Arbitral Tribunal can comprise of a single arbitrator. If the parties have not agreed to
the number it shall be a panel of 03. Parties are also free to determine the manner in
which the arbitrator can be appointed.
A2.6 Awards
Form and content of award are stated in Section 25 of the Arbitration Act which
mandates that an award must be in writing and signed by the arbitrators constituting the
arbitral tribunal. A specific reference to date and place must be stated.
Most importantly, (unless there is an agreement to the contrary) the Arbitral Tribunal is
permitted to make an award for payment of money (whether on a claim for liquidated or
unliquidated amount) and order interest at the rate agreed by the parties (If there is no
such agreement the rate in to be legal interest prevailing at the time of making of the
award) to be paid on the principal sum awarded from date commencement to date of
award, plus any interest awarded for any period prior to the institution of proceedings
together with further interest as stipulated in Section 28 of the Arbitration Act.
Parties are free to determine the rules of procedure governing the conduct of arbitration
under Section 17 of the Act. They may either select institutional procedures or ad-hoc
procedures. Parties need to be mindful of costs when selecting the rules of procedure
such as International Chamber of Commerce (ICC Rules),27 or UNCITRAL 28rules.
One option to consider is to adopt the Rules of the ICLP Arbitration Centre29. Institute For
the Development of Commercial and Practice (ICLP) is an institutional arbitration Centre
and operates under a council of management. ICLP has its own rules which the parties
may incorporate in the arbitration clause.
If parties select ad-hoc arbitration and decide on their own procedures they must ensure
that such procedure is in compliance with the provisions of the Act and is not subject to
legal challenge during enforcement.
27
International Chamber of Commerce-Court of Arbitration (ICC Court)-website: www,iccwbo.org.
28
United Nations Commission on International Trade Law (UNCITRAL) Arbitration Rules. Website: www.uncitral.org.
29
ICLP website – www.iclparbitrationcentre.com.
30
A2.8 Finality of the Arbitral Award
According to Sec 26 of the Arbitration Act the arbitral award made by the tribunal is
deemed to be final and binding on the parties (Unless set aside on the specific grounds
set out in Sec. 32)30.
The specific grounds on which an arbitral award may be set aside by High Court are
stipulated in Sec. 32.The application must be made within 60 days of the receipt of
award.
A2.9 Enforcement
In accordance with the provisions of Section 31 of the Act an application for enforcement
must be made to the relevant High Court by way of petition and affidavit together with the
Original or a certified copy thereof to the satisfaction of court.
The application must be made within one year after the expiry of 14 days of the making
of the award.
It is pertinent to note that unless it is on a question of law and only with leave from
Supreme Court no appeal or revision is permitted. If the Contract Agreement contains an
exclusion clause where parties have specifically agreed on excluding the right of appeal,
leave to appeal is prohibited. (Vide Sections 37(4) and Section 38).
30
“In Light Weight Body Armor Vs Sri Lanka Army SC (CHC) Appeal no. 27/A 2006 ShiraneeTilakawardena J……. held that “ in
exercising jurisdiction under Section 32 of the Act, the Court cannot sit in appeal over the conclusions of the Arbitral Tribunal by
re-scrutinizing and re-appraising the evidence considered by the Arbitral Tribunal.” and that “the Arbitral Tribunal is the sole
judge of the quality as well as the quantity of the evidence and it is not open for the court to take upon itself the task of being a
judge of the evidence before the tribunal. It is not open to the court, in terms of the Arbitration Act to probe the mental process
of the decision contained in the Award and to even speculate or query the reasoning that impelled the decision. Therefore an
Award is not as a rule vulnerable to challenge except to the process and ambit contained in Section 31 of the Act.” “Section 32
contains the sole grounds upon which an Award may be challenged and set aside, courts have no jurisdiction to correct patent
and glaring errors of law in Award unless it can be established to be a jurisdictional error or can be shown to be of such a
nature as to render the award contrary to public policy.”
31
ANNEX 3
The widely used family of Contracts is commonly referred to as FIDIC contracts. There
are certain forms of contracts included within Standard Bidding Documents published by
funding agencies such as World Bank and ADB, which are currently used for foreign
funded projects. ICTAD contracts are widely being used for domestic contracts. However,
upon the enactment of the Construction Industry Development Act, No. 33 of 2014, it is
mandatory to use ICTAD documents for any contract awarded in Sri Lanka, except for
contracts between GOSL owned entities and foreign contractors. 31
The terms and conditions in construction contracts are contained in several documents
which form the contract. Documents forming a contract consist of Contract Agreement,
Letter of Acceptance, Memoranda of Understanding (if any), Letter of Tender, Addenda,
Particular Conditions of Contract, General Conditions of Contract,
Specifications/Employer’s Requirements, Drawings, Bill of Quantities/ Schedules,
Contractor's Proposal (if any) and Supplementary Information (if any).
General Conditions of Contract are standard sets of terms and conditions which should
be read in conjunction with particular conditions.
There are different forms of contracts; namely construction only contracts where the
contractor executes works which are designed by the Employer or a consultant
appointed by him; design and build contracts where the Contractor will design and build
the works; EPC /turnkey contracts where the Contractor executes every stage of the
project including design, procurement and construction until handing over of completed
works, which are ready for use/operation; design, build and operate contracts where a
Contractor will design, build and operates/maintain the works upon completion.
ii. Allocate risks to the parties that are most suitable to bear such risks; and
iii. Sets out procedures to follow in various stages of the contract namely execution
of the works such as commencement, execution, completion and handing over,
defects notification period, contract close out, changes, claims, suspension,
termination and dispute resolution.
There are several types of General Conditions of Contract available under different
standard forms of contracts published by various organizations such as FIDIC, ICTAD,
ADB and WB. The following are the four major types of contracts, which are being used
in infrastructure projects implemented by GOSL.
31
In contrast sub paragraph 1.3.3 of the NPA Guidelines stipulates that in the case of foreign funded projects, if the funding
agencies require their SBDs to be used, this requirement would prevail. Hence, CIDA should clarify this position with GoSL
and the funding agencies.
32
A3.3 Construction Contracts
Construction contracts require a Contractor to execute works which are designed by the
Employer or a consultant appointed by him. It is also possible to allocate a Contractor to
carry out a limited design scope under construction contracts. Payments in construction
contracts are usually based on re-measurement (measure and pay) where the Engineer
certifies payments for works completed after taking measurements. It is however,
possible to include certain items of works within a construction contract, for which
payments can be made on a lump sum basis (e.g. FIDIC Red Book and Pink Book,
ICTAD SBD/1, SBD/2 and SBD/3).
Design and Build contracts require the Contractor to design and build the Works.
However it is possible to include in the contract certain items of works which are not
designed by the Contractor but by the Employer or a consultant appointed by him.
Payments for work in Design and Build contracts is usually in lump sums although
payment for certain items of works can be made on a re-measurement (measure and
pay) basis (e.g. FIDIC Yellow Book, ICTAD SBD/4 and ENAA).
Turnkey Contracts require the Contractor to carry out every stage of a project from its
inception to completion, including conceptual design, detail design, procurement and
construction. The project should be handed over to the employer/owner under full
operational conditions. The Employer may administer the contract himself or appoint an
Employer’s representative to act on his behalf under the contract. The payment for this
type of contract is usually on a lump sum basis. (E.g. FIDIC Silver Book).
Design Build and Operate contracts require the Contractor to design, build and operate
the Works. However in this type of contract, the Engineer’s role is excluded and duties
that are usually performed by the Engineer such as determining the value of Works,
costs or extensions of time, are carried out by a party/person designated as the
“Employer’s Representative” who is responsible for making determinations on the
matters relevant to the Contract”. The payment for this type of contract is - usually lump
sum type contracts. (e.g. FIDIC Gold Book)
33
2 Scope of Construction of Works Design and Conceptual Conceptual design,
Contract for which designs are construction of design, detailed detailed design,
provided by the the Works. design, procurement,
Employer or a consultant However there procurement and construction and
appointed by him. may be certain construction of the operation of the
However there may be a items for which Works. Works.
limited design scope designs are
allocated under the provided by the
contract. Employer or a
consultant
appointed by him.
4 Effectiveness When the Employer When the On the date stated When the Employer
of the Contract issues the Letter of Employer issues in the Contract issues the Letter of
Acceptance to the the Letter of Agreement Acceptance to the
Contractor. Acceptance to Contractor.
the Contractor.
5 Payments for Usually re-measurement Usually lump sum Lump sum type Lump sum type
completed (measure and pay) type type contracts, contracts, contracts, requiring
works requiring the Engineer to requiring the requiring the the Employer’s
certify payments for Engineer (Project Employer or his Representative to
actual quantities of work Manager for Representative to certify payments for
done. There may certain ENAA) to certify certify payments works completed
items of works for which payments for for works based on installments
payments are certified works completed completed based specified in the
based on lump sums. based on on percentages of Contract.
percentages of lump sums.
lump sums.
There may
certain items of
works for which
payments are
certified on a
measure and pay
basis.
The FIDIC Construction form of Contract (the “Red Book”) is intended for Construction of
Building and Engineering Works Designed by the Employer. The main features of this
Contract can be summarized as follows:
i. It is suitable for all types of projects where the main responsibility for design lies with
the Employer (or its Design Consultant) although provision can be made for the
Contractor to design elements of the Works.
ii. The administration of the Contract including approval of the Works, certification of
payments and determination of entitlement of the Contractor for additional costs and
extensions of time, is carried out by the Engineer.
34
iii. Payment to the Contractor is based upon work done and rates are determined
according to a Bill of Quantities (a Standard Method of Measurement should be
stated). The amount paid will reflect or correspond to the Works that have been
completed on site.
iv. Risk sharing is balanced between the parties to the contract. For example, the
Employer usually assumes the risks of unforeseeable “adverse physical conditions”.
vi. The Contractor has a certain degree of financial protection for performance of the
Works in that the Contractor can request evidence from the Employer of his
financing arrangements available to pay the estimated Contract Price.
vii. Materials can be paid for both on and off site if strict criteria are followed, including
the listing of materials for which payment maybe sought within the Contractor’s
tender
A3.7.2 FIDIC Construction Form of Contract MDB Harmonized - Pink Book 2010
The FIDIC Construction form of Contract for Multilateral Development Banks Harmonized
Edition 2010, (the “Pink Book”) is intended for Construction of Building and Engineering
Works Designed by the Employer and is funded by a participating Development Bank.
In comparison to the FIDIC Red Book, the Pink Book imposes stricter
obligations/standards on both the Employer and the Contractor. Examples include:
ii. Employer’s claims: The Employer must give notice of a claim as soon as
practicable and at least within 28 days of the Employer becoming aware, or when
it should have become aware of the circumstances giving rise to the claim; and
iii. Termination by Contractor: mere failure of the Employer to perform its obligations
is not a sufficient basis for termination of the contract by the Contractor. The
breaches of contract committed by the Employer must instead 'materially and
adversely affect the economic balance of the contract and/or the ability of the
Contractor to perform the contract' in order to provide a sufficient basis for
termination of the contract by the Contractor.
(The “Pink Book”) has included additional grounds for termination namely:
ii. if the Engineer does not give the Contractor instructions on the execution of
the Works 180 days after the letter of acceptance.
35
In addition, the Pink Book includes a number of other clauses addressing matters of
concern to MDBs, which are summarized below:
i. Specific provisions relating to Bank audits and inspections of project site and
accounts and other documents;
ii. Provisions to safe guard the well being of workers employed by the
Contractor;
The following amendments have been incorporated into the Pink Book in comparison to
the Red Book.
v. Cost no longer refers to reasonable profit but states profit since at clause 1.2
profit is fixed at 5% unless stated otherwise in the contract data.
vi. Sub-Clause 1.5: is a new clause that allows the lender’s representatives to
inspect the site and audit the Contractor’s accounts and records relative to the
project.
vii. Sub-Clause 2.1: access to the site must be given such that the Program can
proceed “without disruption”.
36
viii. Sub-Clause 2.4: the Employer has to demonstrate its ability to pay the contract
price before “the commencement date” and also “punctually”.
ix. Sub-Clause 2.5: the Employer must give notice of its claims within 28 days.
While this time frame is more onerous, no further condition precedents have been
added.
x. Sub-Clause 3.1: the Engineer has to obtain the Employer’s approval before
dealing with claims in respect of unforeseeable physical conditions and the issue
of variations to the Works.
xi. Sub-Clause 3.5: the Engineer has to give its determination “within 28 days from
receipt of the corresponding claim or request…”
xii. Sub-Clause 6.2: there is an obligation upon the contractor to inform its personnel
of their liability to pay local income tax
xv. The Contractor has reasonable proof that funding is in place; and
xvii. Sub-Clause 8.6: the Contractor can be paid for acceleration measures to
overcome Employer delays.
xviii. Sub-Clause 13.1: the Contractor is not bound to carry out a variation if it would
“trigger a substantial change in the sequence or progress of the works”.
xix. Sub-Clause 15.5: whilst the Employer can terminate for convenience it cannot
terminate to pre-empt a just termination by the Contractor.
xx. Sub-Clause 15.6: is a new clause that attempts to deal with corrupt and/or
fraudulent practices.
xxi. Sub-Clause 16.2: the Contractor must now demonstrate that the Employer’s
failures must “materially and adversely affect the economic balance of the
contract and/or the ability of the contractor to perform the contract” prior to
termination. There are however two further grounds allowing the Contractor to
terminate. Failure of the funder to provide funds; the failure of the Engineer to
give the Contractor instruction to commence execution of the Works 180 days
after the letter of acceptance.
xxii. Sub-Clause 19.2: in order to claim force majeure the claiming party must
demonstrate that it has been prevented from performing “its substantial
obligations”
xxiii. Sub-Clause 20.6: arbitration rules may differ according to the origin of the lending
Employer.
37
A3.7.3 FIDIC Plant and Design-Build Form of Contract - Yellow Book 1999
The FIDIC Plant and Design-Build form of contract (the “Yellow Book”) is intended for
Plant and Design-Build for electrical and mechanical plants and for building and
engineering works designed by the Contractor.
i. It is suitable for all projects where the main responsibility for design lies with the
Contractor based upon the Employer’s Requirements even if provision is made
for the Employer (or his Engineer) to design certain elements of the Works;
ii. The administration of the Contract including approval of the Works, certification of
payments and determination of entitlement of the Contractor for additional costs
and extensions of time, is carried out by the Engineer;
iii. Payment to the Contractor is based upon a Lump Sum price and against a
schedule of milestones to be achieved by the Contractor. This type of payment
mechanism indicates that the Yellow Book will most likely be used for process
plants where a high degree of offsite manufacture of plant and equipment is
foreseen, and payments cannot therefore be made on site on the basis of
inspection of materials. The terms for lump sum based payments should be
drafted to ensure that a proper account of the materials is provided i.e. require the
Contractor to provide a list of such plant and equipment within the Contractor’s
tender similar to the terms provided in the Red Book; and
iv. Testing procedures leading to completion are likely to be more complicated than
those found in the Red Book. Tests after Completion shall be carried out by the
Employer in addition to Tests on Completion.
v. The Yellow Book shares with the Red Book the provisions noted above relative
to:
Risk sharing.
FIDIC EPC/Turnkey form of Contract (the “Silver Book”) is intended for EPC/Turnkey
Projects. Under this form of contract, the Contractor assumes responsibility for a wider
range of risks than under the Red and Yellow Books. To obtain increased certainty of the
final price, the Contractor is often asked to cover such risks such as the occurrence of
poor or unexpected ground conditions. If the Contractor is to carry such risks, the
Employer must provide him time and opportunity to obtain and consider all relevant
information before the Contractor is asked to sign on a fixed contract price.
i. Design liability rests solely with the Contractor. The Employer will provide their
requirements for design but these are often in the form of a brief performance
specification;
38
ii. The Contractor carries out all engineering, procurement, and construction, often
including performance tests after completion; a “turn-key” project allowing
operation of the facility upon completion;
iii. Payments are made on a lump sum basis and the payment terms are most likely
similar to those envisaged under the Yellow Book;
iv. The Employer should pay the Contractor an amount more than the Employer
would have paid under a Plant and Design-Build form of contract, given that the
Contractor assumes the total responsibility for the design and construction of the
works, including all the risks involved;
v. The Employer can expect a higher degree of certainty than the agreed contract
price and time will not be exceeded;
vi. The Employer need not be involved in the day-to-day progress of the construction
works, provided the end result meets the performance criteria that the Employer
has specified; and
vii. It is not required to obtain the services of an Engineer to administer the Contract.
The Employer may appoint an Employer’s Representative to supervise and
provide instruction on the Execution of the Works by the Contractor.
When the Red Book or Yellow Book is used, the Employer pays the Contractor only
when specific risks occur. The Contractor does not therefore have to account for risks
that are difficult to value in the tender. The Employer has a great degree of uncertainty in
respect of the final price and the final time for completion. When the Silver Book is used,
however, the Employer passes the responsibility for most of the risks to the Contractor
for a higher contract amount and therefore, the Employer has a great degree of certainty
in respect of the final price and the final time for completion.
The Silver Book ensures certainty of cost and time. The Contractor is asked to allow
within its tender for a wide range of risks relative to cost and time; such risks will most
likely include all ground conditions (potentially in a country of which the Contractor will
have little knowledge) and the completion of the Works will be based upon a strict but
often brief performance related specification.
The Employer will still bear certain risks such as Force Majeure but the unbalanced risk
profile of this Contract will undoubtedly be a higher price; a factor that Employers must
accept and hence select only a small number of contractors to give tenders.
Given the above circumstances, in the event the Employer selects the Silver Book, the
Employer should recognize the significant costs for a Contractor to produce a tender.
Similarly where Employers have chosen a turnkey style of contract, the Contractor should
be given complete freedom to carry out the Works in the chosen manner in order to
satisfy the performance criteria laid down by the Employer.
If the Employer cannot grasp such factors, or the tender time is too short to allow the
Contractor to compile an adequate tender, or considerable amounts of work are
underground, or difficult to inspect, it is recommended that the Employer uses the Yellow
book, accepting some additional risks and receiving a lower tender price.
39
A3.7.5 Comparison of the Main Features of FIDIC Red, Yellow and Silver Books.
Type of Scope Recommended for Recommended for the Suitable for a process or
building and engineering provision of electrical power plant, a factory or
works if most (or all) of and/or mechanical plant similar facility, or an
the works are to be and for building and infrastructure project or other
designed by (or on engineering works if most type of development, if (i) a
behalf of) the Employer. (or all) of the works are to higher degree of certainty of
be designed by (or on final price and time is
behalf of) the Contractor. required, and (ii) the
Contractor takes total
responsibility for the design
and execution of the project.
Effectiveness The Contract typically The Contract typically The Contract typically
becomes legally becomes legally effective becomes legally effective in
effective when the when the Employer issues accordance with the Contract
Employer issues the the Letter of Acceptance to Agreement.
Letter of Acceptance to the Contractor.
the Contractor. The Letter of Tender may be
Alternatively, there may be worded so as to allow for the
Alternatively, there may no such Letter, and the alternative of the Contract
be no such Letter, and Contract becomes becoming effective when the
the Contract becomes effective in accordance Employer issues a Letter of
effective in accordance with the Contract Acceptance.
with the Contract Agreement.
Agreement.
Responsibility of The Contractor designs The Contractor provides The Contractor provides
the Contractor (but only to the extent plant, and designs (except plant, and designs and
specified) and executes as specified) and executes executes the other works,
the works in accordance the other works, all in ready for operation in
with the Contract (which accordance with the accordance with the Contract,
includes the Contract, which includes which includes his Tender
Specification and his Proposal and the and the Employer's
Drawings) and the Employer's Requirements. Requirements.
Engineer's instructions.
Certification of Interim and final Interim and final payments Interim and final payments
Payments payments are certified are certified by the are made without any
by the Engineer, Engineer, typically certification: typically
typically determined by determined by reference to determined by reference to a
40
measurement of the a Schedule of Payments. Schedule of Payments.
actual quantities of the
works and applying the The alternative of The alternative of
rates and prices in the measurement of the actual measurement of the actual
Bill of Quantities or other quantities of the works and quantities of the works and
Schedules. applying the rates and applying the rates and prices
prices in a Schedule of in a Schedule of Prices can
Other valuation Prices can be specified in be specified in Particular
principles can be Particular Conditions. Conditions.
Specified in Particular
Conditions.
Risk Allocation The General Conditions The General Conditions Disproportionately more risks
allocate the risks allocate the risks between are allocated to the
between the parties on a the parties on a fair and Contractor under the General
fair and equitable basis: equitable basis: taking Conditions. Tenderers will
taking account of such account of such matters as require more data on
matters as insurability, insurability, sound hydrological, sub-surface and
sound principles of principles of project other conditions on the Site,
project management, management, and each to the extent that this data is
and each party's ability party's ability to foresee, relevant to the particular type
to foresee, and mitigate and mitigate the effect of, of works, and more time to
the effect of, the the circumstances relevant review the data and evaluate
circumstances relevant to each risk. such risks.
to each risk.
Note:32
FIDIC Short Form of Contract (the “Green Book”) was issued in 1999. This Contract
recognized the need for simpler and shorter contracts to suit projects with a relatively
low Contract Price and short time duration.
This form of Contract provides for a greater degree of flexibility, and follows the same
layout as the other forms of contract in the Rainbow Suite. It has only fifteen clauses
within a total of ten pages. The clauses are short and easily understood; whilst design
can be carried out by either party. An Engineer is not required, but the Employer may
appoint a Representative. Payment can be made on either a lump sum or re-
measurement basis.
As with the major forms of Contract, this short form of contract includes guidance notes
(noted as not forming part of the Contract) as well as an Agreement together with its
Appendix and Rules for Adjudication. The noticeable feature is the absence of
Particular Conditions because FIDIC is of the view that the Green Book can work
without such conditions. However, a cautionary note is provided that the Employer may
amend the draft form of Contract to include Particular Conditions where the Employer
deems it necessary.
A3.7.7 FIDIC Form of Contract for Dredging and Reclamation Works - Blue Book 2006
This form of contract is designed specifically for use in connection with dredging and
reclamation projects. It is similar to the FIDIC Short Form of Contract (the Green Book)
but differs from the major forms in many ways. The most important difference is that it
32
Extracted from the FIDIC Contracts Guide First Edition 2000.
41
was drafted in close collaboration with the International Association of Dredging
Companies (IADC) and as such has a great input from Contractors from the outset. The
current version of the Form of Contract for Dredging and Reclamation Works is the first
edition issued in 2006.
The Blue Book is like the Green Book in that it is abbreviated and flexible. The general
conditions in the Blue Book are only 16 pages and 15 clauses long. The format has also
changed from the major forms in that the agreement and appendix to the contract are
now found in the first section of the contract.
The Blue Book separates dredging from other works and removes any obligation on the
Contractor to remedy any dredging work defects after completion of the Works, as
stated in the taking-over certificate. The Blue Book also makes another dredging-
specific amendment to the Green Book by including 'climatic conditions more adverse
than those specified in the Appendix' as an additional event of force majeure.
Similarities with other forms of Contract are in the inclusion of standard forms, such as
securities, a section on adjudication (a one or three person DAB) with rules and the
adjudicator’s agreement and the all-important guidance section.
The Engineer is still recognized within the contract. However, design responsibility can
rest with either the Employer (and it’s Consultant) or the Contractor. Payment terms are
extremely flexible and a list of options, such as lump sum, re-measurement, and cost
plus are all noted within the appendix.
i. Notices by the Contractor in respect of a claim must be given within 28 days but
there is no fatal provision;
ii. Claim items are listed as defined risks which may entitle the Contractor to
monetary compensation or extensions of time;
iii. The defined risks, recognizing the likely impacts of whether upon the Contractor’s
ability to make progress, potentially soften the usual clause wording on one hand,
entitling the Contractor to make a claim if “any operation of the forces of nature
affecting the Site/and or the Works”, which was unforeseeable or against which an
experienced Contractor could not reasonably have been expected to take
precautions” but give the Employer (and contractor) less room for debate by also
defining the employer’s risk to be “climatic conditions more adverse than those
specified in the Appendix”; and
iv. If disputes are not settled amicably they are to be settled by referral to
adjudication by a DAB and, if the parties are dissatisfied with the DAB‟s decision
(or if no decision is made within the set timescale) the dispute can be referred by
the parties to Arbitration.
The Blue Book is a model of a contract drafted by those with a particular section of the
industry in mind and with the knowledge to incorporate the necessary variations to
standard forms that may have been considered for use in the past.
However, there is a concern regarding the vesting of plant provisions in the Blue Book.
Historically, vesting of plant provisions have been included in construction contracts to
42
grant rights to an employer to gain title to use and/or sell the Contractor’s equipment in
the event of termination for Contractor default or insolvency. Such vesting provisions
have caused problems not just on the Contractor side, where the value of the remaining
work may be less than the investment held in the equipment, but also on the
Employer’s side where its insurance and/or expertise does not cover the operation of
such equipment. These problems are particularly serious in the context of high-value
dredging/reclamation projects which require specific expertise and make a Contractor
default a devastating prospect.
The Blue Book does nothing to address the contractor’s concerns about this issue. In
the event of termination for Contractor default or insolvency, the Blue Book provides
that the Contractor must leave behind all materials and equipment, until the completion
of the Works. The Employer, however, does not have the right to sell the Contractor’s
equipment to recover outstanding monies. Additionally, the Employer is not permitted to
take over the obligations of a third-party entity which owns the equipment (that is, the
lessor of the dredging vessel) and repay hire charges. This would cause significant
concern to a Contractor as the obligor under a hire or hire purchase contract.
A3.7.8 FIDIC Form of Contract for Design, Build and Operate - Gold Book 2008
The FIDIC Conditions of Contract for Design, Build and Operate (DBO) Projects or
‘Gold Book’ combines design-build obligations with a long-term concession
arrangement which requires the Contractor to complete and maintain and operate the
facility during the concession period up to (20 years).
The Gold Book is used when the Employer does not have knowledge, expertise and
competent staff to carry out operation and maintenance functions in certain special
projects such as desalination plants. Also use of Gold Book is advantageous if there are
concerns regarding availability and cost of spare parts and consumables for any plant
or equipment involved.
i. Design, build plus operation and maintenance for 20 years by the contractor;
ii. Design and build phase risk allocation similar to the Yellow Book with exacting
completion criteria but also a cut-off date should the contractor be 182 days late
leading to termination if desired;
iii. Payment on a lump sum basis but includes a schedule of the type of assets that
can be replaced and the timing and costs of asset replacement. Costs of
replacing plant and equipment outside of the schedule will be borne by the
Contractor, as is a cost that exceeds the amount indicated in the schedule. Any
surplus in the fund at the end of the twenty years is divided equally;
43
iv. The Employer is entitled to deduct 5% from payments during the “operation
service period” (OPS) in case the Contractor does not fulfill its maintenance
obligations. The fund is to be released, if not spent, within the final payment to
the Contractor. The Contractor being responsible for its own defects arising from
design and construction in this period;
v. An independent audit body is jointly appointed for the duration of the OPS to
monitor the performance of the Contractor and Employer. Whilst having no
power, the parties are intended to give “due regard” to matters raised by the
audit body;
vi. A joint inspection is required at least two years before the end of the OPS; any
works identified must be carried out by the Contractor who will also face
completion tests similar to those at the end of the design and build phase.
Defaulting Contractors risk losing the 5% maintenance retention fund; and
vii. A standing DAB is established from a set date for the design and build phase
and a new one every 5 years during the OPS.
The key to success appears to be with the contractor who must design and build a
quality plant with low operating and maintenance costs; fit for purpose and built to last.
The Gold Book’s approach is to award a single contract to a single contracting
authority, such as a consortium or joint venture, so as to optimize the co-ordination of
innovation, quality, and performance. This single-contract approach was intended to
encourage Contractors to focus on the lifespan costs of the facility, the rationale being
that if the contractor is responsible for long-term operation it is in his interest to design
and build a quality plant with low operation and maintenance costs.
The Gold Book, therefore, combines design and construction with long-term operation
and maintenance. The design-build portion widely replicates the Yellow Book and
following commissioning testing, a long-term (20 years minimum) operation and
maintenance period triggers, during which the Contractor must achieve various
operational targets and return the plant to the Employer in an agreed condition.
This gives the Employer the assurance that the facility will remain in good operating
condition for the duration of the contracted period and is particularly helpful in countries
where the Employer cannot provide a suitable workforce. It is critical that the parties do
their utmost to co-operate for the prolonged period of the contract and to facilitate this
there are new provisions dealing with adjustments for ‘changes in technology, new
materials or products’ (rather than just changes in ‘law’ and ‘costs’ as in the Yellow
Book). This is a prudent inclusion given the inevitable change in technologies over such
a long period.
o The subcontractor is required to complete its scope of works such that no act or
omission shall constitute or cause a breach under the Red Book;
44
o Payments are back to back (where legal to do so) such that subcontractors may
find contractors using this as a shield to avoid paying for their own problems;
o The subcontractor is apparently responsible for the care of its works until the
main contract works are taken over. This situation will always require careful
management whatever the form of contract; and
o Notice provisions are passed through to the subcontractor but with a reduction
in time to 21 days to allow the contractor to fulfill its obligations under the main
contract.
This form of subcontract allows fair payment provisions for the subcontractor for all
liabilities of the contractor whilst obliging the subcontractor to allow the contractor to
make claims upwards.
A3.7.10 FIDIC Model Services Agreement for Consultancy Services - White Book 2006
The White Book was drafted to create conditions of agreement that would span the life
cycle of an engineer’s or consultant’s involvement. It is suitable where proposals for
such services are invited on either an international or domestic basis.
As with other FIDIC contracts there are both general and particular conditions of
contract that when combined set out the scope of the consultant’s work, payment terms
and the like. The White Book incorporates the same financial protection as afforded to
Contractors in that the consultant too can ask the Client (as opposed to the Employer) if
it has the ability to pay the Consultant’s fees.
While the White Book addresses the typical issues in a consultancy agreement, it is
generally weighed more in favour of the consultant. One such example is the
consultant’s obligation to undertake the ‘performance of his obligations under the
agreement’ using reasonable skill, care and diligence. However, this would not meet the
reasonable expectations of an Employer who would expect to be able to strictly enforce
certain contractual obligations such as the duty to commence on the date of
commencement, the duty to take out professional indemnity (PI) insurance and to
promptly notify the client of a change in circumstances.
Similarly, key personnel proposed by the consultant are subject to acceptance by the
Employer. However, there is no obligation on the consultant to retain personnel for the
duration of the project. A prudent Employer would ensure that the consultant will not
remove personnel without their consent. Further imbalances in favor of the consultant
exist in relation to insurance, indemnities, and compensation.
The White Book serves as a useful addition to the FIDIC portfolio for added consistency
across project contracts, but Employers may make amendments to suit their specific
requirements.
45
A3.8 ICTAD Forms of Contracts
This form of contract is intended for medium scale domestic contracts with works
designed by the Employer or his consultant and contract administration is carried out by
an Engineer appointed by the Employer under the contract. This form of contracts
includes general conditions of contract which should be read in conjunction with a set of
Contract Data. There are sixty four clauses within five sections from A to E, in the
general conditions of contract.
This form of contract is intended for major domestic works contracts with works
designed by the Employer or his consultant and contract administration is carried out by
an Engineer appointed by the Employer under the contract. It closely follows FIDIC Red
Book 1999 with several deviations including changes to numbering of clauses (e.g.
Numbers of clauses involving “Force Majeure” and “Claims, Disputes and Arbitration”
are interchanged) and important changes are:
ii. Removal of Sub-Clause 3.4: “Replacement of the Engineer” in the Red Book
from ICTAD/SBD/2;
iii. Removal of Sub-Clause 4.19: “Electricity, Water and Gas” in the Red Book from
ICTAD/SBD/2;
v. Removal of Sub-Clause 6.1: “Engagement of Staff and Labour” in the Red Book
from ICTAD/SBD/2;
46
vi. Removal of Sub-Clause 7.1: “Manner of Execution” in the Red Book from
ICTAD/SBD/2;
xii. Removal of Sub-Clause 14.4: “Schedule of Payments” in the Red Book from
ICTAD/SBD/2;
xiii. Removal of Sub-Clause 14.15: “Currencies of Payment” in the Red Book from
ICTAD/SBD/2;
xiv. Removal of Sub-Clause 17.5: “Intellectual and Industrial Property Rights” in the
Red Book from ICTAD/SBD/2;
xv. Removal of Sub-Clause 17.6: “Limitation of Liability” in the Red Book from
ICTAD/SBD/2;
xvi. Clause numbers 19 and 20 involving “Force Majeure” and “Claims, Disputes and
Arbitration” are interchanged;
xviii. Dispute Resolution Process stated in the Sub-Clauses 20.2 to 20.8 of the Red
Book is entirely changed in Sub-Clauses 19.2 to 19.5 in the ICTAD/SBD/2.
This form of contract is intended for small scale domestic contracts where the works
are designed by the Employer or his consultant and contract administration is carried
out by an Engineer appointed by the Employer. This form of contracts includes general
conditions of contract which should be read in conjunction with a Schedule which
includes contract data. There are fourteen clauses in the general conditions of contract
in this document.
This form of Contract is intended for design and build contracts with works designed by
the Contractor and contract administration is carried out by an Engineer appointed by
the Employer. This form of contracts includes general conditions of contract which
should be read in conjunction with a set of Contract Data. It closely follows FIDIC
Yellow Book 1999 with few deviations including changes to numbering of clauses (e.g.
47
Numbers of clauses involving “Force Majeure” and “Claims, Disputes and Arbitration”
are interchanged).
ii. SBD Plant for Plant –Design & Supply and Installation/Build Contracts; and
Above SBDs contain not only Conditions of Contracts but also guidelines and other
documents necessary for the procurement process such as Instructions to Bidders, Bid
Data Sheet and Evaluation and Qualification Criteria.
This form of contract has been prepared by the ADB for use in smaller contracts valued
at generally less than $10 million. This contract is generally based on the Conditions of
Contract of the World Bank’s Standard Bidding Documents for Procurement of Works,
Smaller Contracts, December 2012. General Conditions included within this form of
contract should be read in conjunction with the Particular Conditions of Contract.
i. This document is for contracts in which the Contractor constructs the Works in
accordance with design provided by the Employer. It can also be used for
contracts that include, partly or wholly, Contractor-designed civil, mechanical or
electrical works;
ii. This document can be used for lump sum payment contracts as well as for small
unit price contracts subject to inclusion of certain modifications in particular
conditions;
iii. This document can be used for contract in which the design works are to be
carried out by the Contractor;
iv. This form of contract requires the Employer to appoint a Project Manager (to
carry out functions of the Engineer in FIDIC forms of contracts) to administer the
contract and perform construction supervision; and
v. General Conditions included within this form of contract have seventy nine
clauses.
48
A3.9.2 SBD Works
The SBD Works must be used for the procurement of works contracts under international
competitive bidding, financed in whole or in part by ADB unless ADB agrees to the use of
other bidding documents acceptable to ADB.
The SBD Works make use of the Conditions of Contract for Construction for Building
and Engineering Works Designed by the Employer, Multilateral Development Bank
Harmonized Edition (FIDIC MDB Harmonized edition 2010 – Pink Book), prepared by
the FIDIC, major features of which have already been explained under the sub
paragraph A3.7.2.
SBD Plant documents must be used for all contracts for plant works under international
competitive bidding, which are financed in whole or in part by ADB, unless ADB agrees to
use any other document acceptable to ADB.
The Conditions of Contract in this form of contract are based on the Model Form of
International Contract for Process Plant Construction published by the Engineering
Advancement Association of Japan (ENAA). General Conditions included within this
form of contract should be read in conjunction with the Special Conditions of Contract.
This document is intended to be used when:
II. Value of the plant and equipment represents the major part of the estimated
contract value; and
III. Plant and equipment are so complex that they cannot be safely taken over by
the Employer without comprehensive testing, pre-commissioning,
commissioning and acceptance procedures being followed.
i. This document is for contracts in which the Contractor is responsible for design,
manufacture, delivery, installation, testing, commissioning and training involved
in the contract. It can also be adapted for contracts where certain activities such
as parts of the preliminary designs or site preparation works are carried out by
the Employer or his consultant;
ii. This document can be used for lump sum contracts as well as for small unit
price contracts subject to inclusion of certain modifications in particular
conditions;
iii. This form of contract requires the Employer to appoint a Project Manager (to
carry out functions of the Engineer in FIDIC forms of contracts) to administer the
contract and perform construction supervision; and
iv. General Conditions included within this form of contract have forty five clauses.
49
ANNEX 4
For contracts fully or partially financed by funding agencies such as ADB, World Bank,
JICA and SIDA, it is necessary to comply with certain requirements imposed by such
agencies through various documents. Therefore, it is important for staff of EA/IA involved
in the implementation of projects financed by such agencies to have basic knowledge of
the funding agency’s requirements during the project implementation stage.
A4.2 The staff should ensure that the basic documents of the project are available on hand for
reference.
Financing agreement sets, among other things, the amount to be financed and
the expiry date of financing. It also defines the purpose of the project and
allocation of funds per category. The category allocation shall be modified as
necessary. It may contain certain loan covenants which the Borrower is expected
to fulfill.
I. Procurement Guidelines;
II. Guidelines on the Use of Consultants;
III. Standard Bidding Documents;
IV. Guide to Bid Evaluation; and
V. Project Administration Instructions.
All documents listed in A4 are available on the ADB website.33 It should be noted that
these documents are revised/updated from time to time. Thus, users should ensure
that they use the latest version of such documents to avoid potential confusions.
A4.4 When a contract approved by ADB needs any modification, the Procurement
Guidelines require the borrower to seek ADB’s no objection in advance (except in cases
of extreme urgency) if such change “would in aggregate increase the original amount of
the contract by more than 15% of the original price. The Guidelines also state that “A
copy of all amendments to the contract shall be furnished to ADB for its record.”
33
Refer www.adb.org
50
A4.5 When any contract dispute occurs with a contractor, it is recommended to report it to the
funding agency. Despite the funding agency does not having any direct contractual
relationship with the contractor, it may facilitate the dispute resolution process to find
mutually acceptable solutions in a view of smooth implementation of projects.
A4.6 It should be noted that funding agencies’ regulations and requirements are evolving as
indicated above thus making revisions of such regulations and requirements inevitable.
Although experience and knowledge regarding requirements of these agencies are
important, such knowledge might soon become outdated. It is highly recommended to
establish close communication links and good relationships with the staff of funding
agency. Early consultation will save time significantly and avoid unnecessary /abortive
work.
51
Section 2
Procedures to be Followed
Procedures to be Followed
Part One
executing stage, completion stage and multi-tiered dispute resolution process and
includes all activities which are to be performed by the Employer and the Engineer
to a contract and their representatives/assistants, during the life cycle of a contract,
Section 2
from inception of a contract by issuing the Letter of Acceptance/Award to the
contractor, to close out of the contract and handing over of completed works to the
operations and maintenance division.
52
53
Part One
MOBILIZATION STAGE
54
PROCEDURES CA01 TO CA 37
PROCEDURE NO. CA 01
PROCEDURE TITLE LETTER OF ACCEPTANCE/AWARD
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out prior to and after the
Issuing of Letter of Acceptance/Award and content of the Letter of Acceptance/Award.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built form of Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. Before sending the Letter of Acceptance/Award to the Contractor the Project Director or
the Project Manager shall ensure that:
a. Prior approval for the award of the contract is obtained from relevant authority
(Cabinet of Ministers, Secretary of the line ministry or Project Director as the case
may be) and Attorney General’s clearance is obtained for the finalized draft of
contract document if there are any concerns on legal issues.
b. Prior approval for the award of the contract is obtained from the funding
agency/agencies.
d. All encumbrances are cleared and acquisitions of lands, possession of which are to
be handed over to the contractor, are completed; and
a. The Letter of Acceptance is issued within the validity period of the bid.
55
3. The Letter of Acceptance/Award:
a. Shall not include any new conditions unless previously agreed by parties and such
agreements reached between parties have been formalized through a
Memorandum of Understanding (MOU).
b. Shall be signed by the proper authority (Chairman/GM/PD as the case may be).
d. May include requirements for the Contractor to carry out certain activities such as
submission of an environmental action plan (when the contract involves
environmentally sensitive activities or locations) within a specified time frame.
4. The Project Director or Project Manager shall ensure that there are no discrepancies
that exist between contractual requirements reiterated in the Letter of Acceptance and
contractual requirements stated in other documents constituting the contract.
5. Issuing of the Letter of Acceptance/Award triggers, start of time periods within which
some contractual obligations as listed below are to be fulfilled:
a. Parties shall enter into a Contract Agreement within 28 days after the Contractor
receives the Letter of Acceptance, unless the Particular Conditions establish
otherwise. (FIDIC Sub-Clause 1.6).
b. The Contractor shall deliver the Performance Security to the Employer within 28 days
after receiving the Letter of Acceptance. (FIDIC Sub-Clause 4.2).
c. If the total advance payment and payment modalities are stipulated in particular
conditions the Employer is required to pay a mobilization payment/advance payment
to the contractor ONLY upon receipt of the advance payment guarantee and
performance security which fulfils the requirements stated in the contract (FIDIC
14.2). The first instalment of the advance payment must be made within 42 days
after issuing the Letter of Acceptance or within 21 days after receiving the documents
in accordance with Sub-Clause 4.2 [Performance Security] and Sub-Clause 14.2
[Advance Payment], whichever is later. (FIDIC Sub-Clause 14.7).
REFERENCES
Government Procurement Manual
Sub Sections 8.7 and 8.9.1
Government Procurement Guide
Sub Sections 8.7.1
(General Conditions of Contract –Pink Book)
Sub-Clause 1.1.1.3
Sub-Clause 1.1.4.1
56
Sub-Clause 1.5 [Priority of Documents]
Sub-Clause 1.6 [Contract Agreement]
Sub-Clause 4.2 [Performance Security]
Sub-Clause 8.1 [Commencement of Works]
Sub-Clause 18.1 [General Requirements for Insurances]
ATTACHMENTS
Checklists
CL/CA 01/ 01 - Pre- Award Checklist
Specimen Letters
SL/CA 01/ 01 – Letter of Acceptance/Award
57
PROCEDURE NO. CA 02
PROCEDURE TITLE FORMATION OF CONTRACT MANAGEMENT TEAM
SCOPE
Scope of this procedure covers activities required to be carried out with regard to formation
of the contract management team through utilizing in-house human resources and recruiting
outsiders when suitable personnel are not available within the Public Entity.
APPLICABILITY
This procedure is applicable to any major contract to be awarded by any Public Entity.
ACTIONS REQUIRED
1. The Project Director depending on the size and type of the Contract, shall determine
competency level, experience and number of staff required to establish the Contract
Management Team which shall consist of Project Managers, Chief Engineers, Senior
Engineers, Quantity Surveyors, Engineering Assistances and supporting staff.
2. The Project Director shall identify potential candidates available within the Public Entity
for positions in Contract Management Team through inviting applications and conducting
interviews. Project Director shall make a request to the relevant authority for release of
the persons selected and assign them to the project.
3. If there are no suitable candidates available for any of such positions within the Public
Entity, the Project Director shall seek the approval of the relevant authority to recruit such
personnel on contract basis in accordance with Management Services Circular No. 33 of
2007 and subsequent amendments.
4. Appointment to all positions shall be made only after calling for applications by open
advertisements followed by interviews.
5. The Contract Management Team shall function under the direct supervision of the Project
Director and shall be responsible for attending to contractual matters such as contractual
obligations of parties, management of variations, management of claims, dispute
resolution and drafting of responses for contractor’s letters relevant to contractual matters
REFERENCES
Management Services Circular No. 33 of 2007
ATTACHMENTS
Specimen Formats
SF/CA 02/ 01 – Identification of Key Staff Requirements
Specimen Letters
SF/CA 02/ 01 – Letter to GM Requesting Release of In-house Staff
58
PROCEDURE NO. CA 03
PROCEDURE Handing Over of Documents/Information Relevant to The Contract to
TITLE CM Team
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers taking copies of documents and other information which are
related to feasibility studies, environmental studies, design stage and procurement stage and
would include reports, drawings, minutes of meetings, correspondences with bidders and
loan agreements with funding agencies.
APPLICABILITY
This procedure is applicable to any contract to be awarded by any Public Entity.
ACTIONS REQUIRED
1. Project Director shall obtain following documents and handover a set of copies to the
Contract Management Team:
a. Contract Documents.
b. Feasibility Study Reports.
c. Environmental Impact Assessment Reports.
d. Resettlement Action Plans and information on land acquisition.
e. Letters from authorities giving approval for the project.
f. Loan Agreements with funding Agencies.
g. Survey plans.
h. Hydrological/drainage reports.
i. Rainfall records for the project area.
j. Coastal Hydraulic Reports and model study reports.
k. Soil investigation logs and reports.
l. Material Testing reports.
m. As built information/drawings of previous constructions in same area including
GIS.
n. Information on utility positions in the area including GIS.
o. Design Reports and design drawings.
p. TEC and CAPC/MPC/PPC reports.
q. Memoranda and decisions of Cabinet of Ministers approving the award.
r. Project Management and Contract Management Guide.
2. The Project Manager or Chief Engineer shall obtain above documents/information and
make arrangements to establish a library for such documents/information upon making
an inventory with the assistance of the Project Secretary.
3. Project Secretary shall establish and maintain procedures for lending and returning of
documents to project staff.
4. Project Secretary shall make digital copies of documents by scanning hard copies to put
them in the computerized Document Management system.
59
5. The Project Manager or Chief Engineer shall make a digital copy of Combined
Conditions of Contract by applying changes introduced through Specific Provisions of
Particular Conditions Part B and Addendums to General Conditions of Contract. This
document shall be considered only as a reference tool but not as a contractual
document.
REFERENCES
None
ATTACHMENTS
Checklists
CL/CA 03/ 01 – Checklist for taking Over of Documents/Information
Specimen Formats
SF/CA 03/ 01 – Document Inventory
60
PROCEDURE NO. CA 04
PROCEDURE REVIEWING OF DRAFT CONTRACT AGREEMENT AND OTHER
TITLE DOCUMENTS CONSTITUTING THE CONTRACT
SCOPE
Scope of this procedure covers activities required to be carried out with regard to reviewing
of the draft Contract Agreement and other documents constituting the contract
APPLICABILITY
This procedure is applicable to any contract to be awarded by the Public Entity.
ACTIONS REQUIRED
1. Project Director, Project Manager and Chief Engineer’s shall review the draft
Contract Agreement and other documents forming the contract and take note of
provisions which are specific to the contract concerned.
2. Such specific provisions may be highlighted in hard copies with attached tabs and an
internal memo shall be prepared for project staff, informing them of such provisions.
3. If there are any ambiguities/ discrepancies between different documents forming the
contract, identified during the above review, such ambiguities/ discrepancies shall be
interpreted in accordance with priority of documents stated in the contract.
REFERENCES
ATTACHMENTS
Specimen Letters
SL/CA 04/ 01 – Memo to Staff on Specific Provisions and Ambiguities in Contract
Documents
SL/CA 04/ 02 – Engineer’s Instructions to Clarify Ambiguities and Discrepancies in Contract
Documents
61
PROCEDURE NO. CA 05
PROCEDURE Drafting and Signing of Contract Agreement
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out prior to and after the
signing of the Contract Agreement and content of the Contract Agreement.
APPLICABILITY
This procedure is applicable to any contract for Works exceeding SLR 250,000 (Sri Lanka
Rupees Two hundred and Fifty thousand) which is to be awarded based on Construction or
Plant and Design-Built form of Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director / Project Manager shall ensure that the Letter of
Acceptance/Award is issued to the Contractor together with the draft Contract
Agreement.
2. The Project Director / Project Manager shall make arrangements to sign the Contract
Agreement within the stipulated time frames(FIDIC and ICTAD form of Conditions
of Contract require the parties to enter into a Contract Agreement within 28 days
)upon receipt of the Letter of Acceptance by the Contractor.
3. The Project Director / Project Manager shall ensure that draft Contract Agreement is
prepared and required approvals for the same are obtained.
4. The Project Director / Project Manager shall ensure that Power of Attorney for the
signatory who is authorized to sign on behalf of the Contractor is obtained and
perused by a competent person to ascertain its validity.
5. The Project Director / Project Manager shall ensure that if the Contractor is a Joint
venture of two or more companies, their joint venture agreement is submitted and
reviewed. JV agreement should authorize a leading partner to manage the Contract
and act on behalf of all partners. If JV agreement is found to be inadequate upon
review of the same, the Contractor shall be ask to take action to rectify such
inadequacies.
6. The Contract Agreement in three originals shall be signed by the relevant authority
on behalf of the Employer and the authorized signatory on behalf of the Contractor.
7. Each page of the documents forming the Contract shall be initialled by the relevant
authority on behalf of the Employer and the authorized signatory on behalf of the
Contractor.
8. One signed original of the Contract Document shall be handed over to the Contractor
and another signed original of the Contract Document shall be handed over to the
Employer for safe keeping. Other signed original of the Contract Document shall be
kept by the Project Director at a safe location upon making several copies for use of
the Project Team.
62
9. If the Accepted Contract Amount exceeds SLR 250,000,000 (Sri Lanka Rupees Two
Hundred and Fifty Million), contract award shall be published in at least one widely
circulated national news paper, the line ministry website and government gazette.
Otherwise contract award shall only be published in the NPA website, line ministry
website and/or any other appropriate media.
REFERENCES
Procurement Guidelines
Sub Section 8.9.3
Sub Section 8.10 [Publication of Contract Award]
Procurement Guide
Sub Section 8.9.3 [Execution of Contract]
ATTACHMENTS
Checklists
CL/CA 05/ 01 – Pre- Contract Checklist
Specimen Format
SF/CA 05/ 01 – Contract Agreement
63
PROCEDURE NO. CA 06
PROCEDURE ORIENTATION TRAINING ON CONTRACT MANAGEMENT TO
TITLE PROJECT STAFF
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers planning, preparing and conducting orientation training for
project staff at the outset of the project and also to new staff who would join the team during
the execution of the project. Orientation training should be planned for each project staff
according to his duties and responsibilities and should included training on use of this Guide.
Orientation training may include training on Project Management, Contract Management,
Quality Assurance, use of Project Management and document Management software and
any other specific areas.
APPLICABILITY
This procedure is applicable to any contract to be awarded by a public entity.
ACTIONS REQUIRED
1. The Project Director shall assess the training needs of project staff in Contract
Management, based on their qualifications and past experiences in order to better equip
them with necessary skills and knowledge to carry out their duties and responsibilities
successfully at the initial stage of the contract. The Project Director may consider
including consultants’ staff in the orientation program if he thinks it would benefit the
project execution.
2. The Project Director shall decide on the mode of orientation training to be provided
depending on resources and time available. Mode of training may include, self reading
of this Guide, in-house training programs and lectures/workshops arranged by Public
Entity’s Training Division or external organisations.
3. The Project Director shall prepare a training plan for orientation training based on needs
identified, resources available and time constraints. Orientation training shall be
scheduled at the initial stage of the project when work load is less thus training can be
arrange without interfering with duties of the participants.
4. Self reading of the Project/Contract Management Guide shall be carried out under the
guidance of a senior team member who has previously participated in the CM training
program and following a strict time schedule. The Project Director, Project Manager or
Chief Engineer shall decide, what are the relevant procedures the team member shall
self study.
5. The Project Director shall arrange resource persons from pool of trainers of the Public
Entity, who have been specially trained for the purpose for In-house training programs.
The Project Director may utilize any suitable consultant engaged to work in the project
as a resource persons if available. For the purpose of in-house training, training
materials provided with this Guide such as presentations/handouts shall be used upon
updating them to improve the content.
6. The Project Director may arrange CM training for his team members with the Public
Entity’s Training Division or with external organisations such as ICTAD.
7. The Project Secretary shall maintain training records for each member to ensure that
they have received adequate training to carry out their duties with confidence. Also a
training evaluation form shall be completed by the each participant to give feedback on
the quality of training they received.
64
REFERENCES
None
ATTACHMENTS
Checklists
CL/ CA 06/ 01 – Checklist to Assign Scope of Self Reading for Orientation Training
Specimen Formats
SF/CA 06/ 01 – Training Record
SF/CA 06/ 02 – Training Evaluation Form
65
PROCEDURE NO. CA 07
PROCEDURE COMMENCEMENT OF CONTRACT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out prior to and immediately
after the Commencement of the Contract which shall be considered to be the
Commencement Date defined in the Conditions of Contract.
If the Engineer’s instruction to commence the Works and the notification is not received by
the Contractor within 180 days from his receipt of the Letter of Acceptance, the Contractor
would be entitled to terminate the Contract.
FIDIC Conditions of Contract for Construction 1999 (Red Book) and for Plant and
Design-Build 1999 (Yellow Book)
FIDIC 1999 editions of Conditions of Contract for Construction (Red Book) and for Plant and
Design-Build (Yellow Book) stipulates that the Commencement Date shall be the date which
shall be notified to the Contractor by the Engineer and that date shall be within 42 days upon
the receipt of the Letter of Acceptance by the Contractor, unless otherwise stated in the
Particular Conditions of Contract. Engineer shall give the Contractor not less than 7 days’
notice of the Commencement Date.
APPLICABILITY
This procedure is applicable to any contract to be awarded by any public entity.
ACTIONS REQUIRED
1. The Contract shall be signed by the parties prior to the issue of the Engineer’s
instruction to commence Works.
2. The Contractor shall submit the Performance Security to the Employer in accordance
with the terms of the Contract, prior to the issuance of the Engineer’s instruction to
commence Works.
66
3. Following activities shall be carried out prior to the issuing of the Engineer’s instruction
to commence Works, by the Project Director as the representative of the Employer:
a. If the Engineer is not named in the Contract, the Engineer shall be appointed and the
Contractor shall be informed.
b. Provide the Contractor with evidence of financial arrangements which will enable the
Employer to pay the Contract Price punctually.
c. Provide the Contractor with effective access to and possession of the Site, unless
otherwise agreed in the Contract
d. Issue the Engineer and/or his assistants with copies of all relevant documentation,
including all contract documentation, drawings, site investigation reports, survey details,
designs and other information.
e. Issue the Contractor with copies of the contract document and all other relevant
documentation.
f. Provide the Contractor with detailed information on survey control points including
grid points and benchmarks.
g. Ensure that the Contractor receive the Advance Payment (or first instalment of the
Advance Payment) prior to the Commencement date, if the Contractor submits the
Advance Payment Guarantee within a reasonable time.
h. Approve the Contractor’s proposed locations for his site office and facilities.
4. Following activities shall be carried out prior to the issuing of the Engineer’s instruction
to commence Works, by the Engineer for the Contract; Head of the Entity or the
Consultant appointed as the case may be:
b. The Engineer shall give his consent/objection to the person, the Contractor propose
to appoint as the Contractor’s Representative, upon reviewing of particulars of the
proposed candidate, to ensure such Contractor’s Representative is appointed prior to
the Commencement Date.
c. The Engineer shall ensure that the Contractor carry out dilapidation/condition survey
to record existing defects in structures/buildings In the vicinity of the area where
adverse impacts of the construction activities are expected to be felt.
d. Certify the Advance Payment, if the Contractor submits the Advance Payment
Guarantee within a reasonable time, so that the Contractor receive the Advance
Payment (or first instalment of the Advance Payment) prior to the Commencement
date.
e. The Contractor shall be formally issued with all Contract Documentation, drawings,
designs and other information, necessary for the Contractor to commence the Works.
5. The Contractor shall provide evidence of having arranged all the required insurance
covers prior to commencement of Works.
6. The Head of the Entity, as the Engineer shall issue the Engineer’s instruction to
commence Works.
7. The Project Director/Project Manager shall ensure that the Contractor submit following
information upon receiving the Engineer’s Instruction to commence Works:
67
c. First quarterly non-binding estimate of the payments which he expects to become
due during each quarterly period within 42 days.
d. Details of procedures and compliance documents with regard to the Contractor’s
Quality Assurance System
e. Information on subcontractors he intends to use, for the Engineer’s prior consent, if
such subcontractors are needed to be engaged from the commencement of the
Contract.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 2.4 [Employer’s Financial Arrangements]
Sub-Clause 4.3 [Contractor’s Representative]
Sub-Clause 8.1 [Commencement of Works]
Sub-Clause 8.3 [Program]
Sub-Clause 14.1 [The Contract Price]
Sub-Clause 14.4 [Schedule of Payments]
ATTACHMENTS
Checklists
CL/CA 07/ 01 – Pre-Commencement Checklist
CL/CA 07/ 02 – Post-Commencement Checklist
Specimen Letters
SL/CA 07/ 01 – Letter Notifying Instruction to Commence Works
68
PROCEDURE NO. CA 08
PROCEDURE EVIDENCE OF THE EMPLOYER’S FINANCIAL ARRANGEMENT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to provide
evidence to the Contractor of Employer’s financial arrangements.
APPLICABILITY
This procedure is applicable to any major contract to be awarded by any public entity based
on FIDIC Conditions of Contract.
ACTIONS REQUIRED
1. The Project Director shall ensure that the financing agreement with the financing agency
for funding the contract is signed and allocations to fund local component of the contract
price is arranged prior to awarding the contract.
2. The Project Director shall also ensure that any loan covenant governing the loan
effectiveness is fulfilled to make funds readily available for disbursements.
3. The Project Director shall ensure that the Contractor’s bank accounts details are
obtained and establishment of mechanisms specified under the financing agreement for
disbursement of certified payments to the contractor, have been completed.
4. The Project Director shall submit to the contractor following documents as evidence of
Employer’s financial arrangements for the contract:
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 2.4 [Employer’s Financial Arrangements]
ATTACHMENTS
Specimen Letters
SL/CA 08/ 01 – Letter to the Contractor Informing Employers Financial Arrangements
69
PROCEDURE NO. CA 09
PROCEDURE APPOINTMENT OF THE ENGINEER
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
appointment of the Engineer.
APPLICABILITY
This procedure is applicable to any major contract to be awarded by a Public Entity.
ACTIONS REQUIRED
1. Unless the Engineer is named in the Contract, the Head of the Entity shall appoint the
Engineer in writing prior to commencement of the Contract and notify the same to the
Contractor.
2. When the Employer requires replacing of the Engineer, the Project Director/ Project
Manager shall notify the Contractor of the name, address and relevant experience of the
intended replacement Engineer, 21 days prior to the intended replacement date.
3. If the Contractor notifies the Employer, raising any objections against the intended
replacement Engineer with supporting particulars as evidence of his unsuitability, the
Employer should consider such objections fairly.
4. Upon considering such objections raised by the Contractor, the Employer may notify the
Contractor of another replacement Engineer, if the Employer agrees with the
Contractor’s objections.
5. The Employer may appoint the replacement Engineer if he is of the opinion that the
intended replacement Engineer is suitable, upon fairly considering the Contractor’s
objections (if any) and notify the Contractor accordingly.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 3.1 [Engineer’s Duties and Authority]
Sub-Clause 3.4 [Replacement of the Engineer] - Not valid for ICTAD contracts
ATTACHMENTS
Specimen Letters
SL/CA 09/ 01 – Letter Appointing the Engineer
SL/CA 09/ 02 – Letter Notifying the Intended Replacement of the Engineer
SL/CA 09/ 03 – Letter Notifying the Appointment of Replacement Engineer
70
PROCEDURE NO. CA 10
PROCEDURE DELEGATION OF ENGINEER’S AUTHORITY TO ENGINEER’S
TITLE REPRESENTATIVE / ASSISTANTS
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
appointment of Engineer’s Representative and Assistants for a contract and delegation of
authority to such Representatives and Assistants.
APPLICABILITY
This procedure is only applicable to any contract to be awarded by any public entity within
which Head of the Entity or any other staff member of the Public Entity is named as the
Engineer to the Contract.
ACTIONS REQUIRED
1. The Head of the Entity or any other staff member ofa public entity as may be deemed
appropriate in the circumstances, may be appointed as the Engineer, shall appoint
Engineer’s Assistants to carry out certain specified duties and exercise certain
authorities attributable to him as specified in or to be inferred from the Contract, on
behalf of the Engineer. All such appointments, assignments of duties and delegation of
authorities shall be in writing and it shall be communicate to the Employer and the
Contractor.
3. The Head of the Entity or any other staff member, appointed as the Engineer, shall
revoke certain duties assigned and authorities delegated to Engineer’s Assistants if
there is a need to do so. All such revocation assignments of duties and delegation of
authorities shall be in writing and it shall be communicate to the Employer and the
Contractor.
4. The Engineer shall not delegate authority to make determinations under the Sub-Clause
3.5 [Determinations] of the FIDIC Conditions of Contract or under the Sub-Clause 3.4
[Determinations] of the ICTAD Conditions of Contract
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 3.2
Procurement Guidelines
Sub Section 5.4.1 (b) (iv)
71
ATTACHMENTS
Specimen Letters
SL/CA 010/ 01 – Letter of Appointment of Engineer’s Assistants
SL/CA 010/ 02 – Letter to Assign Duties and Delegate Authorities to Engineer’s Assistants
SL/CA 010/ 02 – Letter to Revoke Authorities Delegated to Engineer’s Assistants
72
PROCEDURE NO. CA 11
PROCEDURE ESTABLISHMENT OF THE DOCUMENT/ CORRESPONDENCE
TITLE MANAGEMENT SYSTEM
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to control of
documents including incoming and outgoing correspondences. Following are the major
categories of documents which are to be controlled:
1. Contract Document
2. Construction Documents
3. Contractual correspondences
4. Contractual records
5. Correspondences with stake holders and regulatory authorities
6. Correspondences with third parties including general public
7. Regulatory documents such as acts, regulations, permits, and licences
8. Institutional documents such as circulars, board papers and guidelines/Guides
9. Standard documents
10. Loan/Grant Agreements and Aide Memoires
11. Reports/Plans such as feasibility reports, EIA reports, Resettlement Implementation
Plan, and design reports
12. Text books and reference literature
APPLICABILITY
This procedure is applicable to any major contract to be awarded by the Public Entity.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that the resources required for
document storage and filing system and computerized document management system
are provided and computerized document management system is installed.
2. The Project Secretary shall ensure that files and storage cabinets/racks which are
required to keep originals and hard copies are neatly labelled and arranged to ensure
adequate protection and easy retrieval.
3. The Project Director/Project Manager shall ensure that competent and trustworthy
people are assigned for registering, filing and storing of documents and inputting data in
to computerized document management system.
b. The Project Director/Project Manager shall be the first official recipient of all
correspondences, with the exception of certain prescribed communications such as
submissions for approval of work in progress which, for practical reasons, may be
submitted direct to nominated site staff.
c. Upon receiving any contractual correspondence from the Contractor, the Project
Secretary shall date stamp it and give it a serial/sequential number which shall be
marked in the document itself. The Project Secretary shall make copies of the
73
document and file the original in the Master File for Incoming Documents in the order
of the serial/sequential number. One copy of the document shall be filed in the
subject file while another copy of the document shall be forwarded to the Project
Director/Project Manager for assigning responsibility for actions to be taken by
placing minutes on it, upon his review.
e. If a staff member is required to draft a response to the Contractor’s letter, such draft
shall be submitted to the Project Director/Project Manager for his review and/or
comments.
f. When the Project Director/Project Manager agrees to the draft response with or
without comments, the Project Secretary shall revise the letter accordingly, give it a
sequential reference number, get it printed on a letter head and submit it for
signature of the Project Director/Project Manager.
g. The Project Secretary shall enter information relevant to the document such as
reference number, date and addressee, the title of the letter and reference number of
the incoming letter for which the response is prepared, into the outgoing
correspondence register and make copies for circulation and for filing in the subject
file. The second signed original for office use, shall be filed in the Master File for
Outgoing Documents and circulation copy shall be circulated among staff members
who have an interest regarding the subject matter contain in the document.
h. The Data Entry Operator shall enter data relevant to the document such as reference
number, date, addressee the title of the letter and reference number of the incoming
letter for which the response is prepared, into the computerized Document
Management System and a scanned copy of the document in pdf format (portable
document format) shall be uploaded in to the computerized Document Management
System.
74
submissions for approval of work in progress which, for practical reasons, may be
submitted direct to nominated site staff.
c. Upon receiving any contractual correspondence from the Contractor, the secretary
shall date stamp it and give it a serial/sequential number which shall be marked in
the document itself. The secretary shall make copies of the document and file the
original in the Master File for Incoming Documents in the order of the
serial/sequential number. One copy of the document shall be forwarded to the
Engineer’s Representative/Assistant for assigning responsibility for actions to be
taken by placing minutes on it, upon his review.
e. If a staff member is required to draft a response to the Contractor’s letter, such draft
shall be submitted to the Engineer’s Representative/Assistant for his review and/or
comments.
g. The secretary shall enter information relevant to the document such as reference
number, date, addressee and the title of the letter into the outgoing correspondence
register and make copies for circulation and for filing in the subject file. The second
signed original for office use, shall be filed in the Master File for Outgoing Documents
and circulation copy shall be circulated among staff members who have an interest
regarding the subject matter contain in the document.
h. The Data Entry Operator shall enter data relevant to the document such as reference
number, date, addressee and the title of the letter into the computerized Document
Management System and a scanned copy of the document shall be uploaded in to
the computerized Document Management System.
i. The document management system shall provide traceability of documents and means
whereby the Engineer’s Representative/Assistant can ascertain whether or not
incoming correspondence has been responded to, whether replies have been
temporarily deferred or whether a response has been overlooked.
b. The Project Director/Project Manager shall assign the responsibility for drafting such
correspondences to a competent staff member.
75
d. The staff member who was assign the task of drafting the letter, shall draft the letter
taking in to account contractual obligations of parties and wherever possible
reference should be given to clauses or sections in the contract documents. When
deciding the title of the letter, it is prudent to include key words within the title to
facilitate searching of the document in a computerized document management
system.
e. Upon completion, the draft shall be submitted to the Project Director/Project Manager
for his review and/or comments.
f. When the Project Director/Project Manager agrees to the draft with or without
comments, the Project Secretary shall revise the letter accordingly, give it a
sequential reference number, get it printed on a letter head and submit it for
signature of the Project Director/Project Manager.
g. The Project Secretary shall enter information relevant to the document such as
reference number, date, addressee and the title of the letter, into the outgoing
correspondence register and make copies for circulation and for filing in the subject
file. The second signed original for office use, shall be filed in the Master File for
Outgoing Documents and circulation copy shall be circulated among staff members
who have an interest regarding the subject matter contain in the document.
h. The Data Entry Operator shall enter data relevant to the document such as reference
number, date, addressee and the title of the letter, into the computerized Document
Management System and a scanned copy of the document in PDF format (portable
document format) shall be uploaded in to the computerized Document Management
System.
REFERENCES
Guide to Document Management system
ATTACHMENTS
Specimen Formats
SF/CA 020/ 01 – Correspondence Register
76
PROCEDURE NO. CA 12
PROCEDURE HANDING OVER OF SITE POSSESSION
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out prior to and during
handing over of possession of the Site
APPLICABILITY
This procedure is applicable to any contract to be awarded by a Public Entity.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that lands required for the works to
be carried out and effective access to such lands are acquired and all encumbrances
are cleared prior to the commencement of the Contract or otherwise specified in the
Contract. Some contracts stipulate phased handing over of possession of the Site in
several stages. For instance, Contracts involving laying of pipelines along road
alignments, possession of site will be subjected to conditions imposed by road
authorities. When construction activities are to be carried out at a facility/plant in
operation, giving full possession of the site is not practical as both operation of the
facility/plant and construction activities are to be carried out simultaneously without
affecting each other.
2. The Employer may delay the handing over of possession of the site until the Contractor
submits Performance Security.
3. When the execution of works involves working in areas controlled by certain authorities,
the Project Staff shall liaise with such authorities to ensure smooth handing over of
limited possession of such areas to the Contractor to carry out construction works,
subject to the Contractor adhere to requirements imposed by such authorities to mitigate
safety risks and inconveniences to public.
4. The Project Director/Project Manager shall notify the Contractor of the handing over of
possession of the site in advance in writing.
5. The Project Director/Project Manager shall nominate his representative to hand over of
possession of the site on behalf of the Employer to a person nominated by the
Contractor’s representative.
6. Handing over of possession of the site to the Contractor shall be carried out in the
presence of representatives of both parties and Handing over record shall be signed by
the Project Director/Project Manager and the Contractor’s representative.
7. If there are any encumbrances upon handing over of the site to the Contractor, the Chief
Engineer or Project Engineer shall take every possible endeavour to clear such
encumbrances as soon as possible. In the event clearing of such encumbrances are
beyond the control of the Chief Engineer/Project Engineer, Project Director/Project
Manager shall be notified immediately. The Project Director/Project Manager shall
inform the Steering Committee if there are any encumbrances which could delay the
completion of the Contract.
77
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 2.1 [Right of Access to the Site]
ATTACHMENTS
Checklists
CL/CA 12/ 01 – Checklist Handing over of possession of the site to the Contractor
Specimen Formats
SF/CA 12/ 01 – Record of Handing Over of possession of the site to the Contractor
78
PROCEDURE NO. CA 13
PROCEDURE HANDING OVER OF SURVEY CONTROL POINTS AND BENCH
TITLE MARKS
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to get
reference survey control points and bench marks and information relevant to them from the
Survey Department and handing over of the same to the Contractor.
APPLICABILITY
This procedure is applicable to any major contract to be awarded by a Public Entity.
ACTIONS REQUIRED
1. The Project Engineer/Surveyor shall liaise with the Survey Department and obtain
information on at least two survey control points and bench marks in close proximity to
project area, which could be used as reference for setting out of permanent works.
Alternatively the Project Engineer/surveyor may engage Survey Department to establish
at least two dedicated survey control points and bench marks for the project in close
proximity to the project area. The Project Engineer/Surveyor shall obtain from the
Survey Department at least three off sets to each such benchmark and control point
from a stable landmark in close proximity.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.7 [Setting Out]
ATTACHMENTS
Specimen Letters
SL/CA 13/ 01 – Letter to the Contractor for Handing Over of Survey Control Points and
Bench Marks
Specimen Formats
SF/CA 13/ 01 – Handing Over of Survey Control Points and Bench Marks
79
PROCEDURE NO. CA 014
PROCEDURE Kick-off Meeting
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out prior to, during and after
the Kick-off Meeting to introduce the project team members and other stakeholders to each
other, to brief the participants of salient features of the Contract, to identify potential issues
which may adversely affect the progress of the contract, to gain a common understanding of
the contract’s objectives and priorities and to discuss about ways and means to execute the
Contract without any adverse impacts.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director or Project Manager shall decide a suitable date to hold the Kick-off
meeting.
2. The Project Director or Project Manager shall identify participants to be invited for the
Kick-off meeting, including the Employer’s Project Team, Consultant’s key personnel,
Contractor’s key personnel, representatives of statutory Public Entities such as RDA,
CEB, LECO, UDA, Irrigation Department and CEA any other individuals or
representatives of Public Entities relevant to the Contract.
3. The Project Secretary shall ensure that invitation letters for the kick-off meeting are sent
to all identified participant at least a week prior to the said meeting.
4. The Project Secretary shall arrange a venue, presentation aids and refreshments for the
Kick-off meeting.
5. The Chief Engineer shall prepare a presentation to provide detailed information on the
project/contract to participants
6. The Project Director or Project Manager shall chair the kick-off meeting and present
project information to the participants.
8. The Project Director or Project Manager shall outline the project goals as well as the
individual roles and responsibilities of team members;
10. Discussions during the kick-off meeting shall focus on way forward by addressing
concerns with regard to initial contractual requirements/obligations.
11. Any follow up actions required and the individuals responsible for each of them shall be
identified and dates by which the actions should be completed shall be fixed.
80
12. The Project Secretary shall prepare minutes of the Kick-off meeting and forward it to the
Chief Engineer for review. Minutes of the Kick-off meeting shall be approved by the
Project Director or Project Manager prior to circulation.
13. The Project Secretary shall circulate minutes of the Kick-off meeting to all
stakeholders/participants within one week after the meeting.
14. The Project Secretary shall maintain records of comments on minutes received from
participants and revised the minutes if necessary.
15. The Project Secretary shall circulate revised minutes of the Kick-off meeting to all
stakeholders/participants.
REFERENCES
None
ATTACHMENTS
Checklists
CL/CA 01/ 01 – Kick-off Meeting Checklist
Specimen Letters
SL/CA 014/ 01 – Invitation Letter for the Kick-off Meeting
Specimen Formats
SF/CA 014/ 01 – Agenda for the Kick-off Meeting
SF/CA 014/ 02 – Attendance Record for the Kick-off Meeting
SF/CA 014/ 03 – Minutes of the Kick-off Meeting
81
PROCEDURE NO. CA 15
PROCEDURE ESTABLISHMENT OF COMMUNICATION MODES AND
TITLE ADDRESSES
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to establish communication modes and
exchange contact information of the parties and the Engineer, unless otherwise stated in the
Contract, in order to ensure smooth execution of the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded by a Public Entity.
ACTIONS REQUIRED
2. Project Director/Project Manager shall ensure that the Contract is provided with
following contact information of the Employer and the Engineer:
a. Postal address
b. Email address
c. Fax number
d. Contact telephone numbers of Employer’s representative, the Engineer and
Engineer’s
Representative/Assistants
3. The Project Secretary shall ensure that an email account with adequate storage
capacity is opened and a fax machine is installed in the project office.
4. The Project Secretary shall ensure that the content of the inbox of email account is
regularly backed up to create adequate space for incoming emails and fax machine is
not run out of papers and ink/toner.
5. Project Director/Project Manager shall ensure that if change occurs to in any of the
above said contact information, to inform the Contractor and the Engineer accordingly.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 1.3 [Communications]
ATTACHMENTS
Specimen Letters
SL/CA 15/ 01 – Letter to the Contract Informing Contact Details
34
Usual modes of communication of a contract with hard originals/copies include, delivery through postal services, courier services or by
hand
and communication through digital means include facsimile and emailing.
82
PROCEDURE NO. CA 16
PROCEDURE AUTHORITY APPROVALS
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out to obtain required prior
approvals on schedule from statutory authorities and local bodies as may be deemed
relevant such as Provincial Councils, RDA, UDA, CEA, Irrigation Department, Railway
Department, BOI, Police and Local Authorities (Municipal/Urban Councils, Pradeshiya
Sabas), for various construction activities to mitigate delays and cost over runs.
APPLICABILITY
This procedure is applicable to any contract to be awarded by a Public Entity.
ACTIONS REQUIRED
1. Project Director/Project Manager shall ensure that all prior approvals required from
various authorities are obtained by the Contractor before commencement of relevant
construction activities.
3. It should be noted that certain activities may require approval in stages as the work
progress and therefore a mechanism shall be agreed with the relevant authority to
obtain such approvals in stages according to the work program.
4. Project staff shall ensure that conditions imposed by authorities for their approvals are
fulfilled by the Contractor prior to or during the execution of relevant activities, as the
case may be.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 1.13 [Compliance with Laws]
ATTACHMENTS
Checklists
CL/CA 16/ 01 – Checklist for Obtaining Authority Approvals
83
PROCEDURE NO. CA 17
PROCEDURE REVIEWING OF WORK PROGRAM
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out to review the Work
Program [Master Program] which is to submitted by the Contractor to the Engineer within 28
days after receiving the notice to commence, depicting the sequence and timing of each
activity required to be carried out to complete the Works within the Time for Completion
specified in the Contract and which is to be used as a base line/ bench mark for execution of
works, is essential in monitoring the progress of works and ascertaining any delays to the
Time for completion.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
a. Dedicated activities and milestones are allocated to all major work items and major
events.
b. Time durations allocated are reasonable and realistic.
c. All activities and milestones are connected with appropriate logics representing
desired relationship and sequence.
d. Resources and costs are allocated.
e. Appropriate calendars are defined and used to represent work week and non-working
days.
f. In-appropriate constrains are introduced to restrict/manipulate the rearrangement of
activities when the program is updated.
g. Contractual milestones and completion dates are met.
h. Interfaces with other contracts and events/activities are defined.
i. Critical Path is well defined.
j. Formatting of the output is acceptable
k. Work sequence and activities defined are accordance with the Contractor’s method
of working.
l. Method of working (Method Statement) submitted with the Work Program is
complying with the contractual requirements and acceptable work practices.
5. If the Work Program is complying with the requirements stipulated in the Contract,
Employer/Engineer may use that to monitor the progress of the Works, using the said
program as the base line. However, it is not required for the Engineer or the Employer to
concur with, accept or approve such program.
84
6. The Contractor shall be notified to revise the Work Program, if it is not complying with
contractual targets when the program is updated using actual progress,.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 8.3 [Program]
ATTACHMENTS
Checklists
CL/CA17/01 – Checklist for reviewing Works Program
Specimen Letters
SL/CA/17/01 – Notification of Comments on Work Program
85
PROCEDURE NO. CA 18
PROCEDURE REVIEWING OF CASH FLOW FORECAST
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required for review of the Contractor’s cash flow
forecasts (non-binding estimates of the payments for quarterly periods) for the execution of
the Contract to assist the Employer to plan disbursement of funds in advance, especially
when local currency components are involved.
APPLICABILITY
This procedure is applicable to any contract to be awarded when there is no schedule of
payments included in the Contract.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that the Contractor submits his first
cash flow forecasts (non-binding estimates) within 42 days after the Commencement
Date.
2. The Project Director/Project Manager shall ensure that cash flow forecast submitted by
the Contractor is in accordance with the Contractor’s Work Program and Contract
rates/prices.
3. The Project Director/Project Manager shall ensure that the Contractor submits his cash
flow forecasts (non-binding estimates) quarterly thereafter.
4. If there is any major variation to the contract requiring major increase in funding the
Project Director/Project Manager shall advise the Contractor to submit a revised cash
flow forecast.
5. The Project Director/Project Manager shall ensure that the if there is any drastic change
in quarterly cash flow forecasts submitted by the Contractor requiring higher amounts of
funds than estimated earlier, he should promptly inform relevant authorities of such a
change in required funding.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 14.4 [Schedule of Payments]
ATTACHMENTS
Specimen Letters
SL/CA 18/ 01 – Letter Requesting the Contractor to Submit Cash-Flow Forecasts
86
PROCEDURE NO. CA 19
PROCEDURE DELEGATION OF AUTHORITY
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to delegate authority to project staff in
order to ensure smooth execution of the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. If the Employer’s representative is not named in the Contract, the head of the IA shall
promptly nominate the Project Director/Project Manager as the Employer’s
representative.
2. The head of the IA shall delegate certain specific authorities to the Project
Director/Project Manager while retaining important authorities for himself.
3. The Project Director/Project Manager shall ensure that certain authorities delegated to
him are delegated to his subordinates as appropriate and notified to the Contractor
accordingly.
4. When the Project Director/Project Manager is of the view such authority is no longer
required, he may revoke such authority by notifying in writing to relevant staff with
copies to all stakeholders
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 1.1.2.6 “Employer’s Personnel”
ATTACHMENTS
Specimen Letters
SL/CA 19/ 01 – Letter Notifying the Appointment of the Employer’s Representative
87
PROCEDURE NO. CA 020
PROCEDURE Performance Security
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to format and
acceptance of the Performance Security.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
2. The Project Director or Project Manager shall ensure that the bid security is valid 14
days beyond the date by which the contractor is to submit Performance Security. Type
of Performance Security required shall be an unconditional on demand bank guarantee
from a reputed bank/agency acceptable to the Employer. Amount guaranteed under a
Performance Security could be used by the employer to recover damages suffered by
him due to breach of contract by the contractor or to recover cost incurred by the
employer due to a contractor’s default.
3. If the Contractor fails to provide a valid Performance Security within the time specified in
the Contract, Project Director or Project Manager shall take action to demand the
amount secured under the bid security, unless the Contractor extend the bid security for
an adequate duration. The Contract could be terminated (in accordance with Sub-
Clause 15.2 [Termination by Employer] of FIDIC/ICTAD Conditions of Contract), if the
Contractor fails to comply with the Contract by not delivering the Performance Security
to the Employer within 28 days after receiving the Letter of Acceptance.
4. The Employer may withhold the handing over of possession of site to the contractor,
until the contractor provides a valid Performance Security.
5. Upon receiving the Performance Security from the Contractor, the Chief Engineer
(Contracts) and the Project Director shall thoroughly review the same to ensure that it
has been written in the required format and the bank/agency which issued the
Performance Security is acceptable to the Employer. If the bank which issued the
Performance Security is not a bank operating in Sri Lanka, the Performance Security
shall be confirmed by a bank operating in Sri Lanka, unless the bank which issued the
Performance Security is a an Export Credit Agency of any foreign government or a
reputed International Financier acceptable to the Central Bank of Sri Lanka.
6. The Project Director or Project Engineer shall write to the bank/agency which issued the
Performance Security on behalf of the Contractor and/or the bank which confirmed the
Performance Security issued by the Contractor’s bank, to verify whether the
88
Performance Security submitted by the Contractor is genuine and enforceable in Sri
Lanka.
8. The Contractor may be required to increase the amount of the Performance Security by
the full replacement cost of defective or damaged works when such works are to be
removed from the Site for the purposes of repair.
9. The Performance Security provided by the Contractor shall be kept in safe custody and
the Project Director/Project Manager shall remind the Contractor to extend the same, 28
days prior to its expiry date, if the Contractor has not become entitled to receive the
Performance Certificate by that time.
10. The Performance Security provided by the Contractor shall remain valid and
enforceable beyond the date on which the Performance Certificate is to be issued,
unless otherwise specified in the Particular Conditions of the Contract and if the
Contractor fails to extend the Performance Security by date 28 days prior to the expiry
date of the same, when the Performance Certificate is yet to be issued, the Project
Director/Project Manager shall make a written request to the bank which
issued/confirmed the Performance Security, informing if the contractor fail to extend the
said security by the expiry date, to consider it as a demand to the bank for payment of
amount guaranteed under the Performance Security.
11. The Project Director/Project Manager shall make a demand to the bank which
issued/confirmed the Performance Security to pay the guaranteed amount, if the
Contract is breached by the Contractor.
12. If the contractor is issued with the Performance Certificate, the employer shall return the
Performance Security to the contractor within 21 day. If the contract is terminated by the
contractor in accordance with the terms of the contract or if the employer terminates the
contract for his convenience, the employer shall promptly return the Performance
Security to the contractor.
REFERENCES
Procurement Guidelines
Sub Section 5.3.11(b) (iv)
Sub Section 5.4.8
Procurement Guide
Sub Section 5.4.8 of Supplement – 18 which superseded original content
89
ATTACHMENTS
Checklists
CL/CA 20/ 01 – Performance Security Acceptance Checklist
Specimen Letters
SL/CA 020/ 01 – Letter to Bank for verification of authenticity of the Performance Security
SL/CA 020/ 02 – Letter to Bank demanding payment of guaranteed amount if Performance
Security is not extended
SL/CA 020/ 03 – Letter to Bank demanding payment of guaranteed amount if the contract is
breached
SL/CA 020/ 03 – Letter to Bank for Authentication of Authorize Signature
Specimen Formats
SF/CA 020/ 01 – Performance Security
90
PROCEDURE NO. CA 21
PROCEDURE REVIEW OF INSURANCE
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to review of
insurance documents.35
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that the Contractor submits evidence
of insurance in the form of copies of the policies for the insurance and receipts for
payments of insurance premiums
2. The Project Director/Project Manager shall review Insurance Policies submitted by the
Contractor to find out whether they fulfil the insurance requirements stipulated in the
Contract and/or agreed by the parties prior to the date of the Letter of Acceptance.
3. The Chief Engineer shall specifically ensure that deductibles and exclusions included
within insurance policies are complying with the Contract and/or agreed by the parties
prior to the date of the Letter of Acceptance.
4. The Chief Engineer shall specifically ensure that such insurance coverage is extended
to cover the time stipulated in the Contract and evidences of such extensions are
submitted for compliance.
REFERENCES
ATTACHMENTS
Checklists
CL/CA 21/ 01 – Checklist for Review of Insurance
35
The Contractor is required to obtain insurance for:
a) Insurance for Works and Contractor’s Equipment
b) Insurance against Injury to Persons and Damage to Property
c) Insurance for Contractor’s Personnel
d) Professional indemnity Insurance for Design (only when designs are included within the scope).
91
PROCEDURE NO. CA 22
PROCEDURE ESTABLISHMENT OF PAYMENT PROCEDURE
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
establishment of mechanisms required to make payments to the Contractor through
disbursement from loans or grants following procedures stipulated under the terms of such
loan/grant agreements.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall review loan/grant agreements to find out
requirements stipulated in such financing agreements for disbursement of payments to
the Contractor.
2. The Project Director/Project Manager shall request the Finance Section to establish
such payment mechanisms to fulfil requirements of funding agencies.
3. The Project Director/Project Manager shall ensure that the Contractor has established
his arrangement for receiving payments and information regarding such arrangements
are shared with the Employer and its finance Section.
REFERENCES
Loan/grant agreements
ATTACHMENTS
Specimen Letters
SL/CA 22/ 01 – Letter to the Contractor Requesting Account Details
92
PROCEDURE NO. CA 23
PROCEDURE ADVANCE PAYMENT GUARANTEE
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance of the Advance Payment Guarantee/Security in accordance with FIDIC and
ICTAD Conditions of Contract prior to making the advance payments to the Contractor.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
2. Upon receiving the Advance Payment Guarantee/Security from the Contractor, the Chief
Engineer (Contracts) and the Project Director shall thoroughly review the same to
ensure that it has been written in the required format and the bank/agency which issued
the Advance Payment Guarantee/Security is acceptable to the Employer. If the bank
which issued the Performance Security is not a bank operating in Sri Lanka, the
Advance Payment Guarantee/Security shall be confirmed by a bank operating in Sri
Lanka, unless the bank which issued the Advance Payment Guarantee/Security is a an
Export Credit Agency of any foreign government or a reputed International Financier
acceptable to the Central Bank of Sri Lanka.
3. The Project Director or Project Engineer shall write to the bank/agency which issued the
Advance Payment Guarantee/Security on behalf of the Contractor and/or the bank
which confirmed the Advance Payment Guarantee/Security issued by the Contractor’s
bank, to verify whether the Advance Payment Guarantee/Security submitted by the
Contractor is genuine and enforceable in Sri Lanka.
5. The Advance Payment Guarantee/Security provided by the Contractor shall remain valid
until the recovery of the full amount taken as the Advance Payment and if the
Contractor fails to extend the Advance Payment Guarantee/Security by date 28 days
prior to the expiry date of the same, the Project Director/Project Manager shall make a
written request to the bank which issued/confirmed the Advance Payment
Guarantee/Security, informing if the contractor fail to extend the said security by the
93
expiry date, to consider it as a demand to the bank for payment of amount guaranteed
under the Advance Payment Guarantee/Security.
7. The Project Director/Project Manager shall make a demand to the bank which
issued/confirmed the Advance Payment Guarantee/Security to pay the guaranteed
amount, if the Contract is unable to pay back the Advance Payment.
REFERENCES
Procurement Guide
Sub Section 5.4.4 of Supplement – 18 which superseded original content
ATTACHMENTS
Checklists
CL/CA 23 01 – Advance Payment Guarantee Acceptance Checklist
Specimen Letters
SL/CA 23/ 01 – Letter to Bank for verification of authenticity of the Advance Payment
Guarantee
SL/CA 23/ 02 – Letter to Bank demanding payment of guaranteed amount if Advance
Payment Guarantee is not extended
SL/CA 23/ 03 – Letter to Bank demanding payment of guaranteed amount if the contractor
has failed to fully repay the advance payment
94
PROCEDURE NO. CA 24
PROCEDURE ADVANCE PAYMENT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to making the
advance payments to the Contractor in accordance with the terms of the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD.
ACTIONS REQUIRED
1. Project Director/Project Manager shall review the Contract document to obtain following
information:
2. Project Director/Project Manager shall ensure that following requirements are fulfilled by
the Contractor prior to making the advance payment:
3. Project Director/Project Manager shall ensure that the Advance Payment is paid within
the time frame specified in the Contract if the Contractor fulfils all the conditions
precedent to the payment of the Advance Payment.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 14.2 [Advance Payment]
ATTACHMENTS
Checklists
CL/CA 24/ 01 – Advance Payment Checklist
95
PROCEDURE NO. CA 25
PROCEDURE ARRANGEMENT FOR ESTABLISHING DISPUTE BOARD/ DISPUTE
TITLE ADJUDICATION BOARD
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
Establishment of a Dispute Board/Dispute Adjudication Board in accordance with FIDIC and
ICTAD Conditions of Contract. 36
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract published by FIDIC or ICTAD when Dispute
Board/Dispute Adjudication Board members are not named in the Contract.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall review the Contract to find out following
information with regard to the establishment of Dispute Boards/Dispute Adjudication
Boards (DB/DAB):
2. The Project Director/Project Manager shall short-list names of potential members for the
Dispute Board/Dispute Adjudication Board from sources such as lists maintained by
CIDA, ICLP and Institution of Engineers (IESL), considering following factors:
a. Integrity
b. Independency and impartiality
c. Qualifications
d. Professional experience in type of construction involved in the Works
e. Experience in adjudication
f. Sound knowledge in interpretation of contractual documents
g. Fluency in language of contract
h. Availability
i. Health conditions
3. The Project Director/Project Manager shall contact prospective candidates and check
with them whether they are available and they have any conflict of interest. Also the
Project Director/Project Manager shall obtain cost proposal for their remuneration and
other costs.
4. The Project Director/Project Manager shall select three most suitable candidates based
on above criteria and cost involved.
36
FIDIC Red Book and Pink Book require a standing Dispute Board/Dispute Adjudication Board while FIDIC Yellow Book requires an ad hoc
Dispute Adjudication Board which shall be established only after the occurrence of a dispute.
96
5. The Project Director/Project Manager shall nominate to the Contractor names of three
most suitable candidates selected by him to select one of them as the sole member or
Employer’s nominated member as the case may be.
6. When DB/DAB is comprised of three members, the members appointed by parties shall
recommend a third member who shall act as the chairman of the DB/DAB.
7. In the event of disagreement to appoint a member for DB/DAB, either party can request
the appointing entity or official named in the Contract to appoint DB/DAB members.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 20.2 [Appointment of the Dispute Board]
ATTACHMENTS
Specimen Letters
SL/CA 25/ 01 – Letter Appointment of DB Members
97
PROCEDURE NO. CA 26
PROCEDURE APPROVAL PROCEDURE FOR CONTRACTOR’S SITE
TITLE ESTABLISHMENT
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to granting
clearance/approval for the Contractor’s site establishment including his offices, workshops,
access roads, accommodation, concrete batching plants and stock yards from the
Employer/Engineer and the relevant authorities.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
3. When the Contractor make a request for such clearance, the Project Director/Project
Manager shall ensure that prompt clearance is granted if the Contractor has fulfilled all
his obligations or inform the contractor of any non-compliances/deficiencies which
prevent granting of such clearances.
4. When the Contractor makes a request for approval to a relevant authority, the Project
Director/Project Manager shall provide any assistance required by the Contractor to
obtain such approval.
5. The Project Director/Project Manager shall ensure that the Contractor continue to
comply with any conditions imposed by any authority, based on which approval is
granted.
REFERENCES
None
ATTACHMENTS
Specimen Letters
SL/CA 26/ 01 – Letter for Approval of Site Installations
98
PROCEDURE NO. CA 27
PROCEDURE APPROVAL OF SUBCONTRACTORS
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to grant prior approval to engage
subcontractors to execute part of the Works, unless such subcontractors are named in the
Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. When the Contractor make a request for prior consent of the Engineer to engage a
subcontractor, the Engineer shall obtain the prior approval of the Employer to give such
consent whenever it is required under the Sub-Clause 3.1 [Engineer’s Duties and
Authority].
2. When the Engineer forwards the information on the subcontractor provided by the
Contractor, the Chief Engineer shall review such information including the draft
subcontract agreement. The Chief Engineer shall check with the contract division of the
organization and CIDA to ensure the subcontractor is not blacklisted and his past
performances are satisfactory. Also the Chief engineer shall check whether the draft
subcontract agreement includes provision for assignment of the subcontract to the
Employer under the Sub-Clauses 4.5 [Assignment of Benefit of Subcontract] or in the
event of termination under Sub-Clause 15.2 [Termination by Employer].
3. The Project Director/Project Manager shall ensure that prompt approval is granted to the
Engineer to give his consent when the past records of the subcontractor are satisfactory
and draft subcontract agreement includes provisions for assignment to the Employer.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.5 [Subcontractors]
ATTACHMENTS
Specimen Letters
SL/CA 27/ 01 – Letter to grant Approval for Subcontractors
99
PROCEDURE NO. CA 28
PROCEDURE APPOINTMENT OF NOMINATED SUBCONTRACTORS
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to Nomination
of subcontractors who are to be named in the Contract or to be employed by the main
Contractor on the instruction of the Engineer.37
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD under which nominated
subcontractors have been named in the Contract or are to be appointed.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall review the Contract to find out whether any
nominated Subcontractor has been named in the Contract and/or any provision is in the
Contract for engaging nominated subcontractors.
2. The Project Director/Project Manager shall ensure that the Engineer instructs the
Contractor to employ such nominated Subcontractors if there are provisions included in
the Contract for nominated Subcontractors but they are not named in the Contract
3. The Project Director/Project Manager shall ensure that the Contractor engages such
nominated Subcontractors who are named in the Contract or provisions for engaging
them are included within the Contract, according to the Contractor’s work schedule with
adequate lead times.
REFERENCES
FIDIC Conditions of Contract MDB 2010
37
Nominated subcontractors are required to be engaged, when certain specialist works are to be carried out within a Contract,
under following circumstances:
a) When an initial work activity such as piling works, which requires a longer lead time for procurement and mobilization, is to
be carried out.
b) When the Contract involves special equipment which require a long lead time for design, manufacture, testing and
transport.
c) When the Employer prefers to install same brand of equipment as already installed in his existing projects to avoid
ordering and keeping stocks of spare parts for various types of equipment.
d) When the Employer’s design is to be carried out using design input parameters of specific brand of equipment to ensure
proper integration.
e) When the Employer has confidence on a particular brand/subcontractor upon repeated usage/engagement.
f) To facilitate engagement of a single servicing and maintenance contractor for several installations, when using proprietary
brands of equipment.
g) When the Employer can get a bargain in price due to long standing business relationship he is having with a particular
subcontractor.
h) When the subcontract involves proprietary components which has been already in use at previously completed parts of
the project.
100
Sub-Clause 5.1 [Definition of “nominated Subcontractor”]
Sub-Clause 5.2 [Objection to Nomination]
Sub-Clause 5.3 [Payments to nominated Subcontractors]
Sub-Clause 5.4 [Evidence of Payments]
Sub-Clause 13.5 [Provisional Sums] – Subparagraph (b)
ATTACHMENTS
Specimen Letters
SL/CA 28/ 01 – Appointment of Nominated Subcontractor
101
PROCEDURE NO. CA 29
PROCEDURE REVIEW OF METHOD STATEMENT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to review of
the Contractor’s Method Statement.38
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that the Contractor submits his
Method Statement with the Work Program.
2. The Chief Engineer shall review the Method Statement and inform the Engineer of any
shortcomings which are identified during such review.
3. The Chief Engineer shall check whether information provided by the Contractor in the
Method Statement is realistic and complying with the Contract.
4. The Project Director/Project Manager shall ensure that the Engineer gives notice to the
Contractor, within 21 days after receiving a program, informing him of shortcomings in
the Method Statement.
5. The Project Director/Project Manager shall note that, in accordance with the Contract,
the Employer or the Engineer is not required to approve or accept the Method
Statement but only required to notify of any noncompliance with the Contract.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 8.3 [Program] – Sub paragraph (d)
Sub-Clause 8.6 [Rate of Progress]
ATTACHMENTS
Checklists
CL/CA 29/ 01 – Checklist for Method Statement
102
PROCEDURE NO. CA 30
PROCEDURE APPROVAL FOR MATERIALS INCLUDING SAMPLES
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance of materials and samples of materials which the Contractor intend to use in the
Works including product information, test certificates, factory/mill certificate and test reports.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that prior to commence works, the
Contractor submits to the Engineer, samples of materials and detailed information on
quality of materials such as catalogues and test certificates, he intend to use in the
works.
2. The Chief Engineer shall inspect such samples and review all information and test
certificates submitted by the Contractor and make arrangements to carry out testing of
materials if required in accordance with the Contract.
3. The Chief Engineer, upon reviewing information provided by the Contractor and
verifying the test reports of tests carried out on such materials, determine whether such
samples of materials are complying with the Contract. If such materials are not
complying, such materials shall be rejected and the Contractor shall be informed
accordingly, informing him to submit samples of materials from a source complying with
the Contract.
4. If such materials are complying with the Contract, approval shall be granted and the
Contractor shall be informed accordingly. Samples of such approved materials shall be
properly labelled and stored in a secured place to ensure such approved materials are
actually used by the Contractor for permanent works, by comparing samples with
materials actually used.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 7.2 [Samples]
Sub-Clause 7.2 [Inspections]
ATTACHMENTS
Specimen Letters
SL/CA 30/ 01 – Approval for Materials
103
PROCEDURE NO. CA 31
PROCEDURE HANDING OVER OF EMPLOYER’S FREE ISSUE MATERIALS
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to handing
over of free-issue materials to the Contractor, in accordance with the terms of the Contract.39
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD when the Employer is
required to provide free-issue material, in accordance with the terms of the Contract.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall review the Contract to find out whether free-
issue materials are provided in the Contract and particulars of such free-issue material
such as quantity and quality required.
2. If free-issue materials are provided in the Contract, the Project Director/Project Manager
shall obtain information on materials available with the Employer to verify whether
sufficient quantity is available and quality of the materials comply with the requirements
in the Contract.
3. If materials with required quality and quantity are available, the Project Director/Project
Manager shall make arrangements to hand over such materials to the Contractor at a
time and place agreed by the parties.
REFERENCES
General Conditions of Contract
Sub-Clause 4.20 [Employer’s Equipment and Free-Issue Materials]
ATTACHMENTS
Specimen Letters
SL/CA 31/ 01 – Handing Over of Free-Issue Materials
39
Free-issue materials are usually originated from materials taken over by the Employer upon termination of a Contract or due
to omission of certain activities for which the Contractor had brought in such materials at the time of issuing the variation to omit
certain works. The Employer is required to provide free-issue materials to the Contractor if such provisions are included in the
Contract, at the time and place stipulated in the Contract.
104
PROCEDURE NO. CA 32
PROCEDURE ACCEPTANCE OF DAILY REPORT FORMAT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance of the Daily Report Format under the FIDIC or ICTAD Conditions of Contract.40
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall advice the Contractor to submit his proposal
for Daily Report format.
2. Upon submission of the proposed Daily Report format by the Contractor, the Project
Director/Project Manager shall review the same to ascertain whether it is acceptable for
the purpose.
3. Upon review of the proposed Daily Report format by the Project Director/Project
Manager, the Contractor shall be informed whether it is acceptable or need revision as
per Engineer’s comments.
4. When a revision to the Daily Report format is necessary, the Project Director/Project
Manager shall review the revised Daily Report format to verify whether it is revised to
accommodate Engineer’s comments, upon submission of the same by the Contractor
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 32/ 01 – Daily Report Format
Specimen Letters
SL/CA 32/ 01 – Acceptance of Daily Report Format
40
Daily Reports can be used to record day to day activities carried out under a Contract, information included in such daily
Reports would become useful as contemporary records when evaluating claims for time and cost.
105
PROCEDURE NO. CA 33
PROCEDURE ACCEPTANCE OF CONTRACOR’S MONTHLY STATEMENT
TITLE FORMAT
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance and approval of format for Contractor’s Monthly Statements which shall be
considered as the applications for Interim Payment Certificates in accordance with FIDIC
and ICTAD Conditions of Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall request the Contractor to submit his
proposed format for Monthly Statements.
2. The Chief Engineer shall review the Contractor’s proposed format for Monthly
Statements and ensure that it includes following items with separate columns for
different currencies in which the Contract Price is payable:
3. If the Contractor’s proposed format for Monthly Statements is acceptable, the Project
Director/Project Manager shall inform the Contractor accordingly but if there are any
comments/concerns regarding the suitability of the format, the Contractor shall be
requested to revise the format to address such concerns.
4. Upon receiving the revised format, the Project Director/Project Manager shall inform the
Contractor whether it is acceptable.
5. The Chief Engineer shall ensure that the Contractor adhere to the accepted format
when he submits his monthly Statements.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 14.3 [Application for Interim Payment Certificates]
ATTACHMENTS
Specimen Letters
SL/CA 33/ 01 – Acceptance of Monthly Statement Format
106
PROCEDURE NO. CA 34
PROCEDURE ACCEPTANCE OF MONTHLY PROGRESS REPORT FORMAT
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance and approval of format for Contractor’s Monthly Progress Report.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.41
ACTIONS REQUIRED
1. The Project Director/Project Manager shall request the Contractor to propose a format
for the Monthly Progress Report taking in to account requirements stipulated under the
terms of the Contract such as:
2. The Project Director/Project Manager shall review the proposed format for the Monthly
Progress Report and informed the Contractor whether it is acceptable or changes to the
format are required.
3. The Contractor shall adopt the format for Monthly Progress Report accepted by the
Engineer.
4. The Engineer shall ensure that the Contractor adhere to the accepted format when he
submits his Monthly Progress Reports.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.21 [Progress Reports]
Sub-Clause 14.3 [Application for Interim Payment Certificates]
ATTACHMENTS
Specimen Letters
SL/CA 33/ 01 – Acceptance of Monthly Progress Report Format
41
It is convenient for parties to agree to a format for such Monthly Progress Report and the Contractor shall be requested to
submit
such format for Engineer’s concurrence.
107
PROCEDURE NO. CA 35
PROCEDURE ISSUING OF DRAWINGS AND INSTRUCTIONS
TITLE
REVISION NO. B REVISION DATE 8th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to issuing of
additional and or modified drawings and instructions in accordance with the FIDIC and
ICTAD Conditions of Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer and his assistants shall identify whether there is a necessity for
additional or modified drawings and instructions due to inadequacies and errors in
contract documents, unforeseen site conditions, change in the design or due to any
other reason. The Engineer should take immediate action to rectify the situation by
promptly issuing such drawings and instructions.
2. The Engineer shall ensure that such instructions will not substantially vary the scope
of the Work or the original intent of the Contract. Site Instructions issued would
typically explain ambiguities in the drawings or clarify technical requirements as
necessary for the proper execution and completion of the Works and the remedying
of any defects therein.
3. If notice is given to the Engineer by the Contractor, under the Contract, that the
Contractor may suffer delay due to lack of drawings or instructions, the Engineer
should take immediate action to rectify the situation.
4. The Engineer shall ensure that the issue of necessary additional or modified
drawings, and instructions required by the Contractor, to comply with his program of
work, are issued without delay.
5. If the Contractor incurs delay or additional costs as a result of failure by the Engineer
to issue drawings and instructions within a reasonable time, the Engineer’s Assistant
should keep relevant records to determine any extension of time and/or additional
costs to which the Contractor may be entitled under the Contract.
6. The Engineer’s site staff should, whenever possible, avoid giving oral instructions to
the Contractor. Should an oral instruction be unavoidable, written confirmation
should be given as soon as possible thereafter. It is preferable that the Engineer’s
Assistants provide written confirmation of his oral instructions rather than giving the
Contractor the opportunity to do this, since the Contractor may well alter the context
of the oral instruction.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 3.3 [Instructions of the Engineer]
ATTACHMENTS
Specimen Letters
SL/CA 35/ 01 – Engineer’s Instruction
Specimen Formats
SF/CA 35/ 01 – Format for Engineer’s Instruction
108
PROCEDURE NO. CA 36
PROCEDURE ACCEPTANCE OF FORMATS FOR RETURNS OF
TITLE LABOUR/EQUIPMENT
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
acceptance of formats for monthly returns of Contractor’s Personnel and Equipment until all
the works under the Contracts are completed.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Engineer shall advise the Contractor to submit his proposed format for
monthly returns of labour and equipment.
2. Upon receiving the proposed format for monthly returns of labour and equipment
from the Contractor, the Engineer shall review the same to ensure that the format is
adequate for the purpose.
3. If the proposed format is acceptable the Engineer shall promptly give his approval for
the same.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 6.10 [Records of Contractor’s Personnel and Equipment]
ATTACHMENTS
Specimen Letters
SL/CA 36/ 01 – Acceptance of Formats for Contractor’s Labour/Equipment Returns
109
PROCEDURE NO. CA 37
PROCEDURE REVIEW OF QUALITY ASSURANCE SYSTEM AND QUALITY
TITLE PLANS
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
Establishment of and implementation of the Contractor’s such quality assurance system and
conducting of periodic quality audits on the Contractor by the Engineer.42
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that his staff are conversant with
quality assurance principles and competent in quality assurance functions such as
quality auditing.
2. The Project Director/Project Manager shall request the Contractor to submit his
quality assurance system documents and his Project Quality Plan for the Contract.
3. The Contractor’s quality assurance system documents shall include a quality Guide,
quality procedure Guide and work instructions.
5. The Contractor’s quality assurance system and Project Quality Plan shall include
provisions for the Contractor’s staff to review and certify certain documents for
compliance with contractual requirements, prior to requesting Engineer’s approval for
the same.
7. Upon completion of the document review, the Project Director/Project Manager shall
inform the Contractor of the acceptance of the Contractor’s quality assurance system
documents if there are no non-compliances found.
8. If there are any non-compliance found in the document, such non-compliances shall
be addressed through either amending the Contractor’s Project Quality Plan or
revising the Contractor’s quality assurance system documents.
42
FIDIC forms of Contracts (Red book, Pink book and Yellow book) require the Contractor to establish a quality assurance
system
forhis organization, which may be structured in accordance with a reputed international standard such as ISO9000 standard
and which shall include a procedure to establish a documented Quality Plan to demonstrate compliance with the requirements
of the Contract.
110
9. The Project Director/Project Manager shall arrange periodic audits of the Contractor’s
quality assurance system to verify whether the implementation of the said system is
effective. Audits shall be carried out by a person who is competent to perform such
quality audits and having adequate experience. Audits may be performed either by
trained in-house auditors or auditors engaged through an external organization such
as CIDA.
10. Upon completion of an audit, the Project Director/Project Manager shall inform the
Contractor of the non-compliances found and issue a request to the Contractor to
submit his proposal for remedying non-compliances within a time frame.
11. Upon receiving Contractor’s proposal for remedying non-compliances, the Chief
Engineer shall review the same for effectiveness and accept the proposal if
satisfactory. If the Contractor’s proposal for remedying non-compliances is not
satisfactory, the Chief Engineer shall request the Contractor to submit a revised
proposal.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.9 [Quality Assurance]
ATTACHMENTS
Specimen Formats
SF/CA 37/ 01 – Non Conformance Notice
SF/CA 37/ 02 – Corrective Action Request
Specimen Letters
SL/CA 37/ 01 – Review of the Contractor’s Quality Assurance System
SL/CA 37/ 02 – Comments on the Contractor’s Quality Assurance System
111
Part Two
112
CONTENT OF PROCEDURES - EXECUTION STAGE
113
PROCEDURES CA 38 TO CA 58
PROCEDURE NO. CA 38
PROCEDURE CONDUCTING OF MONTHLY PROGRESS MEETINGS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to conducting
Monthly Progress Meetings, which are usually chaired by the Engineer or his Assistant with
the participation of the Project Director/Project Manager, Contractor’s representative and
Engineer’s senior staff.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer or his Assistant shall arrange the Monthly Progress Meetings in
consultation with the Project Director/Project Manager and the Contractor’s
Representative.
2. The Engineer or his Assistant shall prepare the agenda for the meeting and circulate
that to all participants with the invitation for the meeting well in advance.
3. The Engineer or his Assistant shall chair Monthly Progress Meetings and assign a
competent person to record and maintain the minutes.
5. Minutes of the Monthly Progress Meetings shall be prepared and circulated to all
participants upon review by the Project Director/Project Manager.
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 38/ 01 – Format for Monthly Progress Review Meeting Minutes
114
PROCEDURE NO. CA 39
PROCEDURE PREPARATION OF MONTHLY PROGRESS REPORTS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to preparation
of Monthly Progress Reports. The Project Director/ Project Manager and the Engineer are
required to submit Monthly Progress Reports regularly to the line ministry, ERD, Funding
Agency, CIDA and the management of the implementation agency.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. Project Director/ Project Manager and the Engineer shall prepare Monthly Progress
Reports to reflect the status of the Contract at the end of each quarter.
2. Monthly Progress Reports should include physical and financial progress of the
Works, financial status, quality issues, resources utilization, variations and claims,
dispute resolution and issues affecting the performance of the Contract.
3. Monthly Progress Reports should be submitted to the secretary of the line ministry,
ERD, Funding Agency, CIDA and the management of the implementation agency on
or before 15th of the following month.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.21 [Progress Reports]
ATTACHMENTS
Specimen Formats
SF/CA 39/ 01 – Format for Monthly Progress Report
115
PROCEDURE NO. CA 40
PROCEDURE PREPARATION OF QUARTERLY PROGRESS REPORTS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to preparation
of Quarterly Progress Reports which are required to the line ministry, ERD, Funding Agency,
CIDA and the management of the implementation agency.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. Project Director/ Project Manager and the Engineer shall prepare Quarterly Progress
Reports to reflect the status of the Contract at the end of each quarter.
2. Quarterly Progress Reports should include physical and financial progress of the Works,
financial status, status of implementation of loan covenants and issues affecting the
performance of the Contract.
3. Quarterly Progress Reports should be submitted to the secretary of the line ministry,
ERD, Funding Agency, CIDA and the management of the implementation agency on or
before 15th of the first month in the following quarter.
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 40/ 01 – Format for Quarterly Progress Report
116
PROCEDURE NO. CA 41
PROCEDURE PREPARATION OF ANNUAL PROGRESS REPORTS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to preparation
of Annual Progress Reports which are required to be submitted to the line ministry, ERD,
Funding Agency and the management of the implementation agency.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. Project Director/ Project Manager and the Engineer shall prepare Annual Progress
Reports to reflect the status of the Contract at the end of each year.
2. Annual Progress Reports should include physical and financial progress of the Works,
financial requirements for the following year and issues affecting the performance of the
Contract.
3. Annual Progress Reports should be submitted to the secretary of the line ministry, ERD,
Funding Agency and the management of the implementation agency on or before end of
the month January in the following year.
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 41/ 01 – Format for Annual Progress Report
117
PROCEDURE NO. CA 42
PROCEDURE STEERING COMMITTEE MEETINGS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to conducting
of Steering Committee Meetings
Steering Committee Meetings are conducted with the participation of all major stakeholders
of the project with the Secretary to the line ministry or his representative chairing the
meeting. Steering Committee is the apex body headed by the Secretary to the line ministry
and has authority to take decisions regarding the matters related to execution of the project
(and all contracts under the project).
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall arrange the Steering Committee Meetings
on the advice of the Secretary to the line ministry.
2. The Project Director/Project Manager shall prepare the agenda for the meeting and
circulate that to all participants with the invitation for the meeting at least one week in
advance.
3. The Secretary to the line ministry shall chair the Steering Committee Meetings and all
major stakeholders shall be invited to participate.
4. The Project Director/Project Manager shall assign a competent person to record and
maintain the minutes of the Steering Committee meetings. The meeting minutes
should state clearly the maters referred for deliberation, issues referred for
discussion and agreed upon and record any dissent
5. The Project Director/ Project Manager and the Engineer shall present information on
status of progress, status of financing, critical issues affecting the progress, any
obstructions or impediments to contractor’s progress and any environmental or social
issues affecting the project.
7. Status of each unresolved resolution and follow up action necessary for the same
shall be discussed during every subsequent Steering Committee Meeting until issues
under such resolutions are finally resolved.
118
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 42/ 01 – Format for Agenda for Steering Committee Meeting
SF/CA 42/ 02– Format for Attendance Record for Steering Committee Meeting
SF/CA 42/ 03 – Format for Minutes of the Steering Committee Meeting
119
PROCEDURE NO. CA 43
PROCEDURE MONITORING OF PROGRESS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried to monitor and document the
progress of works.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. At the start of the project, the Engineer shall review the original Contractual Program
submitted by the Contractor. This program shall be sufficiently detailed to identify
individual activities, milestones and relationship between them. The program also
shall indicate sequence of activities and milestones and the critical path(s) and it
shall comply with the contractual requirements.
2. The Engineer shall use the same project management software or a compatible
software as the Contractor for monitoring of progress.
3. The Contractual Program shall be fixed as a "baseline" program and actual progress
shall be periodically updated to give a comparison between planned and actual
progress.
4. As work progresses, actual progress data will be input on a regular basis for
comparison with that planned in the original Contractual Program. The progress data
will be entered at least monthly but shorter periods may be preferable if the activities
are of short duration and critical.
7. Drawings and/or charts will be prepared for each major item of work such as, but not
limited to, the following examples:
o excavation
o earthworks
o road pavements
o bridge substructures
o bridge superstructures
o drainages
o drilling
o concrete works
o structural steelwork erection
o pipe work
o architectural works
120
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 43/ 01 – Format for Recording Progress for Monitoring
121
PROCEDURE NO. CA 44
PROCEDURE MONITORING OF CRITICAL ISSUES
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out for the management of
critical issues which may impede/interrupt the progress of the works and could result in
additional costs and/or prolongation of the contract period. Variations to the Contract may be
required to resolve certain critical issues while some other critical issues may be resolved
through proper coordination with other stakeholders.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. When a critical issue becomes known, the Engineer will enter the details in the
Critical Issues Register.
2. All relevant information and documentation relevant to each critical issue shall be
compiled and shared among the staff responsible for resolving the critical issue.
3. Circumstances leading to the critical issues shall be analyzed to determine the root
cause and decide on actions to be taken to resolve the same.
5. All unresolved critical issues shall be included in progress reports and shall be
reported to Steering Committee for resolution. Such unresolved critical issues shall
initiate steering committee resolutions and shall be followed up during each Steering
Committee meeting until its resolution.
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 44/ 01 – Format for Register of Critical Issues
122
PROCEDURE NO. CA 45
PROCEDURE UPDATING OF WORK PROGRAM
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to updating of
Work Program.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD which require the
Contractor to submit a comparisons of actual and planned progress of the Works and details
of any events or circumstances which may delay the completion in accordance with the
Contract, in his Monthly Progress Reports.
ACTIONS REQUIRED
1. The Engineer shall ensure that the Contractor submits with his Monthly Progress
Report, an updated work program in tracking Gantt chart with the original program
fixed as a base line and all progress data which he input to update the Program.
2. The Engineer shall assign a competent person to review the program for accuracy of
data input and changes in critical path.
3. Impact of delay events for which the Employer is responsible and the Contractor has
notified within the specified time limit, shall be applied and their effect on completion
date shall be noted
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.21 [Progress Reports]
ATTACHMENTS
Format for updated work program will be included in the Project Management Volume of the
GPMCM Guide
123
PROCEDURE NO. CA 46
PROCEDURE UPDATING OF CONTRACT AMOUNT AND FORECAST COST
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to updating
Contract Amount and Forecast cost.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer shall update the Contract Amount43 and the Forecast Cost44
periodically (preferably at quarterly intervals) and inform.
2. The Project Director/Project Manager and the Engineer shall include such
information in the monthly and quarterly progress reports for higher managements of
Executing and Implementation Agencies to become aware of the financial status of
the project and take action accordingly.
REFERENCES
None
ATTACHMENTS
Specimen Formats
SF/CA 46/ 01 – Format for Updating of Contract Amount and Forecast Cost
43
The Contract Amount is an estimated cost which is an expected value of a contract at a given time, calculated by making
adjustments to the Accepted Contract Amount based on latest information available. Such new information may be:
(a) value of works actually executed and value of works to be executed calculated based on latest information available
(including provision sum items);
(b) value of services, Plants and materials actually supplied and value of services, Plants and materials to be supplied
calculated based on latest information available (including provision sum items);
(c) variations for which valuation agreed or determined and variations for which the Engineer agree in principle;
(d) claims agree or determined and claims for which the Engineer agree in principle;
(e) adjustments made (for changes in costs, changes in legislation and work carried out under provisional sums) in
accordance with the Contract;
(f) Forecast for adjustments to be made for changes in costs based on current cost indices; and
(g) Any other cost actually incurred or to be incurred based on latest information available.
124
PROCEDURE NO. CA 47
PROCEDURE USE OF PROVISIONAL SUMS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to use of
Provisional Sums which are specified in the Contract as a provisional sum, for the execution
of any part of the Works or for the supply of Plant, Materials or services under the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager and the Engineer shall review the Contract to
identify provisional sums45 included within the BOQ/Schedule. Valuation of
provisional sums shall be based on actual amounts expended by the Contractor,
which should be substantiated by submission of quotations, invoices, vouchers and
accounts or receipts.
2. If there is a necessity to execute works under a provisional sum, the Engineer shall
instruct the Contractor to execute such works: and value under the variation
procedure, when the works, supplies or services are to be carried out directly by the
Contractor; or value based on the actual amounts paid (or due to be paid) by the
Contractor to a nominated sub contractor or others with an overhead and profit
component, when the Contractor assigns such works to a nominated sub contractor
or others.
3. The Engineer shall instruct the Contractor to submit quotations, invoices, vouchers
and accounts or receipts, to substantiate his expenses.
45
Provisional Sum is usually provided for a specific work, supply or Service and therefore it should only be use for making
payments for specific work, supply or Service to which it relates. Provisional Sums are specifically included under separate
items in a BOQ/Schedule, when it is impossible to provide BOQ/Schedule items to represent certain works, supplies or services
due to uncertainties involved with regard to extent, specifications and quality of such works, supplies or Services. (e.g.
Provisional Sum for diversion/relocation of electrical services, Provisional Sum for environmental protection and Provisional
Sum for site investigation). However it is prudent to avoid provision of provisional sums in a BOQ/Schedule whenever it is
possible, as valuation of provisional sums may lead to disputes.
A Provisional Sum for Adjustments for Changes in Cost (Price escalation) is usually provided in a BOQ/Schedule in order
to allocate an amount for the same in the Accepted Contract Amount while another Provisional Sum for Contingencies is
provided in a BOQ/Schedule to make allocations in the Accepted Contract Amount for making payments for contingencies such
as variations, claims and DB/DAB costs.
A Provisional Sum should be only be used at the discretion of the Engineer, in accordance with his instructions, in whole, in
part or not at all.
125
4. The Engineer shall value the works carried out under each provisional sum either
following variation procedure or based on actual cost expended together with an
overhead and profit component as the case may be and notify the parties
accordingly. It is recommended that different percentages should be provided as
overheads and profit percentages for provisional sums (at the tender stage),
depending on the extent of involvement of the Contractor in the execution of works
under such provisional sums. (e.g. for provisional sums for utility relocation/diversion
where the Contractor’s involvement is minimal, a lesser percentage such as 5%-
10%; for provisional sum for environmental protection where the Contractor’s
involvement is considerable 15%)
5. The Engineer shall adjust the Contract Price upon valuation of works carried out
under each provisional sum
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 13.5 [Provisional Sums]
ATTACHMENTS
Specimen Letters
SL/CA 47/ 01 – Request for Evidence to Substantiate Provisional Sum Payments
126
PROCEDURE NO. CA 48
PROCEDURE MANAGING DESIGN CHANGES INCLUDING CONTROL OF
TITLE DRAWINGS
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
management of design changes which are often subject to change during the execution of
the contract due to various reasons, irrespective of which party is responsible for such
designs.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer shall review the original design in the light of new information available
including survey data, geotechnical information and hydrological information.
2. The Engineer, upon receiving new information during the execution of the contract,
shall indentify whether there is a necessity for changes/modifications to the original
designs. Such changes may be necessary:
a. When it is clear that actual site conditions are different from assumed site
conditions, based on which original designs were carried out.
b. When there are problems with regard to suitability, buildability and economy
of the original design.
c. When there are obvious errors in the original design with regard to design
inputs, design method, design calculations/analysis and design inputs
(including drawings).
d. When there is a proposal on Value Engineering from the Contractor.
e. When the Employer wants to change the concept of the design and the scope
of the works.
3. The Engineer, if there is a necessity for design changes, assign that responsibility to
a competent person who is conversant with such type of design works involved, upon
informing the Employer. If any design changes are necessary due to a Contractor’s
proposal for Value Engineering, the Contractor is responsible for such design and the
Engineer shall review the same for compliance with contractual requirements.
4. When the Employer obtain a assessable financial benefit from a Contractor’s Value
Engineering proposal, considering the reduction in contract value attributable to such
proposal and the reduction (if any) in the value to the Employer of the varied works,
due to reductions in quality, anticipated life or operational efficiencies, the Contractor
shall be paid a fee amounting to half of such financial benefit upon the Engineer
agree or determine such amount.
5. Upon completion of the design changes, all relevant design inputs, design
analysis/calculations and design drawings shall be submitted to competent persons
for verification and validation of the design.
127
6. Upon verification and validation of the design change, the Engineer shall review and
approve the same.
7. If the design change is affecting only a part of a drawing, that part should be
highlighted using a cloud for ease of identification, revision notes should be included
to indicate description of the design change and revision status of the drawing should
be indicated by adding a capital letter to end of the drawing number (For first revision
letter A).
8. Before issuing the drawing to the Contractor, drawing shall be signed by persons
who designed, checked and approved and drawing register shall be updated to
include the revised drawing. Engineer’s Assistant shall take action to stamp all
obsolete copies of the previous version of the drawing with “OBSOLETE” and
remove them from usage to avoid confusion. All copies of obsolete drawings shall be
destroyed except one copy which should be kept for historical reference.
9. The revised drawing which includes the design change shall be issued to the
Contractor.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 3.3 [Instructions of the Engineer]
Sub-Clause 13.2 [Value Engineering]
ATTACHMENTS
Specimen Formats
SF/CA 48/ 01 – Format for Drawing Register
128
PROCEDURE NO. CA 49
PROCEDURE MANAGING VARIATIONS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to instructing,
processing and evaluation of variations.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer may initiate a variation either through an instruction or a request for the
Contractor to submit a proposal. The Engineer shall initiate a variation upon identifying
himself for necessity for the same. The Engineer may initiate a variation on a request for
the same by the Employer or the Contractor, upon considering whether such requests
fall within the scope of the Permanent Works defined within the Contract and whether
such request is for change which constitutes a variation as defined in the Contract.
2. Variations shall not be issued for any increase or decrease in the quantify of any work
where such increase or decrease is not the result of an instruction given to change the
form, levels, positions and/or dimensions, but is the result of the quantities exceeding or
being less than those stated in the Schedules/Bill of Quantities (as quantities stated in
the BOQ/Schedules are not actual but estimated quantities).
a. For change in the form (levels, positions and/or dimensions), quantity, quality or any
other characteristics of the Works
b. For any additional work, Plant, Materials or services necessary for the Works
c. For changes to the sequence or timing of the execution of the Works
d. For omission of any work unless it is to be carried out by others
4. The Engineer shall provide a unique serial number for each variation instructed,
preferably in the format XXXX/VO NN (XXXX denotes an abbreviation for the contract
e.g. DZWS/VO 12) and that serial number shall be quoted in subsequent exchange of
correspondences relevant to that variation.
5. The Engineer shall carry out valuation of variations by first initiating consultation with
both parties to reach an agreement on the valuation, failing which the Engineer shall
determine the valuation.
6. If there are rates or prices specified in the Contract for items involved in the instructed
variation, those rates or prices shall be used for valuation of the variation, otherwise
rates or prices shall be derived from any relevant rates or prices in the Contract, with
reasonable adjustments to take account of difference between both items in character
and conditions under which such works are to be executed.
7. If there are no relevant rates or prices specified in the Contract from which new rates or
prices could be derived by applying reasonable adjustments, new rates or prices shall
be derived from the reasonable Cost of executing the work with a reasonable profit.
129
8. The Engineer shall use a provisional rate or price for making payments for variations in
Interim Payment Certificates until an appropriate rate or price is agreed or determined.
9. The Engineer shall not instruct variations after issuing of the Taking Over Certificate.
10. Engineer’s authority to order variations may be restricted through provisions in the
Contract which require the Engineer to obtain the specific approval of the Employer prior
to instruct a Variation, or may allow the Engineer to issue Variations within delegated
financial limits except in an emergency situation affecting the safety of life or of the
Works or of adjoining property.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 12.3 [Evaluation]
Sub-Clause 13.1 [Right to Vary]
Sub-Clause 13.3 [Variation Procedure]
ATTACHMENTS
Check List
CL/CA 49/ 01 – Variation Check List
Specimen Formats
SF/CA 49/ 01 – Format for Variation Order Register
SF/CA 49/ 02 – Format for Variation Order
130
PROCEDURE NO. CA 50
PROCEDURE APPROVAL FOR NEW RATES
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to deriving of
new rates when it is required under the terms of the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer shall identify whether there is a necessity for derivation of new rates
with regard to evaluation of variations under Variation Procedure, Provisional Sums
or/and measured quantity of any item of work stated in the Bill of Quantities/the
Schedule being changed by more than the percentage stipulated in the Contract,
from the quantity of this item in the Bill of Quantities/the Schedule.
2. If there is a necessity for derivation of new rates, the Engineer shall consult both
parties to reach an agreement on such new rates, failing which he shall determine
reasonable and appropriate rates based on the provisions in the Contract.
3. The Engineer shall derive new rates from any relevant rates in the Contract, with
reasonable adjustments to take account of the differences in the character and the
conditions under which the item of work is to be executed from that of the item of
work for relevant rates.
4. When there are no relevant rates from which new rates could be derived, the
Engineer shall derive new rates from the expenditure reasonably incurred (or to be
incurred) by the Contractor with overheads and profit46.
5. Whenever the measured quantity47 of any item of work stated in the Bill of
Quantities/the Schedule is changed by more than the percentage stipulated in the
Contract, from the quantity of this item in the Bill of Quantities/the Schedule, new
rates derived by the Engineer shall only be applicable to excess quantity of the item
over and above the BOQ quantity plus the percentage stipulated in the Contract.
Rate applicable for the quantity below the BOQ quantity plus the percentage
stipulated in the Contract, is the rate specified in the BOQ/Schedule.
6. Alternatively, it is possible to derive a uniform rate for the entire quantity of the item
by combining costs of both quantities and deriving a rate by dividing that amount by
total quantity involved. The cost of executing the works up to the BOQ quantity plus
the percentage stipulated in the Contract shall be based on the rate specified in the
BOQ/Schedule.
46
FIDIC Pink Book requires profit to be 5%.
47
If the measured quantity of an item of work stated in the Bill of Quantities/the Schedule is changed by more than the
percentage stipulated in the Contract (25% for pink book but 10% for Red book) from the quantity of this item in the Bill of
Quantities/the Schedule; and this change in quantity multiplied by such specified rate for this item exceeds 0.25% of the
Accepted Contract Amount; and this change in quantity directly changes the Cost per unit quantity of this item by more than 1%
and this item of work is not specified in the Contract as a “fixed rate item”.
131
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 12.3 [Evaluation]
Sub-Clause 13.3 [Variation Procedure]
Sub-Clause 13.5 [Provisional Sums]
ATTACHMENTS
Specimen Letters
SL/CA 50/ 01 – Letter to Inform New Rates Determine by the Engineer
132
PROCEDURE NO. CA 51
PROCEDURE MANAGING CLAIMS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
management of Contractor’s claims in connection with the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
Contractor’s Claims may arise due to loss suffered, additional costs incurred and/or delay
suffered by a contractor, caused by:
a. breach of the terms of the contract due to an action or inaction of the Employer or
the Engineer
b. Changes to the Contract, instructed
c. Unforeseen events for which neither party is responsible
d. action or inaction of a third party
A Contractor should be paid for loss suffered and/or additional costs incurred due events for
which he is not responsible, with additional amounts as compensation which will put him in
the position he would have been in, if he had not incurred such additional costs or suffered
losses due to events for which the claim is made.
All major forms of contracts, including FIDIC Red book and Pink book, provide for a
Contractor to claim additional payments and/or extensions of the Time for Completion which
he entitle under the terms of the Contract or otherwise under the laws, in connection with the
Contract. FIDIC Red book and Pink book require a Contractor to give notice to the Engineer,
describing the event or circumstance giving rise to the claim within 28 days after the
Contractor became aware, or should have become aware, of the event or circumstance, to
become entitle for such claim. Since above notification requirement is mandatory, a
Contractor shall not be entitled for any additional payments and/or extensions of the Time for
Completion, if he fails to give a valid notification within the stipulated time.
Upon submitting a valid notification to the Engineer, the Contractor is required to submit any
other notices required under the Contract and supporting particulars for the claim, which are
relevant to such event or circumstance
133
Usually under the provisions in the Contract, a Contractor is entitled for costs which has
been defined under the FIDIC conditions as “all expenditure reasonably incurred (or to be
incurred) by the Contractor, whether on or off the Site, including overhead and similar
charges, but does not include profit”. However most of the Sub- Clauses in FIDIC form of
contracts, allow payment of profit on such costs. Following table (Table CA 51-01), illustrate
Contractor’s entitlement for such costs and profits under various Sub-Clauses:
Table CA 51-01 - Contractor’s Entitlement for Time Costs and Profits under the
Contract
Sub-Clause in Conditions of Contract
Contractor’s Entitlement
(FIDIC –MDB)
4.24 Fossils Y Y N
7.4 Testing Y Y Y
12.4 Omissions N Y N
17.1 Indemnities N Y N
134
Unless his authority is restricted under the terms of the Contract, the Engineer is required to
give his response on the principles of the claim and his approval, or disapproval with detailed
comments, within the time stipulated in the Contract or otherwise agreed with the Contractor.
The Engineer is also required to agree to or determine any extension of the Time for
Completion and/or any additional payment to which the Contractor is entitled under the
Contract, within the time stipulated in the Contract. When the Engineer’s authority is
restricted under the terms of the Contract, the Engineer is required to obtain specific
approval of the Employer prior to giving any response, approval or determination with regard
to a claim.
However, when the event or circumstance giving rise to a claim has a continuing effect, the
Contractor’s fully detailed claim shall be considered as interim with the Contractor submitting
such further interim claims at monthly intervals as required by the Engineer. The
Contractor’s final claim must be submitted within 28 days or such other period agreed with
the Engineer, of the “continuing effects” coming to an end.
While a Contractor’s failure to comply with notification requirement for a claim will result in
the Contractor’s entitlement being invalidated, his failure to comply with other requirements
stipulated in the Contract with regard to claims may result in the Contractor’s entitlement being
restricted.
ACTIONS REQUIRED
1. The Project Director/Project Manager and the Engineer shall take every endeavour to
avoid claims (or at least minimizing them) during the execution of a contract by
eliminating potential causes for claims such as:
2. The Project Director/Project Manager and the Engineer shall form a strong claim
management team by:
3. Upon receiving a notice for a claim from the Contractor, the Engineer shall Review the
content of the notice and check whether the contractor has adequately described the
event or circumstance giving rise to the claim and the notice has been issued within 28
days after the Contractor became aware, or should have become aware, of the event or
circumstance.
135
4. If the Contractor has not adequately described the event or circumstance giving rise to
the claim for the Engineer to clearly identify the event or circumstance giving rise to the
claim and its effect on the contract price and the time for completion, the Engineer shall
advise the Contractor that his notice is not valid due to his failure to adequately
described the event or circumstance giving rise to the claim, as required under the
Contract.
5. Unless the Contractor’s claim notice is issued within the stipulated time period of 28
days after the Contractor became aware, or should have become aware, of the event or
circumstance, the Engineer shall inform the Contractor that the claim is rejected in
accordance with the Sub-Clause 20.1 of the Conditions of Contract and therefore the
Contractor is not entitled for any additional payment and/or any extension of time for
completion thus discharging the Employer of all liability in connection with the claim.
6. Unless the Contractor has copied the notice of the claim to the Employer, the Engineer
shall inform the Employer of such notice and shall jointly endeavour to mitigate the
effect of the event or circumstance giving rise to the claim.
7. The Engineer, if the Contractor’s notification is satisfactory, shall assign each claim with
a serial number in the format AAAA/Claim XX (e.g. DZWS/Claim 08) and enter in to the
Claim Register format of which is provided in the Attachment XX.
8. The Engineer shall inform the Contractor that his claim is noted and registered in the
Claim Register, without admitting the Employer’s liability for the claim.
9. The Engineer, with the assistance of the claim management team, shall identify
contemporary records which should be maintained to proper evaluation of the claim and
the Engineer shall inform the Contractor accordingly. The Engineer shall direct his staff
to inspect/monitor maintenance of such contemporary records by the Contractor and he
may also instruct the Contractor to submit copies of all such records or certain part of
such records.
10. Upon submission of a fully detailed claim with detailed supporting particulars by the
Contractor, the Engineer shall direct his claim management team to study the same to
verify whether the Contractor is entitled for the claim in principle and if the Contractor is
entitled, quantum (additional amount and/or extension of time) for which the Contractor
entitled.
11. The Engineer shall give his opinion on the claim in principle within 42 days upon
receiving a claim. The Engineer, if necessary, may request the Contractor to submit
further information which may be required for evaluation of Contractor’s claim.
12. The Engineer shall finalize his draft recommendation on a claim and initiate consultation
with each party in order to get their agreement on the draft recommendation. It is
prudent for the Engineer to commence consultation with the Employer first, since most
contracts require Employer’s specific approval for the Engineer to give his
determination.
13. If it is possible to reach an agreement with both parties, the Engineer shall notify his
determination based on such agreement but failing that the Engineer shall notify his
determination based on a fair evaluation in accordance with the Contract, within 42 days
upon receiving a claim, taking in to account all relevant facts and evidence, subject to
restrictions imposed for such determination.
136
14. The Engineer shall include any amounts determined by him for claims in his Interim
Payment Certificate, if the Contractor makes an application for the same in any of his
subsequent monthly statement.
15. If the event or circumstance giving rise to a claim has a continuing effect, the
Contractor’s fully detailed claim shall be considered as interim and the process shall be
repeated monthly until cessation of such event or circumstance when the final
determination shall be given upon the Contractor’s submission of final particulars on a
claim.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 20.1 [Contractor’s Claims]
ATTACHMENTS
Specimen Formats
SF/CA 51/ 01 – Format for Contractor’s Claim Register
137
PROCEDURE NO. CA 52
PROCEDURE MANAGING EXTENSIONS OF TIME
TITLE
REVISION NO. A REVISION DATE 10th November 2014
SCOPE
Scope of this procedure covers activities required to be carried out with regard to claims for
Extension of Time for Completion including carrying out of Delay analysis to assess the
extent of EOT a contractor is entitled for.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
FIDIC forms of Contracts in its Sub-Clause 8.4 of Conditions of Contract provides that the
Contractor is entitled for an Extension of Time (EOT) for Completion, if completion of the
Works is or will be delayed by any of the following causes:
a. A Variation (unless an adjustment to the Time for Completion has been agreed under
Sub-Clause 13.3 [ Variation Procedure ]) or other substantial change in the quantity
of an item of work included in the Contract.
b. A cause of delay giving an entitlement to extension of time under a Sub-Clause of
these Conditions.
c. Exceptionally adverse climatic conditions.
d. Unforeseeable shortages in the availability of personnel or Goods caused by
epidemic or governmental actions, or
e. Any delay, impediment or prevention caused by or attributable to the Employer, the
Employer’s Personnel, or the Employer’s other contractors.
A Contractor will be entitled for an EOT if he suffers or will suffer a delay under following
Sub-Clauses in FIDIC forms of Contracts:
When a valid notice is given and fully detailed claim is submitted the Engineer shall promptly
determine the contractor’s entitlement for such claim in principle and extent of an extension
to be given, to avoid Time for Completion becoming at large. When the Time for Completion
138
is at large, thus having no definite completion date, it may affect the progressing of the
Contract as there are no definite milestones or targets to be met.
A contractor will be entitled for an EOT, only if he suffers a delay which would extend the
Time for Completion due to prolongation of work activities of the critical path effective at the
time of that delay. Therefore, the Contractor should submit a proper delay analysis through
Critical Path Method (CPM) preferably using a project management software such as MS
Projects or Primavera.
There are several accepted methods for delay analysis and following are the methods widely
used in the construction industry:
It should also be noted that the Engineer has no authority to shorten a time for completion or
repeal an EOT or part of it already given.
ACTIONS REQUIRED
1. For management of claims for Extensions of Time (EOT) for Completion, the Project
Director/Project Manager and the Engineer shall follow the procedure described in
items 1 to 13 of the Procedure No. CA 51.
2. In addition to above, if the Contractor has a valid entitlement for an EOT, the
Engineer shall direct his Claims Management Team to review the delay analysis
submitted by the Contractor to assess the quantum of EOT, the Contractor is entitled
for.
3. The his Claims Management Team shall review for the delay analysis, whether the
Contractor has used:
4. Upon reviewing the delay analysis, the Engineer shall initiate consultation process
with each party to reach an agreement. In the event of disagreement the Engineer
shall determine the Contractor’s entitlement for quantum of EOT subject to specific
approval of the Employer if required under the Contract.
5. The Engineer shall grant EOT only if the delay suffered is caused due to a default of
the Employer/Engineer, due to a neutral event for which neither party is responsible
or due to concurrent events for which both parties are responsible. The Contractor
should not be granted EOT for delays due to a default of himself.
6. The Engineer shall also determine whether the Contractor is entitled for prolongation
costs due to EOT granted, considering following:
a) the Contractor is not entitled for prolongation costs for EOT granted for
concurrent delays for which both parties are responsible.
b) the Contractor is not entitled for prolongation costs for EOT granted under the
provisions in the Contract, when such entitlement is not specifically stated (e.g.
EOT granted for exceptionally adverse weather, Delays caused by Authorities)
139
7. The Engineer shall notify the parties of his determination on the EOT with his detailed
analysis.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 8.4 [Extension of Time for Completion]
Sub-Clause 20.1 [Contractor’s Claims]
ATTACHMENTS
Check List
CL/CA 52/ 01 – Extension of Time Check List
Specimen Letters
SL/CA 52/ 01 – Letter to Notify the Engineer’s Determination on Extension of Time
140
PROCEDURE NO. CA 53
PROCEDURE EMPLOYER’S CLAIMS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
management of Employer’s Claims
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager and the Engineer shall identify events or
circumstances for which an Employer’s Claim could be raised including for delays for
which the Contractor is responsible and delay damages could be claimed.
2. The Project Director/Project Manager or the Engineer shall notify the Contractor of
the Employer’s Claim within 28 days after they became aware, or should have
become aware.
3. If the Employer’s Claim is for an extension of the Defects Notification Period, it shall
be given before the expiry of such period.
4. The Project Director/Project Manager or the Engineer shall provide the Contractor
with detailed particulars which should specify the contractual or other basis of the
claim and should include substantiation of the amount and/or extension to which the
Employer considers himself to be entitled.
5. The Engineer shall initiate consultation with each party with regard to Employer’s
claim, to reach an agreement. If it is possible to reach an agreement with both
parties, the Engineer shall notify his determination based on such agreement but
failing that the Engineer shall notify his determination based on a fair evaluation in
accordance with the Contract, within 28 days upon receiving a claim, taking in to
account all relevant facts and evidence.
6. The Employer may deduct any amount determine by the Engineer as due to the
Employer from the Contractor, from his any subsequent Interim Payment Certificates.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 2.5 [Employer’s Claims]
Sub-Clause 4.19 [Electricity, Water and Gas]
Sub-Clause 4.20 [Employer’s Equipment and Free-Issue Materials]
Sub-Clause 7.5 [Rejection]
Sub-Clause 7.6 [Remedial Works]
Sub-Clause 8.6 [Rate of Progress]
Sub-Clause 8.6 [Delay Damages]
Sub-Clause 9.4 [Failure to Pass Tests on Completion]
Sub-Clause 9.4 [Extension of Defects Notification Period]
Sub-Clause 11.4 [Failure to Remedy Defects]
Sub-Clause 15.4 [Payment after Termination]
141
Sub-Clause 18.1 [General Requirements for Insurances]
Sub-Clause 18.2 [Insurance for Works and Contractor’s Equipment]
ATTACHMENTS
Specimen Formats
SF/CA 53/ 01 – Format for Employer’s Claim Register
142
PROCEDURE NO. CA 54
PROCEDURE SUSPENSION OF WORK
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to suspension
of progress of the Works or part of it.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC.
ACTIONS REQUIRED
1. The Engineer shall only instruct the Contractor to suspend progress of part or all of
the Works, when it is absolutely necessary. If the suspension is caused due to a
reason for which the Contractor is responsible and the cause is notified to the
Contractor, he will not be entitled to any extension of time or additional payment due
to such suspension. The Contractor is required to protect, store and secure such part
or the Works against any deterioration, loss or damage during such suspensions.
2. When the instruction for suspension is given due to a fault of the Contractor, the
Engineer shall ensure that the Contractor is notified of the cause of the suspension.
3. The Engineer shall ensure that the Contractor protect, stores and secures such part
or the Works against any deterioration, loss or damage during suspensions.
4. If the instruction for suspension is given due to a cause for which, the Engineer
and/or the Employer are/is responsible, the Engineer shall take every attempt to
remove or mitigate such cause jointly with the Employer, in order to resume the
works as early as possible.
5. If a suspension affects the work on Plant or delivery of Plant and/or Materials for
more than 28 days, the Contractor shall be entitled to payment of the value (as at the
date of suspension) of Plant and/or Materials which have not been delivered to Site,
if the Contractor has marked the Plant and/or Materials as the Employer’s property in
accordance with the Engineer’s instructions
6. The Engineer and/or the Employer shall take every endeavour to avoid prolongation
of suspensions over 84 days as that would entitle the Contractor to omit the affected
part of the Works if the suspension affects only a part of the Works or terminate the
Contract, if the suspension affects the whole of the Works.
7. Upon the cessation of the cause for suspension, the Engineer shall give his
permission/instruction to proceed.
8. The Engineer and the Contractor shall carry out a joint inspection to identify any
deterioration or defect in or loss of the Works or Plant or Materials, which has
occurred during the suspension. The Engineer shall issue an instruction for a
variation to the Contractor to rectify the Works, Plant and Materials, affected by the
suspension.
143
9. If the instruction for suspension is given due to a fault of the Contractor, he should
bear the costs of any consequences and otherwise costs shall be paid to the
Contractor and the Time for Completion shall be extended under the claims
procedure.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 8.8 [Suspension of Work]
Sub-Clause 8.9 [Consequences of Suspension]
Sub-Clause 8.10 [Payment for Plant and Materials in Event of Suspension]
Sub-Clause 8.11 [Prolonged Suspension]
Sub-Clause 8.12 [Resumption of Work]
ATTACHMENTS
Specimen Letters
SL/CA 54/ 01 – Instruction to Suspend Works
144
PROCEDURE NO. CA 55
PROCEDURE CERTIFICATION OF INTERIM AND FINAL PAYMENT
TITLE CERTIFICATES
REVISION NO. A REVISION DATE 24th September
2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to certification
of interim and final payment certificates
APPLICABILITY
This procedure is applicable to any contract awarded or to be awarded by the Public Entity.
ACTIONS REQUIRED
2. When the measurements are from records, the Contractor’s agreement to such records
shall be sought and if the Contractor disagrees with such records and notify the Engineer
of such disagreement with particulars of any inaccuracies in the records, the Engineer
shall vary or confirm such records upon reviewing the records in the light of any
comments given by the Contractor.
3. The Engineer shall ensure that the measured works are complying with the contractual
requirements and he may request further particulars from the Contractor, such as test
certificates/reports and records of measurements carried out by the Contractor.
4. The Engineer shall ensure that the Contractor submits, a proposed breakdown of each
lump sum price in the Schedules, within 28 days after the Commencement Date. The
Engineer may take account of the breakdown when certifying interim payments.
5. The Engineer shall agree or determine the estimated contract value of the Works
executed by evaluating each item of work, based on the measured quantity and the
appropriate rate applicable to that item of work. However, when the Contract Price
constitutes of a lump sum with a schedule of payments specifying the instalments to be
paid, such instalments stated in the schedule of payments shall be the estimated
contract value.
6. The Engineer shall review the Contractor’s Application for Interim Payment Certificates
and agree or determine estimated contract value of the Works executed and the
Contractor’s Documents produced including Variations, up to the end of the month.
7. The Engineer shall review the Contractor’s Application for Interim Payment Certificates
and agree or determine any amounts to be added and/or deducted for changes in
legislation and changes in cost.
145
8. The Engineer shall determine any amounts to be deducted as retention money within
the limit specified in the Contract or any amounts to be released as retention money
upon handing over of the works or expiry of the Defect Notification Period.
9. The Engineer shall determine any amount to be paid as advance payment or any
amount to be deducted as repayment of the advance payment as specified in the
Contract.
10. The Engineer shall determine any amounts to be added and deducted for Plant and
Materials in accordance with the Contract.
11. The Engineer shall determine any amounts to be added or deducted due to a claim
under the Contract or otherwise, due to a decision of the DB/DAB, due to an amicable
settlement or an arbitration award.
12. The Engineer shall certify all above amounts as appropriate upon deduction of amounts
certified in all previous Payment Certificates, within 28 days after the Engineer receives
the Statement and supporting documents.
13. The Employer’s Representative shall ensure that amounts certified by the Engineer as
interim payments are paid to the Contractor within 56 days after the Engineer receives
the Statement and supporting documents.
15. The Engineer shall ensure that the Contractor submits, to the Engineer, a draft final
statement with supporting documents within 56 days after the Contractor receiving the
Performance Certificate. Contractor’s draft final statement should include the value of all
work done in accordance with the Contract and any further sums (under Contractor’s
Claims) which the Contractor considers to be due to him under the Contract or under the
law governing the Contract.
16. The Engineer shall review the draft final statement to verify the accuracy of
measurements of the works executed, which may require the Engineer either to take
actual on site measurements or use records available. The Engineer shall also review
amounts claimed by the Contractor for entitlement and accuracy of the quantum.
17. If the Engineer needs further information to verify the Contractor’s draft final statement,
he should request the Contractor to submit such information within 28 days from receipt
of said draft final statement.
18. The Engineer, upon consultation with the Employer and the Contractor, agree to
changes required to make the Contractor’s draft final statement, acceptable to him.
19. When the Contractor submits its Final Statement incorporating changes agreed with the
Engineer to the Contractor’s draft final statement, the Engineer shall review it to ensure
that it is prepared as agreed with him.
20. The Engineer shall issue the Final Payment Certificate to the Employer and the
Contractor within 28 days after receiving the Final Statement and discharge in
accordance with the terms of the Contract.
146
21. If the Contractor fails to submit the Contractor’s draft final statement, Final Statement
and/or discharge, the Engineer shall request the Contractor to do so. If the Contractor
further fails to submit such documents within a period of 28 days, the Engineer shall
issue the Final Payment Certificate for such amount as he fairly determines to be due to
the Contractor.
22. The Employer’s Representative shall ensure that amounts certified by the Engineer in
the Final Payment Certificate are paid to the Contractor within 56 days after the
Employer receives this Payment Certificate.
REFERENCES
Procurement Guidelines
Sub Section 8.12.1 (a)
ATTACHMENTS
Specimen Formats
147
PROCEDURE NO. CA 55 A
PROCEDURE DETERMINATION OF ESTIMATED CONTRACT VALUE
TITLE
REVISION NO. A REVISION DATE 4th October 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
determination of estimated contract value of Works which is required for certification of
interim and final payment certificates
APPLICABILITY
This procedure is applicable to any contract awarded or to be awarded by the Public Entity.
ACTIONS REQUIRED
1. When determining contract value of each Measure and Pay BOQ item, the Engineer shall
measure the works executed up to the end of the month for which the interim payment is
to be certified, either taking actual on site measurements or from records.
2. The Engineer shall determine the estimated contract value of the Works executed by
evaluating each item of work, based on the measured quantity and the appropriate rate
applicable to that item of work in the BOQ.
3. When determining contract value of each Lump Sum item, the Engineer shall evaluate
the contract value of such items, considering the time involved in completing such items.
When evaluating a Lump Sum item such as for purchasing vehicles for the
Employer/Engineer, the whole Lump Sum shall be taken as the contract value upon
handing over of such vehicles to the Employer.
4. When evaluating a Lump Sum item such as providing certain services to the Engineer
which would continue during a period of time, contract value shall be determine based
on a monthly rate calculated using the Lump Sum amount and the period of time the
service is envisaged to be provided.
5. When determining contract value of Provisional Sum items, procedure described in the
Procedure No. CA 47 shall be followed.
6. When the Contract Price constitutes of a lump sum with a schedule of payments
specifying the instalments to be paid, such instalments stated in the schedule of
payments shall be the estimated contract value.
7. The Engineer shall ensure that the Contractor submits, a proposed breakdown of each
lump sum price in the Schedules, within 28 days after the Commencement Date.
148
8. The Engineer may take in to account of the breakdown of each lump sum price in the
Schedules submitted by the Contractor when determining contract value of Lump Sum
contracts.
REFERENCES
Procurement Guidelines
Sub Section 8.12.1 (a)
ATTACHMENTS
Please refer to the Specimen Format SF/CA 55/ 01 – Format for Interim Payment Certificate
149
PROCEDURE NO. CA 56
PROCEDURE ENGINEER’S DETERMINATIONS
TITLE
REVISION NO. A REVISION DATE 24th September
2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to Engineer’s
Determinations.
APPLICABILITY
This procedure is applicable to any contract awarded or to be awarded by the Public Entity.
ACTIONS REQUIRED
1. The Engineer, unless otherwise agreed by both Parties, should not delegate his authority
to his assistants to make determinations on any matter for which such authority is
provided to him within the terms of the Contract.
2. When the Contract requires the Engineer to agree or determine any matter, he should
first consult each party and attempt to reach agreement, failing which he should make a
fair determination, taking in to account all relevant information available.
3. The Engineer shall notify both Parties of any agreement reached or any determination
made, with supporting particulars, within 28 days from the receipt of the corresponding
claim or request unless otherwise specified in the Contract.
a. An extension of time for any delay suffered by the Contractor due to an event for
which the Employer is responsible or due to a neutral event for which neither party is
responsible;
b. For payment of additional amounts for any costs incurred by or any damages
suffered by the Contractor due to an event for which the Employer is responsible.
b. Payment of amounts for which the Employer is entitled from the Contractor.
a. Reduction in Contract Price for failure to pass repeated Tests on Completion when a
Taking-Over Certificate is issued on the Employer request;
150
c. A reasonable reduction in Contract Price If the Contractor fails to remedy any defect
or damage by the date notified by the Employer and such remedial work is to be
executed at the cost of the Contractor.
d. The Contract Price by evaluating each item of work at the end of each month.
e. A fee to the Contractor for design changes involved in a proposal for Value
Engineering when such design changes results in a reduction in the contract value of
the relevant part of the Works.
g. Value of the Works, Goods and Contractor’s documents, and any other sums due to
the Contractor at the date of termination.
h. New rates or prices when relevant works are instructed as variations and no
appropriate rates or prices are specified in the Contract for such works or measured
quantity of any item is changed by more than 25% from quantity of this item in the Bill
of Quantities or other Schedule.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 3.2 [Delegation by the Engineer]
Sub-Clause 3.5 [Determinations]
ATTACHMENTS
Specimen Letters
151
PROCEDURE NO. CA 57
PROCEDURE
DEDUCTION AND RELEASE OF RETENTION MONEY
TITLE
REVISION NO. A REVISION DATE 25th September
2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to deduction
and release of Retention Money.
APPLICABILITY
This procedure is applicable to any contract awarded or to be awarded by a Public Entity.
ACTIONS REQUIRED
1. The Engineer should deduct Retention Money from each Interim Payment Certificate at
the percentage given in the Appendix to the Bid or Contract Data
2. The Engineer shall ensure that amount of Retention Money withheld should not exceed
the limit for Retention Money stated in the Appendix to the Bid or Contract Data.
3. The Engineer shall certify payment of half of the Retention Money withheld to the
Contractor when the Taking-Over Certificate is issued for the Works. If the Taking-Over
Certificate is issued only for a Section or part of the Works, the Engineer shall only certify
payment of a proportion of half of the Retention Money, calculated using the ratio
between the estimated contract value of the Section/part and estimated final Contract
Price.
4. The Engineer shall certify payment of the second half of the Retention Money withheld to
the Contractor after the latest of the expiry dates of the Defects Notification Periods. If a
Taking-Over Certificate is issued for a Section, a proportion of the second half of the
Retention Money shall be certified and paid after the expiry date of the Defects
Notification Period for that Section and the proportion shall be calculated using the ratio
between the estimated contract value of the Section/part and estimated final Contract
Price.
5. When any remedial works are remaining uncompleted, the Engineer shall withhold
certification of the estimated cost of such work until it is executed.
6. The Engineer is required to release the second half of the Retention Money, if the
Contractor submits a valid Retention Money Guarantee for the value of the Retention
Money withheld. The Retention Money Guarantee shall be of similar conditions that are
specified for the Performance Security.
REFERENCES
Procurement Guide
Sub Section 5.4.6 of Supplement – 18 which superseded original content
152
FIDIC Conditions of Contract MDB 2010
Sub-Clause 14.3 [Application for Interim Payment Certificates]
Sub-Clause 14.9 [Payment of Retention Money]
ATTACHMENTS
Please refer to the Specimen Format SF/CA 55/ 01 – Format for Interim Payment Certificate
153
PROCEDURE NO. CA 58
PROCEDURE DAY WORK
TITLE
REVISION NO. A REVISION DATE 25th September
2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to execution
of works on day work basis.
APPLICABILITY
This procedure is applicable to any contract awarded or to be awarded by a Public Entity.
ACTIONS REQUIRED
1. The Engineer shall ensure that day work basis is only used for works of minor or
incidental nature which are instructed as variations.
2. The Engineer shall ensure that the Contractor submits quotation for purchase of materials
and hiring of equipment and temporary works, prior to making orders for the same.
3. The Engineer shall ensure that the Contractor submits day work records for each day on
the following day and such records shall include:
4. The Engineer shall review the day work records submitted by the Contractor and he shall
sign them if they are correct or acceptable.
5. The Engineer shall ensure that the Contractor submits priced statement for day works
prior to include such amounts in the Monthly Statement.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 13.6 [Day work]
ATTACHMENTS
Specimen Formats
SF/CA 58/ 01 – Format for Day work Order
SF/CA 58/ 02 – Format for Day work Records
154
Part Three
COMPLETION STAGE
155
CONTENT OF PROCEDURES - COMPLETION STAGE
156
Procedures CA 59 to CA 66
PROCEDURE NO. CA59
PROCEDURE Termination of Contract
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers terminating a contract by the Employer due to default of a
Contractor or for the convenience of the Employer.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
2. The Project Director/ Project Manager shall confirm through a thorough review that an
event or circumstance, occurrence of which is stated in the Contract (Sub-Clause 15.2
[Termination by Employer] in FIDIC Red Book and Pink Book and ICTAD SBD/02) as
would entitled the Employer for termination of the Contract, has occurred.
3. The Project Director/ Project Manager shall issue the Notice of Termination with the
signature of the proper authority, giving 14 days notice to the Contractor. In the event of
termination due to the Contractor’s bankruptcy/insolvency or the Contractor having
given/offered bribes/gifts/commissions as an inducement or reward, a contract can be
terminated immediately.
4. The Project Director/ Project Manager shall expel the contractor from the site and
ensure that the Contractor leaves the Site and delivers any required goods, all
Contractor’s Documents, and other design documents made by or for him, to the
Engineer.
5. The Project Director/ Project Manager shall ensure that the Contractor complies
immediately with any instructions included in the termination notice for the assignment
of any subcontract, and for any action required to protect life and/or property and for the
safety of the Works.
6. Project Director/ Project Manager shall take over any materials/plants at site, which are
required for the completion of the Works, only upon a thorough inspection to ensure
their quality and a count to determine the exact quantity available.
157
7. Project Director/ Project Manager may retain and use any of the Contractor’s Equipment
and/or temporary works for the completion of the Works and upon completion of the
Works such equipment and temporary works shall be released to the Contractor after
notifying him.
8. The Project Director/ Project Manager shall verify whether the Contractor has fulfilled his
obligation towards third parties in repairing /compensating any third party damages. The
Project Director/ Project Manager may take suitable action to redress the affected
parties through the insurance provider or through other means. He should consider
informing such parties of the situation.
9. The Project Director/ Project Manager shall inform utility agencies and other authorities
such as RDA and Inland Revenue Department of the termination to enable them to
recover any amounts due from the Contractor.
10. The Engineer shall agree to or determine the value of the Works, Goods and
Contractor’s Documents, and any other sums due to the Contractor for works executed
in accordance with the Contract at the time of termination.
12. Project Director/ Project Manager shall raise Employer’s Claims for above amounts
which are to be recovered from the Contractor.
13. Project Director/ Project Manager shall pay any balance to the Contractor after
recovering any such losses, damages and extra costs from any amount due to the
Contractor under Valuation at Date of Termination.
14. If any amount due to the Contractor is not sufficient to recover all amounts due from the
Contractor, the Project Director/ Project Manager shall take action to demand the
amounts guaranteed under the Performance Security and Retention Money Guarantee
(if any).
158
16. Project Director/ Project Manager assess the situation and if he is of the opinion that
termination is beneficial to the Employer, he shall seek approval of the relevant authority
and the funding agency upon providing all information relevant to the Contract, including
his reasoned recommendation.
17. The Project Director/ Project Manager shall ensure that contract is terminated only upon
obtaining approval of the relevant authority and consent of the funding agency. The
Project Director/ Project Manager may obtain considered legal opinion of the Attorney
General’s Department if necessary.
18. The Project Director/ Project Manager shall issue the Notice of Termination with the
signature of the proper authority, giving 14 days notice to the Contractor.
19. The Project Director/ Project Manager shall return the Performance Security to the
Contractor, if there are no amounts to be recovered from the Contractor.
20. The Termination of the Contract will be effective after 28 days of the receipt of the notice
of termination by the Contractor or Employer returning the Performance Security to the
Contractor, whichever is later.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 15.2 [Termination by Employer]
Sub-Clause 15.3 [Valuation at Date of Termination]
Sub-Clause 15.4 [Payment after Termination]
Sub-Clause 15.5[Employer’s Entitlement to Termination for Convenience]
ATTACHMENTS
Specimen Letters
SL/CA 59/ 01 – Termination of the Contract
SL/CA 59/ 02 – Termination of the Contract for Employer’s Convenience
159
PROCEDURE NO. CA60
PROCEDURE Force Majeure
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out subsequent to a Force
Majeure event.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/ Project Manager shall ensure that each exceptional event or
circumstance is carefully reviewed to determine whether it constitutes a Force Majeure
event as defined in the Sub-Clause 19.1 of the General Conditions of Contract, which is
beyond the control of both parties to a Contract.
2. If such exceptional event or circumstance is a Force Majeure event, the Project Director/
Project Manager shall assess the potential consequences of such Force Majeure event
to decide upon the actions to be taken.
3. If the Force Majeure event prevents the Employer or the Engineer from performance of
its obligations under the Contract, the Project Director/ Project Manager shall notify the
Contractor of such event specifying the obligations, the performance of which is or will be
prevented, within 14 days after he became aware of such event.
4. The Project Director/ Project Manager shall notify the Contractor when the Force
Majeure event ceases and no it longer affects the performance of any contractual
obligation by the Employer or the Engineer.
5. If a Force Majeure event prevents a Contractor from performance of its obligations under
the Contract, within 14 days after he became aware of such event he should notify the
Employer of such event specifying the obligations, the performance of which is or will be
prevented.
6. The Project Director/Project Manager shall ensure that all contemporary records
pertaining to any delays suffered and any additional costs incurred by the Contractor are
maintained.
7. The Project Director/Project Manager shall ensure that if the Contractor suffers delay
and/or incurs Cost by reason of such Force Majeure event, the Contractor is given an
extension of time for completion and he is paid all costs incurred including costs incurred
in repairing/replacing any part of the Works, Plants, Materials, Contractor’s Equipment,
Plant and/or Temporary Works damaged and/or destroyed by Force Majeure event,
except any amount received through insurance policies.
160
8. If the execution of substantially all the Works in progress is prevented for a continuous
period of 84 days or for multiple periods which total more than 140 days due to a notified
Force Majeure event, making either Party entitled for termination of the Contract upon
giving a notice of termination, the Project Director/ Project Manager shall assess the
situation and take a decision in consultation with the higher management of the
organization, line ministry and the Attorney General’s Department on whether to
terminate the Contract.
9. If the Contract is terminated by either party due to a Force Majeure event, such
termination is effective upon 7 days of giving a notice of termination and the Project
Director/Project Manager shall ensure that the Contractor:
a. Ceases all further work and hand over all completed works.
b. Hand over all Contractor’s Documents, Plant and Materials for which the
Contractor has received payment.
c. Remove all Temporary Works and Contractor’s Equipment from the Site.
10. If the Contract is terminated by either party due to a Force Majeure event, the Engineer
shall determine the value of the work done and issue a Payment Certificate which shall
include:
11. In this event, the termination shall take effect 7 days after the notice is given, and the
Contractor shall proceed in accordance.
12. The Project Director/Project Manager shall ensure that the Contractor is discharged
from further performance of the Contract.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 19.1 [Definition of Force Majeure]
Sub-Clause 19.2 [Notice of Force Majeure]
Sub-Clause 19.3 [Duty to Minimize Delay]
Sub-Clause 19.4 [Consequences of Force Majeure]
Sub-Clause 19.6 [Optional Termination, Payment and Release]
Sub-Clause 19.7 [Release from Performance]
ATTACHMENTS
Specimen Letters
SL/CA 60/ 01 – Termination of the Contract Subsequent to Force Majeure
SL/CA 60/ 02 – Notice to Release from Performance
161
PROCEDURE NO. CA 61
PROCEDURE TAKING OVER OF WORKS
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to taking over
of the Works, Sections or part of it.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC.
ACTIONS REQUIRED
1. Unless it is absolutely necessary, the Employer should not use any part of the works
until such part is substantially completed, as in such an event it is deemed to be taken
over by the Employer.48
2. Upon receiving a notice/application from the Contractor to take over of the Works or
Section, the Engineer and the Employer shall verify whether the Works or the Section
for which a Taking-Over certificate is applied, are substantially completed except for
some minor outstanding works and defects49 which will not substantially affect the use of
the Works or Section for their intended purpose.
3. The Engineer upon reviewing the completion status of the Works or Section shall
arrange a joint inspection of the Works or Section for which the Contractor has applied
for a Taking-Over Certificate, with the Employer and the Contractor.
4. During the joint inspection, a defect list (schedule of defects, punch list or snagging list)
shall be prepared to include all outstanding works, defects and damages
observed/identified.
5. The Engineer upon reviewing the completion status of the Works or Section, within 28
days upon receiving the Contractor’s notice, shall either:
a. Issue a Taking-Over Certificate for whole of the Works or Section, to the Contractor,
stating the date on which the Works or Section were completed in accordance with
the Contract, if the Works or Section have been substantially completed; or
48
Any major form of contract requires the Employer to take over the Works or Section, upon:
(a) whole of the Works or Section have been completed in accordance with the Contract,
(b) achieving the passing of the Tests on Completion and
(c) Taking-Over Certificate for the Works or Section has been issued, or is deemed to have been issued in accordance with
the Contract by the Engineer.
49
The Contractor is entitled for payment of Cost incurred plus profit, If the Contractor incurs Cost as a result of the Employer
taking over and/or using a part of the Works, other than such use as is specified in the Contract or agreed by the Contractor,
subject to Contractor giving notice to the Engineer under Sub-Clause 20.1 [Contractor’s Claims].
162
b. reject the application, giving reasons and specifying the work required to be done by
the Contractor to enable the Taking-Over Certificate to be issued, if substantial
amount of works are required to be done by the Contractor to enable the Taking-Over
Certificate to be issued.
6. The Engineer shall ensure that a response, either issuing a Taking-Over certificate or
rejecting issuing of the same, is issued within 28 days upon receiving the Contractor’s
notice/application to avoid a situation of a Taking-Over certificate deemed to be issued
due to such failure.
7. The Engineer may issue a Taking-Over Certificate for any part of the Permanent Works,
upon obtaining prior approval of the Employer.
8. The Engineer shall issue a Taking-Over Certificate for any part of the Permanent Works,
which the Employer has used before a Taking-Over Certificate is issued. That part shall
be deemed to have been taken over as from the date on which it is used.
9. The Engineer shall issue a Taking-Over Certificate for the Works or Section, if the
Contractor is prevented from carrying out the Tests on Completion for more than 14
days, by a cause for which the Employer is responsible. The Works or Section deemed
to have taken over on the date when the Tests on Completion would otherwise have
been completed.
REFERENCES
Sub-Clause 10.1 [Taking Over of the Works and Sections]
Sub-Clause 10.2 [Taking Over of Parts of the Works]
Sub-Clause 10.3 [Interference with Tests on Completion]
Sub-Clause 10.4 [Surfaces Requiring Reinstatement]
ATTACHMENTS
Specimen Letters
SL/CA 61/ 01 – Rejection of Application for Taking-over Certificate
SL/CA 61/ 02 – Taking-over Certificate for the Works/Section
163
PROCEDURE NO. CA62
SCOPE
Scope of this procedure covers activities required to be carried out for the preparation of “As-
Built” drawings.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Engineer shall ensure that his staff maintains a dedicated set of drawings on which
notes of as constructed changes to the drawings identified by taking actual
measurements of completed works are progressively recorded.
2. The Engineer shall ensure that the Contractor is regularly keeping accurate, properly
marked-up as-built drawings.
3. The Engineer shall ensure that As-Built drawings prepared by the Contractor represent
as constructed information of the Works such as positions, dimensions and levels by
reviewing them against information available.
4. Before issuing a Taking-Over Certificate, the Engineer shall ensure that the Contractor
submits all As-Built drawings as required.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 4.1 [Contractor’s General Obligations] Item (d)
ATTACHMENTS
Specimen Formats
SF/CA 62/ 01 – Format for As-Built Drawing Register
164
PROCEDURE NO. CA 63
SCOPE
Scope of this procedure covers activities required to be carried out during the Defects
Notification Period.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC.
ACTIONS REQUIRED
1. The Employer and the Engineer shall agree with the Contractor for a schedule for
completion of any works outstanding at the time of issuing the Taking-Over
Certificate and remedying of any defects or damages identified before the issuing of
the Taking-Over Certificate, which are included in the defect list (punch list).
2. The Employer and the Engineer, during the Defect Notification Period, shall monitor
the execution of works which are outstanding at the time of issuing the Taking-Over
Certificate and remedying of any defects or damages.
3. The Employer and the Engineer, during the Defect Notification Period, shall arrange
regular inspections to identify any defects or damages and such defects or damages
shall be entered in to the “List of Defects subsequent to TOC” together with any other
defects or damages identified by other stake holders who are using or operating the
Works/Section.
4. The Employer and the Engineer shall notify the Contractor of any defects or
damages identified during the Defect Notification Period.
5. The Engineer shall instruct the Contractor to search for the cause of any defect, if
necessary, using an appropriate method such as site investigation and/or testing.
Cost of such search shall be at the cost of the Contractor if the cause of such defect
is attributable to the Contractor.
6. The Employer and the Engineer, during the Defect Notification Period, shall also
monitor remedying of any defects or damages identified after the issuing of the
Taking-Over Certificate, which are notified to the Contractor by the Employer or the
Engineer.
7. The Engineer shall recover the cost of remedying of any defects and damages which
are at the risk and cost of the Contractor, when the cause of such defects and
165
damages are attributable to the Contractor, through following the Employer’s Claim
process.
8. The Engineer shall instruct a variation for remedying of any defects or damages,
causes of which are not attributable to the Contractor.
9. If the Contractor fails to remedy any defect or damage within a reasonable time
agreed with the Engineer and the Employer, the Employer shall notify the Contractor
of a date by which the defect or damage is to be remedied.
10. If the Contractor fails to remedy the defect or damage by the notified date and this
remedial work was to be executed at the cost of the Contractor as the cause of such
defect is attributable to the Contractor, the Employer shall either:
a. Carry out the work himself or by others and recover the costs reasonably incurred
by him.
c. Terminate the Contract as a whole, or in respect of such major part which cannot
be put to the intended use due to the defect or damage.
11. Upon requested by the Contractor, the Employer may give his consent to remove
items of Plant from the Site for the purposes of repair, if such defect or damage
cannot be remedied expeditiously on the Site, subject to the Contractor providing an
appropriate security for the full replacement cost of these items, such as increasing
the amount of the Performance Security.
12. The Engineer shall extend the Defects Notification Period for the Works or a Section,
if the Works, Section or a major item of Plant cannot be used for the purposes for
which they are intended by reason of a defect or damage attributable to the
Contractor, subject to the Employer/ Engineer giving a notice for a Employer’s Claim
prior to the expiration of the Defects Notification Period. However the Engineer shall
not extend a Defects Notification Period by more than two years.
13. The Engineer shall arrange for a review of the Contractor’s Documents and a joint
inspection of the Works or Section, with the Employer and the Contractor to ensure
that the Works and Contractor’s Documents, and each Section, shall be in the
condition required by the Contract (fair wear and tear excepted) by the expiry date of
the relevant Defects Notification Period.
14. The Engineer shall issue the Performance Certificate to the Contractor with a copy to
the Employer within 28 days after the latest of the expiry dates of the Defects
Notification Periods, unless the Contractor fails to submit all the Contractor’s
Documents and complete and test all the Works, including remedying any defects
and damages, in accordance with the Contract.
166
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 11.1 [Completion of Outstanding Work and Remedying Defects]
Sub-Clause 11.2 [Cost of Remedying Defects]
Sub-Clause 11.3 [Extension of Defects Notification Period]
Sub-Clause 11.4 [Failure to Remedy Defects]
ATTACHMENTS
Specimen Formats
SL/CA 63/ 01 – Notification of Defects during Defect Notification Period
167
PROCEDURE NO. CA64
SCOPE
Scope of this procedure covers activities required to be carried out with regard to issuing of
the Performance Certificate which is considered as the completion of the Contractor’s
obligations to perform under the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
2. The Engineer shall issue the Performance Certificate to the Contractor within 28 days
after the latest of the expiry dates of the Defects Notification Periods, with a copy to
the Employer, stating the date on which the Contractor completes his obligations
under the Contract.
3. The Employer shall ensure that the Contractor removes any remaining Contractor’s
Equipment, surplus material, wreckage, rubbish and Temporary Works from the Site
within 28 days after receipt by the Contractor of the Performance Certificate.
4. The Employer shall return the Performance Security to the Contractor within 21 days
after receiving a copy of the Performance Certificate.
5. The Employer shall ensure that if the Contractor fails to remove any remaining items
after 28 days of receipt by the Contractor of the Performance Certificate, the
Employer may sell or otherwise dispose of such items remaining in the site.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 11.9 [Performance Certificate]
ATTACHMENTS
Specimen Letters
SL/CA 64/ 01 – Performance Certificate
168
PROCEDURE NO. CA 65
PROCEDURE CLOSE OUT OF THE CONTRACT
TITLE
REVISION NO. B REVISION 9th September 2015
DATE
SCOPE
Scope of this procedure covers activities required to be carried out with regard to closing out
of the Contract.
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that the Contractor commences
closing out of the Contract and complete removing of any remaining Contractor’s
Equipment, surplus material, wreckage, rubbish and Temporary Works from the Site,
clears the Site, within 28 days upon receiving the Performance Certificate.
2. The Project Director/Project Manager shall ensure that the Contractor submits to the
Engineer, a draft final statement with supporting documents showing in detail, the value
of all work done in accordance with the Contract, and any further sums which the
Contractor considers to be due to him under the Contract or otherwise within 56 days
after receiving the Performance Certificate.
3. The Engineer shall take every endeavour to reach an agreement with the Contractor to
finalize the Final Statement of the Contractor in order to issue the Final Payment
Certificate.
4. The Engineer, before issuing the Final Payment Certificate, shall obtain a discharge
from the Contractor and such discharge should confirm that the total of the Final
Statement represents full and final settlement of all moneys due to the Contractor under
or in connection with the Contract
5. The Project Director/Project Manager and the Engineer shall make arrangements to
wind up the project and following activities shall be carried out:
a. Packing and labelling of all project documents and handing over them to a person
nominated by the Management.
b. Backing up of all information in the Server and the computer network.
c. Handing over of all buildings, furniture and equipments to persons nominated by the
Management.
d. Transfer or terminate all staff involved in the project as directed by the Management.
e. Drafting of the Final Completion Report.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 11.11 [Clearance of Site]
Sub-Clause 14.11 [Application for Final Payment Certificate]
Sub-Clause 14.12 [Discharge]
ATTACHMENTS
Checklists
CL/CA 65/ 01 – Checklist for Closing out of the Contract
169
PROCEDURE NO. CA 66
PROCEDURE HANDING OVER OF COMPLETED WORKS AND
TITLE DOCUMENTS/INFORMATION INCLUDING AS BUILT
INFORMATION TO THE OPERATION/MAINTENANCE TEAM
REVISION NO. B REVISION 9th September 2015
DATE
SCOPE
Scope of this procedure covers activities required to be carried out with regard to handing
over of completed works and documents/information including as built information to the
operation/maintenance team
APPLICABILITY
This procedure is applicable to any contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD.
ACTIONS REQUIRED
1. The Project Director/Project Manager shall ensure that a representative of the Operation
and Maintenance team participates in the taking over of the Works from the Contractor
including the joint inspection.
2. The Project Director/Project Manager shall arrange back to back handing over of the
Works to the Operation and Maintenance team on the same day.
3. The Project Director/Project Manager shall ensure that following items are handed over
to the representatives of the Operation and Maintenance team, in addition to the Works:
a. As-built documents
b. Operation and Maintenance Guides (if applicable)
c. Spare parts, spare materials and certain consumables
d. Tools and accessories
e. Inspection and test equipments
f. Warranties for equipment
g. Catalogues for equipment
h. Keys including master keys
i. Documents relating to utility accounts
j. Contact information of the Contractor, sub contractors and equipment suppliers
k. Licenses issued by authorities
l. Computer storage media containing software
REFERENCES
None
ATTACHMENTS
Checklists
CL/CA 66/ 01 – Checklist for Items to be Handed Over to O&M Division
170
Part Four
DISPUTE RESOLUTION
171
CONTENT OF PROCEDURES – DISPUTE RESOLUTION
172
Procedures CA 67- CA 69
PROCEDURE NO. CA 67
PROCEDURE Adjudication
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to
establishment and functioning of Dispute Boards/Dispute Adjudication Boards (DB/DAB)
including referring a dispute to the DB/DAB for decision as well as defending the position of
the Employer in a dispute referred to DB/DAB by a Contractor.
APPLICABILITY
This procedure is applicable to any Contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD
General Principles
Disputes may arise due to a variety of reasons under a Contract. FIDIC or ICTAD conditions
of Contracts provide a multi-tiered dispute resolution scheme with escalating severity for
resolving disputes arising out of and in connection with a Contract. Adjudication is the first
attempt in resolving a dispute through such multi-tiered dispute resolution scheme.
Adjudication is a quick and relatively inexpensive way of resolving disputes in construction
Contracts. For the purpose of resolving such disputes expeditiously, Contracts require
appointment of Dispute Boards/Dispute Adjudication Boards. Usually Dispute
Boards/Dispute Adjudication Boards, which should be establish at the commencement of the
Contract in accordance with the terms of the Contract, consist of either a sole adjudicator or
a panel of three adjudicators with one of them acting as the chairman. Mandate of the
Dispute Boards/Dispute Adjudication Boards under FIDIC, includes not only resolution of
disputes but also providing advice to parties to prevent potential problems or claims from
becoming disputes.
The DB is an essential component in a Contract with the aim of assisting the Parties and the
Engineer to prevent disagreements from becoming formal Disputes. If a formal Dispute
cannot be avoided, the DB makes a Decision on the Dispute which is binding on both Parties
and the Engineer unless either party gives its notice of dissatisfaction regarding the decision
of the DB/DAB.
ACTIONS REQUIRED
2. Upon establishment of the DB/DAB, the Chief Engineer shall coordinate with the
Resident Engineer (Engineer’s Assistant) and the Contractor to arrange the signing of
tripartite DB/DAB agreement by AB/DAB members, representatives of the Employer and
the Contractor.
173
3. The Chief Engineer shall coordinate with the Resident Engineer (Engineer’s Assistant)
to arrange the preliminary meeting and the first site visit of the DB/DAB in consultation
with the Contractor.
4. The Project Director/Project Manager or his representative shall attend the preliminary
meeting and the site visit of the DB/DAB to discuss and agree to procedural
arrangements of the DB/DAB to ensure smooth functioning of the DB/DAB.
5. The Project Director/Project Manager or his representative shall ensure that reasonable
time periods are allocated for submission of various pleadings/submissions when
agreeing to a tentative time table for adjudication during the preliminary meeting.
6. The Chief Engineer shall ensure that Monthly Progress Reports are submitted to each
DB/DAB member regularly for DB/DAB members to get acquainted themselves with the
site activities and progress of the works.
7. The Chief Engineer shall ensure that each DB/DAB member is provided with a set of
copies of the Contract Documents.
8. The Chief Engineer shall take necessary action to prevent issues, problems or claims on
any matter relevant to the Contract, from becoming potential disputes by seeking
advice/opinion of the DB/DAB, jointly with the Contractor.
10. In case a dispute is to be referred to the DB/DAB on behalf of the Employer, the Project
Director/Project Manager shall ensure that a proper referral of the dispute is prepared
and submitted with a copy to the Contractor with adequate facts and evidence to
support the Employer’s position on the dispute. Drafting of the referral may require
specialist assistance from Head Office or from an external consultant depending on the
nature and type of the dispute and the Project Director/Project Manager shall decide the
extent of external support required.
11. The Project Director/Project Manager shall ensure that a competent group of staff with
adequate knowledge of issues at dispute participate in the DB/DAB hearing to defend
the position of the Employer.
12. The Chief Engineer shall ensure that any information requested by the DB/DAB are
promptly submitted to the DB/DAB with a copy to the Contractor.
13. If further submissions are allowed, the Project Director / Project Manager shall ensure
that a proper submission to challenge/contest/counter any allegations
/arguments/assertions raised by the Contractor subsequent to his referral of the dispute
174
to DB/DAB, is submitted to the DB/DAB with a copy to the Contractor within the time
allowed.
14. When DB/DAB give its decision on the dispute, the Project Director/Project Manager
shall ensure that said decision is thoroughly reviewed by a competent panel of persons
and give their opinion on the reasonability and acceptability of such decision.
15. If the Project Director/Project Manager is of the view that the DB/DAB’s decision is
reasonable and acceptable, he shall forward his recommendation to Head of Entity
seeking his approval to give effect to the DB/DAB’s decision.
16. The Project Director/Project Manager shall ensure that the DB/DAB’s decision is
honoured upon obtaining Head of Entity’s approval.
17. If the Project Director/Project Manager is of the view that the DB/DAB’s decision is
unreasonable and/or unacceptable, he shall forthwith send a Notice of Dissatisfaction to
the Contractor within 28 days and seek the Head of Entity’s advice on giving effect to
the DB/DAB’s decision.
18. Notice of Dissatisfaction shall state that it is given under the Sub-Clause 20.4, and shall
set out the matter in dispute and the reason(s) for dissatisfaction.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 20.2 [Appointment of the Dispute Board]
Sub-Clause 20.4 [Obtaining Dispute Board’s Decision]
ATTACHMENTS
Specimen Letters
SF/CA 67/ 01 – Referral of a Dispute to the DB/DAB by the Employer
SF/CA 67/ 02 – Response to a Referral of a Dispute to the DB/DAB by the Contractor
SF/CA 67/ 03 – Notice of Dissatisfaction
175
PROCEDURE NO. CA 68
PROCEDURE Amicable Settlement
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to Amicable
Settlement when parties fail to resolve their dispute through adjudication by a DB/DAB.
Amicable Settlement is the second attempt in resolving a dispute through multi-tiered dispute
resolution scheme incorporated under FIDIC and ICTAD forms of Contract when
adjudication is not successful.
APPLCABILITY
This procedure is applicable to any Contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC (ICTAD based Conditions of Contract
do not have any provisions for Amicable Settlement.)
ACTIONS REQUIRED
1. When a decision of the DB/DAB is not acceptable to the Employer, the Project Director/
Project Manager shall seek approval of the Head of the Entity to initiate Amicable
Settlement upon giving Notice of Dissatisfaction.
2. The Project Director/ Project Manager shall make an assessment of the status of the
dispute in consultation with the AG’s Department and based on the above assessment
Head of Entity shall decide as to whether pursuing an amicable settlement is desirable.
4. Minister in charge of relevant subject shall appraise the Cabinet of Ministers to take an
appropriate decision based on information compiled by the Secretary to the relevant line
ministry.
5. Upon getting the approval from the Cabinet of Ministers, the Secretary of the line
ministry shall take action to form an Amicable Settlement Committee to conduct
negotiations for Amicable Settlement with the Contractor.
6. Relevant Authority shall appoint members of the Amicable Settlement Committee and
they should be given authority to negotiate with the Contractor on behalf of the
Employer.
176
7. Upon establishment of the Amicable Settlement Committee, the Chief Engineer shall
prepare a brief report on the dispute and submit it together with all relevant
documents/information including submissions to DB/DAB by both parties and the
DB/DAB decision.
8. Prior to commence negotiations with the Contractor the Amicable Settlement Committee
shall review/study all information available.
9. The Project Director/ Project Manager or Chief Engineer shall brief the Amicable
Settlement Committee on the dispute and make clarifications on any matter which is not
clear to the Amicable Settlement Committee.
10. The Amicable Settlement Committee shall negotiate with the Contractor and come to a
settlement considering the adverse implications of resorting to arbitration, but not much
compromising the Employers interests.
12. The Project Director/ Project Manager shall obtain approval of the Cabinet of Ministers,
the Secretary of the line ministry or the Head of Entity (as the case may be) for the
agreement reached by the Amicable Settlement Committee and the Contractor.
13. The Project Director/ Project Manager shall give effect to the agreement reached by the
Amicable Settlement Committee and the Contractor upon negotiations.
REFERENCES
FIDIC Conditions of Contract MDB 2010
Sub-Clause 20.5 [Amicable Settlement]
Other Regulations/Directives
Cabinet Paper No. 11/0811/504/072 on Settlement of Disputes in Relation to Contract
Management
ATTACHMENTS
Specimen Letters
SL/CA 68/ 01 – Letter to Attorney General Seeking His Opinion on the Matter in dispute
SL/CA 68/ 02 – Letter to Standing Cabinet Appointed Review Committee
Specimen Formats
SF/CA 68/ 01 – Format for Minutes of Amicable Settlement Committee Meeting
177
PROCEDURE NO. CA 69
PROCEDURE Arbitration
TITLE
REVISION NO. B REVISION DATE 9th September 2015
SCOPE
Scope of this procedure covers activities required to be carried out with regard to resolution
of disputes through arbitration. 50
APPLICABILITY
This procedure is applicable to any Contract to be awarded based on Construction or Plant
and Design-Built type Conditions of Contract by FIDIC or ICTAD
ACTIONS REQUIRED
1. Arbitration process is deemed to commence when one party receives a notice requiring
that party to refer, or to concur in the reference of, the dispute to arbitration; or a notice
requiring that party to appoint an arbitral tribunal or to join or concur in or approve the
appointment of, an arbitral tribunal in relation to the dispute.
2. When the Employer receives a notice from the Contractor as above, the Project
Director/Project Manager shall review provisions in the arbitration agreement, which is
embedded within the Conditions of Contract, to find out following information:
a. Place of Arbitration
b. Whether arbitration is Institutional or ad hoc
c. Rules of arbitration
d. Number of Arbitrators
e. Method of appointing Arbitrators
f. Language of arbitration
g. Law of arbitration
3. During the arbitration process, the party who initiated the arbitration is called as the
“Claimant” and the other party is called as the “Respondent”.
4. When the arbitration agreements stipulates the appointment of a sole arbitrator, the
Employer is required to agree to one of the candidates proposed by the Contractor or
propose names of several candidates to the Contractor, for selection of a sole arbitrator.
For this purpose, the Project Director/Project Manager shall short-list potential
candidates from sources such as lists maintained by CIDA, ICLP and Institution of
Engineers (IESL) and potential candidates shall possess adequate qualifications,
relevant work experience, experience in arbitration and sound knowledge of Contract
management. They also shall be independent, impartial and available. The Project
Director/Project Manager may seek advice of the Attorney General’s Department in
selecting candidates for arbitral tribunals.
50
Please refer Annex 2.
178
5. In the event of disagreement for proposed candidates, a party may request the
institution stated in the arbitration agreement to appoint such sole arbitrator or if there is
no such provision, parties may appoint a panel of three arbitrators, one each by the
parties and the third arbitrator who will be the chairman of the arbitral tribunal, by the
two arbitrators appointed by parties. When either party or the institution appointed to
nominate arbitrators fails to appoint an arbitrator/s within sixty days after receiving the
request, a party may request High Court to appoint arbitrator/s in accordance with
Section 7 of the Arbitration Act No.11.
6. Upon appointment of the arbitral tribunal, the Project Director/Project Manager shall
consult the Attorney General’s Department to form an arbitration team to defend the
interest of the Employer in the arbitration. The Project Director/Project Manager shall
assign several competent engineers who possess an in depth knowledge regarding the
issues at dispute, for the Arbitration Team. If the Project Director/Project Manager is of
the view that in house capabilities are not adequate he may engage external experts to
complement the composition of the Arbitration Team, subject to the approval of the GM.
7. The Project Director/Project Manager shall provide the Arbitration Team with required
resources such office space, filing racks, computers, printers, copiers and fax machines
8. The Arbitration Team shall collect whatever information available to use as evidence to
support the position of the Employer.
9. The Arbitration Team shall prepare for the preliminary procedural meeting within which
procedural arrangements including time frame for various activities are discussed and
agreed. The Arbitration Team shall request adequate time for submission of various
statements in response to submissions by the Contractor. The Project Director/Project
Manager and Team members shall participate in the preliminary procedural meeting
while state counsels from AG’s Department may appear on behalf of the Employer.
10. The Arbitration Team shall prepare admissions and issues in the arbitration and in
consultation with the Contractor’s team prepare a joint draft of admissions and issues
base on admissions and issues prepared individually by both parties.
11. The Arbitration Team shall participate in any other procedural hearings and take any
action directed by the tribunal through such hearings or procedural orders.
12. Upon submission of the Statement of Claim by the Contractor as the Claimant, the
Arbitration Team shall assist the AG’s Department to carefully review the Statement of
Claim and draft the Statement of Defence on behalf of the Employer as the Respondent.
13. The Statement of Defence shall be submitted to the Arbitral Tribunal within the agreed
time frame with copies to the Claimant and the Institution administering the arbitration.
14. Upon receiving the Statement of Reply from the Claimant in response to Statement of
Defence, the Arbitration Team shall assist the AG’s Department to carefully review the
Statement of Reply and check whether there are any new issues and/or arguments
included within it. If there are any new issues or/and arguments are included within the
Statement of Reply, a request shall be submit to the Arbitral Tribunal for an opportunity
179
to counter such new issues or/and arguments through a Rejoinder. If the Arbitral
Tribunal permits submission of a Rejoinder, the Arbitration Team shall assist the AG’s
Department to draft the Rejoinder.
15. The Rejoinder shall be submitted to the Arbitral Tribunal within the agreed time frame
with copies to the Claimant and the Institution administering the arbitration.
16. The parties shall assist the Arbitral Tribunal in preparing a list of supporting documents
involved in the arbitration under categories of admitted documents and disputed
documents. Either party may request other party for documents not available to them
but which are relevant to issues involved through discovery of documents.
17. The Arbitration Team shall identify potential witnesses of fact to support the
Respondent’s position and the Arbitration Team with the assistance of State Counsels
help such witnesses to prepare “Witness Statements”.
18. The Arbitration Team shall identify potential Expert Witnesses to support the
Respondent’s position and the Arbitration Team with the assistance of State Counsels
help such Experts to prepare “Expert Reports”.
19. The Arbitration Team, jointly with the Claimant, shall coordinate arrangements for the
arbitration hearing, including venue, facilities, documents involved, refreshments and
transcript writers.
20. The Arbitration Team shall assist State Counsels to prepare opening oral submission
and prepare for cross examination of Claimant’s witnesses of fact and expert witnesses
based on their witness statements/expert reports.
21. The Arbitration Team shall assist State Counsels during the cross examination of
Claimant’s witnesses of fact and expert witnesses during the arbitration hearing.
22. The Arbitration Team shall assist State Counsels to review transcripts of the hearing
and note important sections which can be used to support Respondent’s position.
23. The Arbitration Team shall assist State Counsels to prepare closing oral submission.
24. The Arbitration Team shall assist State Counsels to prepare any other submissions as
directed by the Arbitral Tribunal (such as cost of arbitration, taxes and interest).
25. The Arbitration Team shall assist State Counsels to prepare Final Submissions.
26. Upon receiving the arbitral award, The Arbitration Team shall assist State Counsels to
review the arbitral award to find out any avenues to challenge the award and request the
High Court to set aside the award if the same is not in the favour of the Respondent.
27. The Employer also can initiate arbitration by notifying the Contractor. In this scenario
Employer will be called the “Claimant” and the Contractor will be called the
“Respondent” and the process involved will be similar to above.
180
REFERENCES
Procurement Guidelines
Sub Section 5.4.14
Sub Section 5.4.15
Sub Section 5.4.16
Procurement Guide
Sub Section 5.4.14 of Supplement – 15 which superseded original content
ATTACHMENTS
Specimen Letters
SL/CA 69/01 – Notice of Arbitration
SL/CA 69/02 – Statement of Claim
SL/CA 69/03 –Statement of Defence
SL/CA 69/04 –Statement of Reply of the Claimant
181
SECTION 3
182
183
Attachments for Procedure CA/01
Pre-award Checklist
184
SPECIMEN LETTER : SL/CA 01/ 01 – LETTER OF ACCEPTANCE/AWARD
[Contract Name]
[Contract No]
1. We refer to your bid dated [Date] for execution of [Contract name and number] and the
attached Memorandum of Understanding (MOU) which contained subsequent
agreements reached between us, resulting an amendment to your bid price.
2. We wish to inform you that your bid, as corrected and modified in accordance with the
Instructions to Bidders and above referred MOU, for a sum of (currency) [Amount in
figures](currency) [Amount in letters]), including an amount of US$ [Amount in figures]
(currency) [Amount in letters]) as contingencies, defined as the Accepted Contract
Amount (exclusive of VAT) payable for the execution and completion of Works and the
remedying of any defects therein in accordance with the provisions of the Contract, is
hereby accepted.
3. In addition to the said Accepted Contract Price, a sum of LKR [Amount in figures]( LKR
[Amount in letters]) is allocated under this Contract for meeting your obligations to pay
VAT and Custom duties for Goods to be imported under this Contract.
4. Payment of all other taxes including company taxes and personnel taxes of Contractors’
staff, except VAT, custom duties and NBT (if applicable), shall be the responsibility of
the Contractor.
5. VAT applicable under this Contract will be paid separately upon production of a Tax
Invoice. VAT registration number of the [Name of the organization] is [VAT registration
number]
6. Pending the signing of a formal Contract Agreement, your amended bid together with
the said MOU and this Letter of Acceptance with the attachments shall form a binding
Contract between us.
7. You are required to enter into a contract agreement with us within 28 days after you
receive this Letter of Acceptance and please find enclosed the draft contract agreement
for your perusal.
8. The following documents shall be deemed forming the Contract and the priority of the
documents shall be in accordance with the given sequence:
185
a. Contract Agreement (when signed)
b. This Letter of Acceptance
c. Memoranda of Understanding (if any)
d. All Minutes of Negotiation meetings and correspondence between parties
relevant to negotiations, among which latest having higher priority
e. Letter of Tender
f. Addenda
g. Particular Conditions of Contract [– Part A]
h. [Particular Conditions of Contract – Part B]
i. General Conditions of Contract
j. Specifications/[Employer’s Requirements]
k. Drawings
l. Bill of Quantities/ Schedules
m. Contractor's Proposal and any other documents forming part of the Contract.
n. Supplementary Information
10. Time for Completion of this Contract is [Number of Months] months calculated from the
Commencement Date.
11. The Employer will pay you an amount equal to [Percentage of the Advance Payment] of
the Accepted Contract Amount as an advance payment within [No. of days] after
receiving the Advance Payment Guarantee in accordance with the terms of the
Contract.
12. You are hereby requested to obtain the Insurances required under the Contract, provide
receipts for payment of the premiums and produce the original policies for our
verification along with a certified copy for our retention within [No. of days] days of the
receipt of this Letter of Acceptance.
13. You are also requested to submit a Power of Attorney, acceptable to us, of the
authorized representative of yours for the Project as required by the Contract.
14. The Contract Number allocated to this Contract is [Contract Number], which should be
quoted in all future correspondence in reference to the Contract.
15. You are required to provide a Performance Security within 28 days of the receipt of this
Letter of Acceptance, in accordance with Sub-Clause ..of the Conditions of Contract, in
the form of a on demand Bank Guarantee issued by an acceptable bank in accordance
with the terms of the Contract.
16. All correspondence with the Employer shall be addressed to the Project Director,
[Project Name], [Name of the Employer], [Address of the Project office]
17. The “Engineer” for the Contract is Eng. [Head of the Entity’s name], Head of the Entity,
[Name of the Employer] [Address of the Employer]
18. Please acknowledge and advise the date of receipt of this letter.
Thanking you.
Yours faithfully,
186
[Chairman/Head of the Entity/Project Director]
[Name of the Employer]
cc:
1. Secretary, [Name of the line ministry] /Chairman, Procurement Committee
2. Chairman, [Name of the Employer]
3. Head of the Entity[Name of the Employer]
4. Project Director
5. [Funding Agency]
6. Director (……….) ,ERD
7. Director General of Public Finance, General Treasury
8. Director General, External Resources Department
9. CIDA
10. Auditor General
11. Commissioner General of Inland Revenue
2. Chief Engineers
3. Senior Engineers
4. Engineers
5. Quantity Surveyors
6. Engineering
Assistants
7. Technical Officers
187
SL/CA 02/ 01 – LETTER TO HOD REQUESTING RELEASE OF IN-HOUSE STAFF
GM/DG
[Name of the Organization]
[Contract Name]
Contract No. [Contract No]
Subject: Request to Release Staff for Project Works
I have assessed that qualified and competent persons for following positions are required for
this project as mobilization of certain contracts under this project are expected within next
few months:
Upon my inquiry, I have identified that following in-house candidates are available to be
engaged, as their current projects are nearing completion.
I appreciate if you could make arrangements to release above persons for this project.
Also I appreciate if you could make arrangements to recruit suitable persons for following
positions in this project on contract basis, in accordance with Management Services Circular
No. 33 of 2007 and its subsequent amendments, as suitable persons to fill such positions
are not available within in-house staff.
Thanking you.
Yours faithfully,
188
Attachments for Procedure CA/03
189
10. Soil investigation logs and reports
Available
Not Available
Not Applicable
11. Material Testing reports
Available
Not Available
Not Applicable
12. As built information/drawings of previous
constructions in same area including GIS Available
Not Available
Not Applicable
13. Information on utility positions in the area
including GIS Available
Not Available
Not Applicable
190
22. Cabinet Memoranda and decisions of
Cabinet of Ministers approving the award Available
Not Available
Not Applicable
23. Letter of Acceptance/Award
Available
Not Available
Not Applicable
24. Project Management Guide
Available
Not Available
Not Applicable
Available
Not Available
Not Applicable
Available
Not Available
Not Applicable
191
Attachments for Procedure CA/04
[Contract Name]
Contract No. [Contract No]
Subject: Important/Specific Provisions and Ambiguities/ Discrepancies in the
Contract Documents
MEMO
Please find below certain important provisions which are specific to the captioned contract:
2.
Please find below some ambiguities/ discrepancies between different documents forming the
contract, which were identified during the review of contract documents. Please note that the
contractual interpretations/positions for such ambiguities/ discrepancies are stated against
each of them in the table.
1. Particular Conditions of Sub-Clause …… Appendix to the Bid shall prevail over the
Contract Particular Conditions of Contract
192
[Contract Name]
[Contract No]
Subject: Engineer’s Instruction to Clarify Ambiguities/Discrepancies between
Documents Forming the Contract
We wish to inform you that upon our review of Contract Documents, we have identified
following ambiguities/ discrepancies between documents forming the Contract:
1.
2.
Accordingly, we hereby instruct you our position with regard to above ambiguities/
discrepancies, in accordance with the Sub-Clause 1.5 of the Conditions of Contract, as
follows:
1.
2.
Thanking you.
Yours faithfully,
[Engineer/Team Leader]
[the Public Entity]
cc:Project Director
193
Not OK
Not Applicable
This Contract Agreement is made on the [day of the month]day of [Month and Year] between
the [Name of the Employer], established under the [Act/Law which established the Employer]
having its head office at [Address of the Employer] (hereinafter called “the Employer” which
term means and includes the said [Name of the Employer], its successors and assigns) on
the one part, and [Contractor’s name], a company duly incorporated in [Contractor’s
country], having its principal office at [Contractor’s HO address] (hereinafter called “ the
Contractor” which term means and includes the said [Contractor’s name], its successors and
assigns) on the other part.
WHEREAS the Employer is desirous that Works with regard to [Contract name], should be
executed by the Contractor and has accepted a Tender submitted by the Contractor for the
[designing,] execution and completion of such Works and the remedying of any defects
therein, in accordance with the provisions of the Contract.
1. In this Agreement works and expressions shall have the same meanings as are
respectively assigned to them in the Conditions of Contract hereinafter referred to.
2. The following documents shall be deemed to form and be read and construed as part
of this Agreement:
194
c. Minutes of Negotiation meetings and correspondence between parties
relevant to negotiations, among which latest having higher priority
d. The Letter of Tender dated ….
e. The Addenda nos. …
f. The Particular Conditions of Contract [– Part A]
g. [The Particular Conditions of Contract – Part B]
h. The General Conditions of Contract
i. The Specifications/[Employer’s Requirements]
j. The Drawings
k. The completed Bill of Quantities/ Schedules
l. The Contractor's Proposal and any other documents forming part of the
Contract.
m. Supplementary Information
The priority of above documents shall be in accordance with the given sequence,
item a. having the highest priority after this Contract Agreement.
IN WITNESS whereof the parties hereto have caused this Agreement to be executed the
day, month and year first before written.
Signed by [Name of the Chairman], Chairman and [Name of the Board Member] Board
Member on the part of the said [Name of the Employer]at [Place at which contract is to be
signed], in the presence of the following witnesses.
……………………………………… ………………………………………
[Name of the Chairman] [Name of the Board Member]
Witnesses:
01.Signature:……………………………….. 02.Signature:…………………………………..
Name:……………………………………….. Name:……………………………………………
Address:…………………………………….. Address:…………………………………………
……………………………………………….. ……………………………………………………
195
Signed by [Name of the authorized signatory of the Contractor] in the capacity of authorized
signatory for the said [Contractor’s name] at [Place of signing], in the presence of the
following witnesses.
………………………………………………
……………………
Witnesses:
01.Signature:……………………………….. 02.Signature:…………………………………..
Name:……………………………………….. Name:……………………………………………
Address:…………………………………….. Address:…………………………………………
……………………………………………….. ……………………………………………………
To From
1.
2.
3.
4.
196
Training Record
1.
2.
Description of Training:
197
5. Quality of the Venue Excellent
Very Good
Good
Not Bad
Poor
6 Quality of the Food/Refreshment Excellent
Very Good
Good
Not Bad
Poor
7. Has the training provided enhance Excessively
your knowledge and improved your Significantly
competence in Contract Management Moderately
Slightly
Not at all
8. Do you have any other
comments with regard to the
content of the training or manner
in which the training was
conducted?
198
3. The Contractor has been provided with OK
effective access to and possession of the Site Not OK
Not Applicable
4. Advance payment or its first installment has OK
been paid Not OK
Not Applicable
5. The Engineer and/or his assistants has been OK
provided with copies of all relevant Not OK
documentation, including all contract Not Applicable
documentation and drawings
[Contract Name]
[Contract No]
Subject: Instruction to Commence Works
3. Accordingly we hereby instruct you to commence works with effect from [Date], in
accordance with the provisions of Sub-Clause 8.1 of the Conditions of Contract.
Thanking you.
Yours faithfully,
199
[Name of the GM/Consultant as the case may be]
[Head of the Entity/Team Leader]
cc:
1. Secretary, [line ministry]/Chairman, Procurement Committee
2. [Chairman,[ the Entity]
3. [Head of the Entity
4. [Project Director]
5. [Team Leader, Supervision Consultants]
6. [Funding Agency]
7. Director (……….) ,ERD
8. Director General of Public Finance, General Treasury
9. Director General, External Resources Department
10. Auditor General
11. Commissioner General of Inland Revenue
200
SL/CA 08/ 01 – LETTER TO THE CONTRACTOR INFORMING EMPLOYERS
FINANCIAL ARRANGEMENTS
[Contract Name]
[Contract No]
Yours faithfully,
cc:
1. [Chairman of the Entity]
2. [Head of the Entity, [the Entity]
3. [Project Director]
4. [Team Leader, Supervision Consultants]
5. [Funding Agency]
[Contract Name]
[Contract No]
Subject: Appointment of the Engineer
201
We hereby appoint you as the Engineer for the captioned contract in accordance with the
Sub-Clause 3.1 of the Conditions of Contract.
Accordingly we hereby advise you to commence your services with immediate effect in
accordance with the provisions of the Contract.
Thanking you.
Yours faithfully,
cc:
1. Secretary, [line ministry]/Chairman, Procurement Committee
2. [Chairman, [the Entity]
3. [Project Director]
4. [Funding Agency]
[Contract Name]
[Contract No]
Subject: Appointment of the Engineer
We hereby notify you that M/S [Name of the Engineer] has been appointed as the Engineer
for the captioned contract in accordance with the Sub-Clause 3.1 of the Conditions of
Contract.
Also please note that M/S [Name of the Engineer] has appointed [Name of the Authorized
Person] as their Authorized Person for this Contract.
Accordingly we hereby advise you to communicate with the Engineer and take instructions
from him in accordance with the provisions of the Contract.
Thanking you.
Yours faithfully,
[Name of the GM]
Head of the Entity
202
cc:
1. Secretary, My of WS&D/Chairman, Procurement Committee
2. [Chairman[the Entity]
3. Addl. GM- [the Entity]
4. [Project Director]
5. [Funding Agency]
[Contract Name]
[Contract No]
Subject: Notification of Intention to Replace the Engineer
We hereby notify you of our intention to replace the incumbent Engineer M/S [Name of the
Engineer] with M/S [Name of the intended replacement Engineer] as the Engineer for the
captioned contract in accordance with the Sub-Clause 3.4 of the Conditions of Contract.
Please find enclosed profile of the [Name of the intended replacement Engineer] together with
his experience and other particulars for your information
Thanking you.
Yours faithfully,
Head of the Entity
cc:
1. Secretary, [line ministry]/Chairman, Procurement Committee
2. [Chairman, [Entity]
3. [Project Director]
4. [Funding Agency]
203
SL/CA 09/ 03 – LETTER NOTIFYING THE APPOINTMENT OF REPLACEMENT
ENGINEER
[Contract Name]
[Contract No]
Subject: Appointment of the Replacement Engineer
We hereby notify you of appointment of M/S. [Name of the replacement Engineer] as the
Engineer for the captioned contract replacing the incumbent Engineer M/S [Name of the
Engineer] with effect from [Date], in accordance with the Sub-Clause 3.4 of the Conditions of
Contract.
Please note that the incumbent Engineer M/S [Name of the Engineer] will be ceased to
function as the Engineer for this Contract with effect from the same date.
Also please note that M/S [Name of the replacement Engineer] has appointed [Name of the
Authorized Person] as their Authorized Person for this Contract.
Address:
Telephone No.:
Fax No.:
Email Address:
Thanking you.
Yours faithfully,
Head of the Entity
cc:
1. Secretary, [line ministry]/Chairman, Procurement Committee
2. [Chairman
3. [Project Director]
4. [Funding Agency]
[Contract Name]
204
[Contract No]
Subject: Appointment of the Engineer’s Assistants
We hereby appoint you as a [Position] for the captioned contract in accordance with the Sub-
Clause 3.2 of the Conditions of Contract.
Accordingly we hereby advise you to commence your services with immediate effect in
accordance with the provisions of the Contract.
Thanking you.
Yours faithfully,
Head of the Entity
cc:
5. Project Director
6. The Contractor
[Contract Name]
[Contract No]
Subject: Assign Duties and Delegate Authorities to the Resident Engineer
We hereby assign you following duties and delegate following authorities to you with regard
to the captioned contract in accordance with the Sub-Clause 3.2 of the Conditions of Contract:
1 Monitor progress.
2 Clarify technical requirements and draft supplementary drawings, site sketches, and site
instructions as required.
3 Supervise survey teams in checking the Contractor's setting out and the accuracy of line,
level, and dimensions after construction.
4 Quality control and approval of works in progress, in liaison with Materials Engineer,
including signing “Work Approval Sheets”, checking manufacturer’s test certificates,
advising the Engineer’s Representative of the rejection of materials and workmanship,
and checking remedial works.
5 Monitor safety and security of the Works.
6 Check Contractor’s temporary works and method statements.
7 Monitor compliance with environmental requirements.
8 Agree Contractor’s Day works sheets
9 Supervise measurement of the Works.
10 Advise on and draft day works orders, provisional sum orders, and variation orders for the
approval of the Engineer.
205
11 Immediately advise the Engineer of claims / contractual disputes and ensure that
contemporary records are maintained of all events which might affect the outcome. All
“time and materials” sheets to be signed “without prejudice”
12 Immediately advise the Engineer of any accidents or emergencies and recommend
action.
13 Attend Site meetings when required to do so.
14 Assist in co-ordination with local authorities and the police, and public relations.
15 Maintain site diaries and site records including the preparation of Daily Reports
16 Provide direct on-the-job training in construction supervision to their local counterpart and
draft input to Training Reports for the Employer.
17 Assist in the preparation of the Monthly Contract Administration Report to the Employer.
18 Carry out inspections for Taking-Over the Works.
19 Check Contractor(s)' working and "as built" drawings.
Accordingly we hereby advise you to carry out above duties assigned to you in accordance
with the provisions of the Contract.
Thanking you.
Yours faithfully,
Head of the Entity
cc:
1. Project Director
2. The Contractor
[Contract Name]
[Contract No]
Subject: Revocation of Authority Delegated to Engineer’s Assistants
We hereby revoke duties assign to you and authority delegated to you as a [Position] for
the captioned contract in accordance with the Sub-Clause 3.2 of the Conditions of Contract.
Accordingly we hereby advise you not to engage in any activity involving the captioned
contract with immediate effect in accordance with the provisions of the Contract.
Thanking you.
Yours faithfully
206
cc:
1. Project Director
2. The Contractor
1.
2.
3.
4.
5.
6.
7.
8.
9.
10.
1.
2.
3.
207
Attachments for Procedure CA/12
4. OK
Not OK
Not Applicable
5. OK
Not OK
Not Applicable
6. OK
Not OK
Not Applicable
Remarks:
It is hereby confirmed that possession of the site for above mentioned Sections/ Parts of the Works
have been handed over to the Contractor.
Signature:
Position:
208
Attachments for Procedure CA/13
[Contract Name]
[Contract No]
Subject: Handing Over of Survey Control Points and Bench Marks
We wish to inform you that we intend to hand over Survey Control Points and Bench Marks
which are required for setting out and level/position controlling of Works in this Contract.
Accordingly, we hereby advise you to arrange your surveyor on [Date] to take over such
Survey Control Points and Bench Marks from our surveyor [Name of the Surveyor]. You may
contact our surveyor at telephone number [telephone number] for necessary arrangements.
Thanking you.
Yours faithfully,
Engineer
Enclosed : Form SF/CA 13/ 01 – Handing Over of Survey Control Points and Bench Marks
SF/CA 13/ 01 – HANDING OVER OF SURVEY CONTROL POINTS AND BENCH MARKS
Following Survey Control Points have been handed over to the Contractor’s Surveyor on
[Date of handing over]:
S/No. Reference Coordinates Remarks
No.
N E
Following Bench Marks have been handed over to the Contractor’s Surveyor:
209
Attachments for Procedure CA/14
[Contract Name]
[Contract No]
Subject: Kick-off Meeting
We wish to invite you for the kick-off meeting for the captioned contract which will be held at
[Venue of the meeting] on [Date of the meeting] at [Time of the meeting]. Your participation
in this kick-off meeting is appreciated.
Thanking you.
Yours faithfully,
[Name of the Project Director / Project Manager as the case may be]
[Project Director / Project Manager]
210
Enclosed : Agenda for the Kick-off meeting
cc:
1. Secretary, [Line Ministry] Chairman, Procurement Committee
2. [Chairman]
3. [Head of the Entity
4. HoD
5. [Project Director]
6. [Funding Agency]
Contract:
Contract No.:
Venue:
Date:
Time:
AGENDA
S/No. Time Item
Welcome and Introductions
Meeting Purpose
Project Overview
Project Background and Purpose
Project Objectives
Project Scope & Schedule
Roles & Responsibilities of Team Members
Project status
Project Schedule
Discussion on Potential issues
Discussion on contractual obligations of parties during initial stage
Discussion on establishing various mechanisms/procedures
Follow up actions
Other Business
Summary
Close
211
SF/CA 014/ 03 – MINUTES OF THE KICK-OFF MEETING
[Contract Name]
[Contract No]
Present
Vetted by Approved by
212
Attachments for Procedure CA/15
[Contract Name]
[Contract No]
Subject: Communication Details
We wish to inform you that following are the Contact information which should be use for
communication of all contractual correspondences relevant to this Contract:
Postal Address:
Telephone Number:
Facsimile Number:
Email Address:
Thanking you.
Yours faithfully,
Project Director
cc:
1. Head of the Entity
2. [Team Leader, Supervision Consultants]
1. OK
Not OK
Not Applicable
2. OK
Not OK
Not Applicable
213
3. OK
Not OK
Not Applicable
4. OK
Not OK
Not Applicable
5. OK
Not OK
Not Applicable
6. OK
Not OK
Not Applicable
214
10. Formatting of the output is acceptable OK
Not OK
11. Work sequence and activities defined are OK
accordance with the Contractor’s method Not OK
of working
12. Method of working (Method Statement) OK
submitted with the Work Program is Not OK
complying with the contractual
requirements and acceptable work
practices.
[Contract Name]
[Contract No]
Subject: Notification of Comments on Work Program
We refer to your letter ref: [Reference No.] dated [Date], within which you submitted your
Work Program to the Engineer in accordance with Sub-Clause 8.3 of the General Conditions
of Contract.
Upon carefully reviewing your above Program, we wish to notify you in accordance with Sub-
Clause 8.3 that said Program is not complying with the requirements stipulated in the
Contract due to following reasons:
1.
2.
3.
Accordingly we hereby instruct you to submit a revised work Program to the Engineer to
address above concerns raised, in accordance with Sub-Clause 8.3.
Thanking you.
Yours faithfully,
Project Director
cc:
1. Head of the Entity
2. [Team Leader, Supervision Consultants]
215
Attachments for Procedure CA/18
[Contract Name]
[Contract No]
Subject: Submission of Cash Flow Forecast
We hereby instruct you to submit your non-binding estimates of the payments for quarterly
periods (quarterly Cash Flow Forecast) in accordance with Sub-Clause 14.4 of the General
Conditions of Contract, within 42 days after the Commencement Date.
Please note that revised estimated quarterly Cash Flow Forecasts shall be submitted at
quarterly intervals, until the Taking-Over Certificate has been issued for the Works.
Thanking you.
Yours faithfully,
Project Director
cc:
1. Head of the entity
2. [Team Leader, Supervision Consultants]
[Contract Name]
[Contract No]
Subject: Appointment of the Employer’s Representative
We hereby notify you that Mr. [Name of the Employer’s Representative], Project Director of
the [Name of the Project] has been appointed as the Employer’s Representative for the
captioned Contract.
216
Accordingly we hereby advise you to send your contractual correspondence, including any
notifications, to the Project Director, on behalf of the Employer, in accordance with the
provisions of the Contract.
Thanking you.
Yours faithfully,
Chairman
cc:
1. Secretary, [Line Ministry], Procurement Committee
2. Head of the Entity
3. [Project Director]
4. Engineer
5. [Funding Agency]
Attachments for Procedure CA/20
217
SL/CA 020/ 01 – LETTER TO BANK FOR VERIFICATION OF AUTHENTICITY OF THE
PERFORMANCE SECURITY
[Reference] [Date]
Manager
[Name of the Bank which issued/confirmed the Performance Security]
Dear Sir,
We refer to the Performance Security No. [Ref, No. of Performance Security] dated [Date
of Performance Security], [provided/confirmed] by your bank on behalf of the Contractor
for [Name of the Project] project; [Name of the Contractor], a copy of which is enclosed.
In terms of the said Performance Security, you have agreed to pay us up to a [Guaranteed
amount]( [Guaranteed amount in letters]), on behalf of [Name of the Contractor], upon our
first written demand.
We wish to request you to confirm in writing, authenticity of the said Performance Security
which shall remain valid and in force until [Expiry date].
We also wish to request you to confirm in writing your undertaking to pay us any sum within
the limit of [Guaranteed amount in letters]( [Guaranteed amount in letters]), on behalf of
[Name of the Contractor], upon our first written demand, without any cavil, arguments or to
prove or show grounds or reasons for our demand or the sum specified therein, disregarding
any dispute we may have with the Contractor with regard to the underlying contract with us.
Thanking you.
Yours faithfully,
[Reference] [Date]
Manager
218
[Address of the Bank]
Dear Sir,
We refer to the Performance Security No. [Ref, No. of Performance Security] dated [Date of
Performance Security], provided by your bank on behalf of the Contractor for [Name of the
Project] project; [Name of the Contractor].
In terms of the said Performance Security, you have agreed to pay us up to a [Guaranteed
amount]( [Guaranteed amount in letters]), on behalf of [Name of the Contractor], upon our
first written demand.
We wish to inform you that the Contractor is yet to extend the said Performance Security,
expiry date of which is on [Expiry date]. We have already advised the Contractor to extend
the validity of said Performance Security until [Date] through our letter reference [Reference
No.] dated [Date of the letter], (a copy of which is attached), as the Performance Certificate
has not been issued, for reasons attributable to the Contractor.
We wish to request you to confirm in writing whether the said Performance Security has
been extended and the same remain valid and in force until [Date].
If the said Performance Security is not extended, before the expiry of the same on[Expiry
date], we hereby advise you to consider this as our demand for payment of [Guaranteed
amount in letters]( [Guaranteed amount in numbers] ) guaranteed under the said
Performance Security, as the Performance Certificate has not been issued, for reasons
attributable to the Contractor.
Accordingly, if the said Performance Security is not extended on or before [Expiry date], we
herby demand you to pay us [Guaranteed amount in letters]( [Guaranteed amount in
letters]), on behalf of [Name of the Contractor], the Contractor, as guaranteed in the above
referred Performance Security, to our Bank Account, details of which are given below,
219
We appreciate your early and prompt action.
Thanking you.
Yours faithfully,
cc:
1. Secretary ([Name of the Line Ministry])
2. Project Director
3. Resident Engineer
[Reference] [Date]
Manager
[Name of the Bank]
[Address of the Bank]
Dear Sir,
We refer to the Performance Security No. [Ref, No. of Performance Security] dated [Date of
Performance Security], provided by your bank on behalf of the Contractor for [Name of the
Project] project; [Name of the Contractor].
You have undertaken within the above referred Performance Security, to pay us any sum
within the limit of [Guaranteed amount in letters]( [Guaranteed amount in letters]), on behalf
of [Name of the Contractor], upon our first written demand.
We also wish to inform you that the Contractor has breached the Contract by [the respect in
which the Principal is in breach] and the said Performance Security is still remaining valid as
the Performance Certificate is yet to be issued.
220
the above referred Performance Security, to our Bank Account, details of which are given
below,
Thanking you.
Yours faithfully,
Enclosed: 1. A copy of the Performance Security No. [Ref, No. of Performance Security]
dated [Date of Performance Security]
2. Authentication of authorize signature by a notary public
cc:
1. Secretary (My W&D)
2. Head of the Entity
3. Resident Engineer
4. Project Director
[Reference] [Date]
Manager
[Name of the Bank]
[Address of the Bank]
Account No:
Account Type:
Manager
[Name of the Bank with whom Entity has its account]
[Date]
221
SF/CA 020/ 01 – PERFORMANCE SECURITY - DEMAND GUARANTEE
Name and address of Beneficiary [Name and address of the Employer] (whom the Contract
defines as the Employer).
We have been informed that [Name of the Contractor] (hereinafter called the "Principal") is
your contractor under such Contract, which requires him to obtain a performance security.
At the request of the Principal, we [Name of the Bank] hereby irrevocably undertake to pay
you, the Beneficiary/Employer, any sum or sums not exceeding in total the amount of (the
"guaranteed amount", say: [Guaranteed amount]) upon receipt by us of your demand in
writing and your written statement stating:
(a) that the Principal is in breach of his obligation(s) under the Contract, and
(b) the respect in which the Principal is in breach.
Any demand for payment must contain your Chairman’s or Head of the Entity’s signature
which must be authenticated by your bankers or by a notary public. The authenticated
demand and statement must be received by us at this office on or before [the date 70 days
after the expected expiry of the Defects Notification Period for the Works] (the "expiry date"),
when this guarantee shall expire and shall be returned to us.
We have been informed that the Beneficiary may require the Principal to extend this
guarantee if the performance certificate under the Contract has not been issued by the date
28 days prior to such expiry date. We undertake to pay you such guaranteed amount upon
receipt by us, within such period of 28 days, of your demand in writing and your written
statement that the performance certificate has not been issued, for reasons attributable to
the Principal, and that this guarantee has not been extended.
This guarantee shall be governed by the laws of Sri Lanka and shall be subject to the
Uniform Rules for Demand Guarantees, published as number 458 by the International
Chamber of Commerce, except as stated above.
Date Signature(s)
222
Attachments for Procedure CA/21
Project Manager
[Name of the Contractor]
[Address of the Contractor]
[Contract Name]
Contract No. [Contract No]
Subject: Arrangement for Disbursement of Payments
223
Thanking you.
Yours faithfully,
cc:
1. [Head of the Entity]
2. [funding Agency]
224
SL/CA 023/ 01 – LETTER TO BANK FOR VERIFICATION OF AUTHENTICITY OF THE
ADVANCE PAYMENT GUARANTEE
[Reference] [Date]
Manager
[Name of the Bank which issued/confirmed the Advance Payment Guarantee]
[Address of the Bank]
Dear Sir,
We refer to the Advance Payment Guarantee No. [Ref, No. of Advance Payment Guarantee]
dated [Date of Advance Payment Guarantee], [provided/confirmed] by your bank on behalf
of the Contractor for [Name of the Project] project; [Name of the Contractor], a copy of which
is enclosed.
In terms of the said Advance Payment Guarantee, you have agreed to pay us up to a sum of
[Guaranteed amount]( [Guaranteed amount in letters]), on behalf of [Name of the
Contractor], upon our first written demand.
We wish to request you to confirm in writing, authenticity of the said Advance Payment
Guarantee which shall remain valid and in force until [Expiry date].
We also wish to request you to confirm in writing your undertaking to pay us any sum within
the limit of [Guaranteed amount]( [Guaranteed amount in letters]), on behalf of [Name of the
Contractor], upon our first written demand, without any cavil, arguments or to prove or show
grounds or reasons for our demand or the sum specified therein, disregarding any dispute
we may have with the Contractor with regard to the underlying contract with us.
Thanking you.
Yours faithfully,
[Reference] [Date]
Manager
[Name of the Bank]
[Address of the Bank]
225
Dear Sir,
We refer to the Advance Payment Guarantee No. [Ref, No. of Advance Payment Guarantee]
dated [Date of Advance Payment Guarantee], provided by your bank on behalf of the
Contractor for [Name of the Project] project; [Name of the Contractor].
In terms of the said Advance Payment Guarantee, you have agreed to pay us up to a sum of
[Guaranteed amount]( [Guaranteed amount in letters]), on behalf of [Name of the
Contractor], upon our first written demand.
We have advised the aforesaid Contractor to extend the validity of said Advance Payment
Guarantee until [Date] by our letter [Reference No.] dated [Date of the letter], (a copy of
which is attached), as the advance payment has not been fully repaid yet. We wish to inform
you that the Contractor is yet to extend the said Advance Payment Guarantee, expiry date of
which is on [Expiry date].
We wish to request you to confirm in writing whether the said Advance Payment Guarantee
has been extended and the same remain valid and in force until [Date].
If the said Advance Payment Guarantee is not extended, before the expiry of the
sameon[Expiry date], we hereby advise you to consider this as our demand for payment of
[Guaranteed amount]( [Guaranteed amount in letters] guaranteed under the said Advance
Payment Guarantee, as the advance payment has not been repaid yet.
Accordingly, if the said Advance Payment Guarantee is not extended on or before [Expiry
date], we herby demand you to pay us [Guaranteed amount]( [Guaranteed amount in
letters]), on behalf of [Name of the Contractor], the Contractor, as guaranteed in the above
referred Advance Payment Guarantee, to our Bank Account, details of which are given
below:
Account No :
Account Name:
Bank Name :
Bank Code :
Branch Code :
Swift Code :
226
Enclosed: 1. A copy of the Advance Payment Guarantee No. [Ref, No. of Advance
Payment Guarantee] dated [Date of Advance Payment Guarantee]
2. Authentication of authorize signature by a notary public
cc:
1. Secretary
2. Head of the Entity
3. Project Director
4. Resident Engineer
[Reference] [Date]
Manager
[Name of the Bank]
[Address of the Bank]
I hereby certify that the signature below which was placed before me, is a genuine and
authentic signature of [Name of the Chairman/General Manger], [Chairman/General Manger]
of [name of entity], according to records pertaining to the following bank account maintained
in this bank.
Account No. :
Account Type :
Manager
[Name of the Bank with whom the entity has its account]
[Date]
Dear Sir,
227
We refer to the Advance Payment Guarantee No. [Ref, No. of Advance Payment Guarantee]
dated [Date of Advance Payment Guarantee], provided by your bank on behalf of the
Contractor for [Name of the Project] project; [Name of the Contractor].
In terms of the said Advance Payment Guarantee, you have agreed to pay us up to a sum of
[Guaranteed amount]( [Guaranteed amount in letters]), on behalf of [Name of the
Contractor], upon our first written demand.
We wish to inform you that the aforesaid Contractor has failed to repay an amount of
Rs[Amount to be repaid] of the Advance Payment, in accordance with the conditions of the
Contract.
Account No :
Account Name:
Bank Name :
Bank Code :
Branch Code :
Swift Code :
Thanking you.
Yours faithfully,
[Name of the Chairman]
Chairman
Enclosed: 1. A copy of the Advance Payment Guarantee No. [Ref, No. of Advance
Payment Guarantee] dated [Date of Advance Payment Guarantee]
2. Authentication of authorize signature by a notary public
cc:
1. Secretary
2. Head of the Entity
3. Resident Engineer
4. Project Director
[Reference] [Date]
Manager
[Name of the Bank]
[Address of the Bank]
228
Authentication of Authorized Signature
I hereby certify that the signature below which was placed before me, is a genuine and
authentic signature of [Name of the Chairman/General Manger], [Chairman/General Manger]
of [insert name of entity], according to records pertaining to the following bank account
maintained in this bank.
Manager
[Name of the Bank with whom the entity has its account]
[Date]
229
Attachments for Procedure CA/25
[Contract Name]
[Contract No]
Subject: Subject: Appointment of Dispute Board Members
Accordingly we hereby request you to nominate a Dispute Board member and also your
early confirmation of the Dispute Board member nominated by us.
Thanking you.
Yours faithfully,
[Project Director]
cc:
1. Head of Entity
2. Engineer
3. DB Member
[Contract Name]
[Contract No]
Subject: Subject: Approval for Installation of [Name of the Installation; e.g. Batching Plant]
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
requested our prior approval for your proposed installation of [Name of the Installation].
Upon reviewing your above proposal, we wish to grant you our prior approval for your
proposed installation of [Name of the Installation], subject to following conditions:
1.
2.
230
3.
Thanking you.
Yours faithfully,
[Project Director]
cc:
1. Head of Entity
2. Engineer
[Contract Name]
[Contract No]
Subject: Subject: Approval for Sub Contractors
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
requested our prior approval for proposal to engage [Name of the sub contractor] as your
sub contractor for [Scope of sub contract].
Upon reviewing your above proposal, in accordance with Sub-Clause 4.5 [Subcontractors] of
the General Conditions of Contract, we wish to grant our prior approval for your proposal to
engage [Name of the sub contractor] as your sub contractor for [Scope of sub contract].
Thanking you.
Yours faithfully,
[Project Director]
cc:
Head of Entity
Engineer
231
Attachments for Procedure CA/28
[Contract Name]
[Contract No]
Subject: Subject: Appointment of Nominated Subcontractor for [Scope of sub contract]
Accordingly, we advise you to enter into a subcontract with the said subcontractor, subject to
the provisions in the Sub-Clause 5.2 of the Conditions of Contract.
Thanking you.
Yours faithfully,
[Project Director]
cc:
1. Head of Entity
2. Engineer
232
identified Not OK
Not Applicable
5. Inspections and tests to be carried out OK
including hold points for quality control are Not OK
included
[Contract Name]
[Contract No]
Subject: Approval of Materials
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
requested our prior approval for [Name of the Material].
Upon inspecting and testing the samples of materials and reviewing information submitted
by you, we hereby grant our prior approval to use materials from the same source which
provided samples for submission.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
233
Attachments for Procedure CA/31
[Contract Name]
[Contract No]
Subject: Handing Over of Free-Issue Materials
We intend to hand over following free-issue materials which are to be used in the permanent
Works, in accordance with the Contract:
Accordingly, we hereby advise you to make arrangements to take over above materials from
our stores at [location].
Thanking you.
Yours faithfully,
Project Director
cc:
1. Head of Entity
2. Engineer
Date :
Section :
Progress of the Works
Location Description of work in progress Instructions/NCNs issued Remarks
234
Test Carried out
Location Description of the Test Results Remarks
Safety
Concerns :
Environmental
Concerns :
Public
Complaints :
Any other
Concerns :
Visitors :
Engineer’s Assistant
[Contract Name]
[Contract No]
Subject: Acceptance of Daily Report Format
235
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your proposed format for Daily Report for our acceptance.
Upon reviewing your proposed format for Daily Report, we hereby give our acceptance for
the same.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
[Contract Name]
[Contract No]
Subject: Acceptance of Contractor’s Monthly Statement Format
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your proposed format for Contractor’s Monthly Statements for our acceptance.
Upon reviewing your proposed format for Contractor’s Monthly Statements, we hereby give
our acceptance for the same.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
236
Attachments for Procedure CA/34
[Contract Name]
[Contract No]
Subject: Acceptance of Contractor’s Monthly Progress Report
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your proposed format for Contractor’s Monthly Progress Report for our
acceptance.
Upon reviewing your proposed format for Contractor’s Monthly Progress Report, we hereby
give our acceptance for the same.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
[Contract Name]
[Contract No]
Subject: Engineer’s Instruction No. [Serial No.]for [Title of the Instruction]
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
requested our instructions/clarifications on the captioned matter.
Please find enclosed Engineer’s Instruction No. [Serial No.]for [Title of the Instruction],
issued in accordance with Sub-Clause 3.3 of the Conditions of Contract.
237
[Please note that you would not be entitled to any extension of time for completion and/or
additional costs due to this instruction, as this instruction is issued merely to clarify certain
matters which were not clear to you.]
Thanking you.
Yours faithfully,
Engineer
ENGINEER’S INSTRUCTION
[Project Name]
Contract : [Name of the Contract]
Contract No. :
Engineer’s Instruction No.: [Serial No.] Date: [Date of instruction]
To : [Name of the Contractor], the Contractor
Instruction:
This instruction is issued in accordance with Sub-Clause 3.3 of the Conditions of Contract.
You are hereby instructed as follows:
……………………………………………………………………………………………………………
(signed) The Engineer/Engineer’s
Assistant
Enclosed : Drawings [Drawing Nos.]
Original : Contractor
Copies : Employer
238
Attachments for Procedure CA/36
[Contract Name]
[Contract No]
Subject: Acceptance of Formats for Contractor’s Labour/Equipment Returns
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your proposed format for Contractor’s Labour/Equipment Returns for our
acceptance.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
E Date of NCN
F Deadline for taking action
Engineer/Engineer’s Assistant
239
2. To be filled by the Contractor
A Investigations/Tests Required
B Root cause for the non-conformance
C Remedial Action proposed
D Date of proposal
Contractor’s Representative
Engineer/Engineer’s Assistant
240
SF/CA 37/ 02 CORRECTIVE ACTION REQUEST (CAR)
C NCN No.
D Date of CAR
E Deadline for taking action
Engineer/Engineer’s Assistant
D Date of proposal
Contractor’s Representative
Engineer/Engineer’s Assistant
241
SPECIMEN LETTER : SL/CA 37/ 01 – REVIEW CONTRACTOR’S QUALITY
ASSURANCE SYSTEM & QUALITY PLANS
[Contract Name]
[Contract No]
Subject: Review of the Contractor’s Quality Assurance System & Quality Plans
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your Quality Assurance System & Quality Plans, for our information.
We have reviewed your Quality Assurance System & Quality Plans, and we have no
objections for you to implement said system for this Contract.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
[Contract Name]
[Contract No]
Subject: Acceptance of the Contractor’s Quality Assurance System & Quality Plans
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your Quality Assurance System & Quality Plans, for our acceptance.
Upon reviewing your Quality Assurance System & Quality Plans, we have following
comments/concerns regarding the same:
1.
Thanking you.
Yours faithfully,
Engineer
cc:Project Director
242
Attachments for Procedure CA/38
PROJECT:
CONTRACT :
CONTRACT NO.
ENGINEER:
CONTRACTOR :
Date of the meeting : Venue :
Participants :
Name Position/Organization
1
2
Item Description Action By
243
12.0 Drawings
Operational and Maintenance Guides
Contractor’s Questions
244
Attachments for Procedure CA/39
[Organization]
PROJECT :
CONTRACT :
CONTRACT NO:
ENGINEER:
CONTRACTOR:
For the Month :
MONTHLY PROGRESS REPORT NO. ……
SECTION 1 - Project Summary
SECTION 2 - Project Description
SECTION 3 - Executive Summary
SECTION 4 - Progress of Work (Physical & Financial )
SECTION 5 - Variation Orders
SECTION 6 - Claims
SECTION 7 - Critical Issues
SECTION 8 - Minutes of Meeting
SECTION 9 - Contractor’s Report
SECTION 10 - Quality Control Report
SECTION 11 - Environmental and Social Issues
SECTION 12 - Progress Photographs
[Project ]
Funded by
[Funding Agencies]
EXECUTING AGENCY :
IMPLEMENTATION AGENCY :
245
SECTION 2 - Project Purpose and Project Data
APPENDICES
Appendix – 1 : Project Map
Appendix – 2 : Disbursement details
Appendix – 3 : Implementation Schedule and Progress Computation
Appendix – 4 : S-Curve for Construction Contract
Appendix – 5 : Status of Compliance with Loan Covenants
Appendix – 6 : Progress of Land Acquisition and Resettlement
Appendix – 6 : Status of Mitigation of Environmental and Social Impacts
[Project ]
Funded by
[Funding Agencies]
EXECUTING AGENCY :
IMPLEMENTATION AGENCY :
SECTION 2 - Introduction
246
SECTION 3 - Implementation Progress (Physical & Financial )
Project:
Venue:
Date:
Time:
AGENDA
S/No. Item
1. Welcome and Introductions
Confirmation of minutes of previous meeting
2. Progress of implementation
3. Critical Issues
4. Land Acquisition and Resettlement
5. Social and Environmental Issues
6. Status of Post resettlement Social Impact Mitigation Measures
7. Status of Environmental Impact Monitoring
8. Project Performance Monitoring and Evaluation
9. Expenditure
10 Status of Resolutions Adopted by the Steering Committee
11 Other Business
12 Next Meeting
Close
247
SF/CA 42/ 03 – MINUTES OF THE STEERING COMMITTEE MEETING
[Project Name]
Minutes of the Steering Committee Meeting No.[Serial No. of the meeting] Held on [Date of
the meeting] at [Time of the meeting]
At the Conference Hall of [Venue]
Present
248
previous resolutions.]
11. Any other Business
Since there was no further business, the Secretary thanked all
participants and declared the meeting closed.
12. Date and Time of the Next Steering Committee Meeting
Next Steering Committee Meeting No. [Serial No. of the next
meeting], was agreed to be held on [date] at [Time of the
meeting]
Prepared by
Vetted by Approved by
249
Attachments for Procedure CA/45
Format for this Procedure is included in the Project Management Volume of the GPMCM
Guide
250
Attachments for procedure CA/47
[Contract Name]
[Contract No]
Subject: Request for Evidence to Substantiate Provisional Sum Payments
We refer to your letter Ref: [Reference No. of the letter] dated [Date], within which you have
submitted your cost proposal for carrying out works under the Provisional Sum for [Title of
the Provisional Sum].
We hereby instruct you to produce information such as quotations, invoices, vouchers and
accounts or receipts to substantiate the actual amounts paid (or due to be paid) by you to
your subcontractors.
Thanking you.
Yours faithfully,
Engineer
Project Name]
[Contract Name] Contract No. [Contract No.]
A B C D E F G H I
251
Attachments for Procedure CA/49
252
9. EOT agreed with the Contractor Yes
No
Engineer
Project Name]
[Contract Name] Contract No. [Contract No.]
Variation Orders Register
VO Date of Value of Value of Nett Value Employer’s Remarks
No. Description of the VO Issue Work Work of Work Approval
Added Omitted
This Variation Order is issued in accordance with Sub-Clause 13.1 of the Conditions of Contract.
You are hereby instructed to carry out following varied works:
Total
Employer’s Specific Approval in accordance with Sub-Clause 3.1 of the Conditions of Contract:
253
Attachments for PROCEDURE CA/50
Project Manager
[Name of the Contractor]
[Address of the Contractor]
[Contract Name]
Contract No. [Contract No]
Subject: New Rates
We hereby inform you that the Engineer has determined following new rates in accordance
with the Sub-Clause 12.3 [Evaluation] of the General Conditions of Contract.
Thanking you.
Yours faithfully,
Engineer
cc:
1. [Head of the Entity]
2. [Project Director]
3. [funding Agency]
Project Name]
[Contract Name]
Contract No. [Contract No.]
254
Attachments for Procedure CA/52
Engineer
255
SL/CA 52/ 01 – LETTER TO INFORM EXTENSION OF THE TIME FOR COMPLETION
DETERMINED BY THE ENGINEER
Project Manager
[Name of the Contractor]
[Address of the Contractor]
[Contract Name]
Contract No. [Contract No]
Subject: Extension of the Time for Completion
We refer to your letter Ref: [Reference No.] dated [Date] within which you have notified the
Engineer of your entitlement for an extension of Time for Completion for delay suffered due
to [delay event] for which the Employer was responsible.
Accordingly, upon carrying out an delay analysis to assess the extent of delay suffered by
you due to above said event, we have determined that you are entitled for an extension of
Time for Completion of [No. of days] days in accordance with Sub-Clause 8.4 [ Extension of
Time for Completion ].
We hereby instruct you to submit a revised work Program to reflect the new completion date
for this Contract.
Thanking you.
Yours faithfully,
cc:
1. [Head of the Entity]
2. [Project Director]
[Project Name]
[Contract Name] Contract No. [Contract No.]
Register of Employer’s Claims
Claim Date of Date of Amount Extensi Status Amou Extensi Remarks
No. Description of Notice Submis- Claimed on to of - on to
the Claim sion DNP Appro- ntApp DNP
Claim- val ro-ved Appro-
ed ved
256
Attachments for Procedure CA/54
[Contract Name]
[Contract No]
Subject: Instruction to Suspend Works
We hereby instruct you in accordance with the Sub-Clause 8.8 [Suspension of Works] of the
General Conditions of Contract, to suspend the works of [description of the part of the works]
with immediate effect until further notice.
[Please note that this suspension is required due to your delay in providing acceptable
design for rectification measures for defects occurred in the works, for which you are
responsible.]
Please ensure that such effected parts or the Works are secured and protected against any
deterioration, loss or damage during the period of suspension.
Thanking you.
Yours faithfully,
Engineer
cc:
1. Head of Entity
2. [Project Director]
3. [Funding Agency]
Format for Interim Payment Certificate provided in the Paragraph 7.9 of Guidelines for
Effective Construction Management (ICTAD/CM/01) published by CIDA should be adopted
257
Attachments for Procedure CA/56
Please refer to the format SF/CA 55/ 021 for Format for Interim Payment Certificate
Please refer to format SF/CA 55/ 021 for Format for Interim Payment Certificate.
Please refer to formats SL/CA 020/ 01 for Letter to Bank for verification of authenticity of the
Performance Security, SL/CA 020/ 02 for Letter to Bank demanding payment of guaranteed
amount if Performance Security is not extended, SL/CA 020/ 03 for Letter to Bank
demanding payment of guaranteed amount if the contract is breached and SL/CA 020/ 03 for
Letter to Bank for Authentication of Authorize Signature which should be change to suit the
purpose.
Daywork Order
[Project Name]
Contract : [Name of the Contract]
Contract No. :
Daywork Order No. : DWO [Serial No.] Date of Issue: [Date of issue]
Variation:
This Daywork Order is issued in accordance with Sub-Clause 13.6 of the Conditions of Contract.
You are hereby instructed to carry out following varied works:
Description
Original : Contractor
Copies : Employer
258
SF/CA 58/ 02 – FORMAT FOR DAYWORK RECORDS
[Contract Name]
[Contract No]
Subject: Termination of Contract
We have noted with regret that despite our repeated instructions, you have failed to achieve
any progress during recent months and that shows your clear intention not to continue with
the performance of the Contract until completion.
Since you have plainly demonstrated your intention not to continue performance of your
obligations under the Contract by your actions and inactions, the Employer hereby notify you
in accordance with sub paragraph (b) of Sub-Clause 15.2 [Termination by Employer] of the
General Conditions of Contract, that the Employer hereby terminate the Contract and expel
you from the site with effect from [Date 14 days after the date of this letter].
(i) To take necessary action immediately, to ensure protection of life and property and
Also to ensure safety of the Works.
(ii) Leave the Site and deliver any required Goods, all Contractor's Documents, and other
design documents made by or for you, to the Engineer.
(iii) To assign your following sub contractors to the Employer.
We also request you to provide any assistance required by the Engineer in agreeing or
determining Valuation at Date of Termination in accordance with Sub-Clause 15.3.
Please be informed that the Employer will pay you any balance amounts due to you upon
recovering any losses, damages and extra costs due to the Employer in accordance with
Sub-Clause 15.4 of the General Conditions of Contract.
Thanking you.
Yours faithfully,
[Name of the Chairman]
259
3.Head of Entity
4.[Project Director]
5.[Team Leader, Supervision Consultants]
6.[Funding Agency]
7.Attorney General
8.Auditor General
9.Commissioner General of Inland Revenue
[Contract Name]
[Contract No]
Subject: Termination of Contract Subsequent to Force Majeure
We refer to your Notice of Force Majeure dated [Date] which has been given under Sub-
Clause 19.2 [Notice of Force Majeure]
We have noted that the Force Majeure event, for which you have issued the above referred
notification, is continuing for[more than 84 days/multiple periods which total more than 140
days], preventing the execution of all the Works in progress substantially.
In the light of the above, we herewith give you our Notice of Termination in accordance with
the Sub-Clause 19.6 [Optional Termination, Payment and Release] of the General
Conditions of Contract and the termination of this Contract will become effective upon expiry
of 7 days of this notice.
Please be informed that the Employer will pay you any amounts due to you after the
Engineer issue a Payment Certificate upon determining the value of the works done, in
accordance with Sub-Clause 19.6.
Thanking you.
Yours faithfully,
260
7.Attorney General
8.Auditor General
9.Commissioner of General Inland Revenue
[Contract Name]
[Contract No]
Subject: Notice to Release from Performance
We wish to inform you that [describe the event/circumstance] which was outside the control
of the Parties, has arisen making it impossible/[unlawful] for either/both Parties to fulfill
its/their contractual obligations/[which, under the law governing the Contract].
Therefore, we herewith issue our Notice to Release from Performance in accordance with
Sub-Clause 19.7 [Release from Performance] of the General Conditions of Contract.
Please be informed that the Employer will pay you any balance amounts due to you in
accordance with Sub-Clause 19.6 [Optional Termination, Payment and Release] of the
General Conditions of Contract.
Thanking you.
Yours faithfully,
cc:
3. Secretary, [line ministry]
4. [Chairman,[ the organization]
5. [GM/DG, [the organization]
6. Addl. GM- [the organization]
7. [Project Director]
8. [Team Leader, Supervision Consultants]
9. [Funding Agency]
10. Attorney General
11. Auditor General
12. Commissioner of General Inland Revenue
261
Attachments for Procedure CA/61
[Contract Name]
[Contract No]
We refer to your application dated [Date] to the Engineer for a Taking-Over Certificate for the
Works/[Section….], within which you have notified that the Works/[Section….] would be
completed and ready for taking over by [Date], in accordance with Sub-Clause 10.1 [Taking
Over of the Works and Sections] of the General Conditions of Contract.
We wish to inform you that we have carried out a thorough review jointly with the Employer
to ascertain whether the Works/[Section….] have been completed and ready for taking over.
Upon above review, we are of the opinion that the Works/[Section….] have not been
completed in accordance with the Contract as there were outstanding works and defects
which would substantially affect the use of the Works/[Section….] for their intended purpose
and therefore it was not ready for taking over. (Please refer to the attached list of
outstanding works and defects)
Therefore, we wish to inform you that your application to the Engineer for a Taking-Over
Certificate for the Works/[Section….] has been rejected and you are required to complete all
outstanding works and remedy all defects which have been identified and included in the
attached list of outstanding works and defects, to enable us to issue Taking-Over Certificate
for the Works/[Section….].
Thanking you.
Yours faithfully,
Engineer
cc:
1. Head of Entity
2. [Project Director]
3. [Funding Agency]
262
SPECIMEN LETTER : SL/CA 61/ 02 – TAKING-OVER CERTIFICATE
[Contract Name]
[Contract No]
Subject: Taking-Over Certificate for the Works/[Section….]
We refer to your application dated [Date] to the Engineer for a Taking-Over Certificate for the
Works/[Section….], within which you have notified that the Works/[Section….] would be
completed and ready for taking over by [Date], in accordance with Sub-Clause 10.1 [Taking
Over of the Works and Sections] of the General Conditions of Contract.
We wish to inform you that we have carried out a thorough review jointly with the Employer
to ascertain whether the Works/[Section….] have been completed and ready for taking over.
Upon above review, we are of the opinion that the Works/[Section….] have been completed
in accordance with the Contract on [Date], except for certain outstanding works and defects
which would not substantially affect the use of the Works/[Section….] for their intended
purpose and therefore it was ready for taking over. (Please refer to the attached list of
outstanding works and defects)
Accordingly, we wish to inform you that we herewith issue the Taking-Over Certificate for the
Works/[Section….] with effect from [Date], in accordance with Sub-Clause 10.1 [Taking Over
of the Works and Sections] of the General Conditions of Contract as you have completed the
Works/[Section….] in accordance with the Contract.
Furthermore, we herewith advise you to complete all outstanding works and remedy all
defects which have been identified and included in the attached list of outstanding works
and defects, within the Defect Notification Period specified under the Contract.
Thanking you.
Yours faithfully,
Engineer
cc:
1. Head of Entity
2. [Project Director]
3. [Funding Agency]
263
completed
[Project Name]
[Contract Name]
Contract No. [Contract No.]
[Contract Name]
[Contract No]
Subject: Notification of Defects during Defect Notification Period
Thanking you.
264
Yours faithfully,
Engineer/[Project Director]
cc:
1. Head of Entity
2. [Project Director]
3. [Funding Agency]
Attachments for Procedure CA/64
Project Manager
[Name of the Contractor]
[Address of the Contractor]
[Contract Name]
[Contract No]
We wish to inform you that in accordance with the Sub–Clause 11.9 of the Conditions of
Contract, herewith we are issuing you the Performance Certificate for the captioned Contract
with effect from [Date], the date on which you have completed your obligations under the
Contract.
Thanking you.
Yours faithfully,
cc:
1. Chairman, [the organization]
2. [Head of the Entity], [the organization]
3. [Project Director]
4. [Team Leader, Supervision Consultants]
5. [Funding Agency]
265
Attachments for Procedure CA/65
1 As-built documents
266
3 Spare parts
4 Spare materials
5 Consumables
[Contract Name]
[Contract No]
We refer to the Contractor’s DB referral dated [Date], regarding the dispute on the [Dispute
Name]
In accordance with the Sub-Clause 20.4 of the General Conditions of the Contract, we
hereby submit our response to the Claimant’s above referred DAB referral.
1. Introduction:
The Contractor’s claim in the referral to the DAB is in respect of [Dispute Name], within
which the Contractor contended that he was entitled to be paid an amount of Rs. [Amount
claimed] as the payment for [brief description of the Contractor’s contention]
267
2. Employer’s Position in Summary :
Respondent’s Reply
[State the Employer’s position regarding each issue of the Contractor.]
Respondent’s Reply
[State the Employer’s position regarding each issue of the Contractor.]
Respondent’s Reply
[State the Employer’s position regarding each issue of the Contractor.]
5. Employer’s Conclusion:
(e.g. The Employer assert that there is no justifiable reason to pay the Contractor a
higher rate than the rate specified in the Contract when the work was exactly what has
been envisaged in the Contract;. The Employer concludes that the Contractor is not
entitled to be paid at the rate for ……………………………………….)
Thanking you.
Yours faithfully,
cc:
1. [Contractor]
2. [ Head of the relevant entity], [Name of the Entity]
3. [Team Leader, Supervision Consultants]
268
Attachments to the Employer’s Response
LIST OF ATTACHMENTS
[Contract Name]
[Contract No]
Subject: Employer’s Referral of Dispute No. [Dispute no.] for [Dispute Name]
to DB for a Decision
We hereby refer the Dispute No. [Dispute no.] for [Dispute Name]to you for a decision, in
accordance with the Sub-Clause 20.4 of the General Conditions of the Contract.
1. Introduction:
[brief description of the background to the dispute]
5. Employer’s Conclusion:
[State the Employer’s conclusion.]
(e.g. The Employer concludes that he is entitled for Delay damages for the period
………………………………………. as the said delay was due to a reason for which the
Contractor was responsible.)
Thanking you.
269
Yours faithfully,
cc:
6. [Contractor]
7. [Head of the Entity], [the organization]
8. [Team Leader, Supervision Consultants]
LIST OF ATTACHMENTS
Project Manager
[Name of the Contractor]
[Address of the Contractor]
[Contract Name]
[Contract No]
Subject: Notice of Dissatisfaction with DB’s Decision dated [Date] regarding Dispute No.
[Dispute no.] for [Dispute Name]
The Employer, the [Name of the Employer] , hereby gives its Notice of Dissatisfaction with
the above mentioned DB’s decision in accordance with Sub-Clause 20.4 of the General
Conditions of Contract.
270
Part of the Decision for which Dissatisfaction is Notified
We dispute the following statements in the DB´s aforementioned decision;
1.
2.
3.
Reasons for Dissatisfaction
The Employer’s dissatisfaction with the above DB’s decision on the captioned issues is due
to the following reasons:
a)
b)
c)
Furthermore, in the light of above facts, the Employer reiterates that the DB’s decision was
based on wrong interpretation of the Contract and inaccurate contentions and therefore
items 1, ….and …. of the DAB’s decision are not reasonable and are not contractually valid.
The Employer reiterates that some parts of the DAB’s decisions which have been highlighted
above, are not acceptable due to the reasons stated and the Employer hereby gives his
Notice of Dissatisfaction in accordance with the Sub-Clause 20.4 of the General Conditions
of Contract.
The Employer further asserts that in accordance with the Sub-Clause 20.4 of the General
Conditions of Contract, the DB’s aforesaid decision would not become final and binding due
to this Notice of Dissatisfaction.
Thanking you.
Yours faithfully,
cc:
1. [Head of the Entity], [the organization]
2. [Project Director]
3. [Team Leader, Supervision Consultants]
4. [Funding Agency]
271
Attachments for Procedure CA/68
Contractor has referred following disputes to the DB, and the DB has given his decision in
favour of the Contractor. We have issued Notices of Dissatisfaction to the Contractor as
those decisions of the DB were not acceptable to us.
DAB Reference Title
[Dispute No.] [Dispute Title]
[Dispute No.] [Dispute Title]
[Dispute No.] [Dispute Title]
We wish refer these disputes to the Standing Cabinet Appointed Review Committee for
evaluation, in accordance with the Cabinet Paper No. 11/0811/504/072 on Settlement of
Disputes in Relation to Contract Management.
Therefore, I appreciate if you could provide us your views on attempting amicable settlement
of above disputes. Accordingly, I herewith submit following information to you for evaluation.
If you need any further information, please contact [Name of the Project Director] at
telephone number [Telephone No.].
Thanking you.
Yours faithfully,
Head of the Entity
272
6. [Funding Agency]
Chairman
Standing Cabinet Appointed Review Committee
[Project Name]
[Contract Name]
Contract No. [Contract No.]
Proposal for Amicable Settlement
Contractor has referred following disputes to the DB, and the DB has given his decision in
favour of the Contractor. We have issued Notices of Dissatisfaction to the Contractor as
those decisions of the DB were not acceptable to us.
Subsequently, we have sought the opinion of the AG’s Department and they are of the view
that our issuing of the Notices of Dissatisfaction to the Contractor was reasonable.
I have reviewed an assessment of the issues in dispute submitted by the relevant Project
Director together with the opinion of the AG’s Department and I am of the view that these
disputes should be referred for amicable settlement. Accordingly, I herewith submit following
information to you for evaluation by the Standing Cabinet Appointed Review Committee in
accordance with Cabinet Paper No. 11/0811/504/072 on Settlement of Disputes in Relation
to Contract Management.
If you need any further information, please contact [Name of the Project Director] at
telephone number [Telephone No.].
Thanking you.
Yours faithfully,
273
[Head of the relevant entity]
[Name of the Entity]
cc:
1. Secretary, [Line Ministry]
2. [Chairman], [the organization]
3. Hon. Attorney General
4. [Project Director]
5. [Team Leader, Supervision Consultants]
6. [Funding Agency]
[Project Name]
[Contract Name]
Participants
Representing Employer
[Name] - Project Director, [Project Name]
[Name] - [Position]
[Name] - [Position]
- [Position]
Representing the Contractor
[Name] - [Contractor’s representative]
[Name] - [Position]
[Name] - [Position]
274
[Name] - [Position]
Pursuant to Sub Clause 20.4 of the General Conditions of Contract, the Contractor, [Name
of the Contractor] requested by his letter [Letter Ref:] dated [Date of the letter], that the
parties should attempt to settle the following disputes for which DB has given their decision,
and a party/parties has/have issued Notice of Dissatisfactions:
Above disputes were taken up for discussion at the meeting of the Amicable Settlement
Committee. The following is a record of the discussions that took place.
Matters Discussed:
The Employer briefed the ASC on his position regarding the claim and reasons for his
dissatisfaction for the DB’s decision.
[ASC’s Decision]
(e.g. ASC decided that the present method of payment followed by the Engineer will
not be changed.)
The Employer briefed the ASC on his position regarding the claim and reasons for his
dissatisfaction for the DB’s decision.
[ASC’s Decision]
(e.g. ASC decided to follow the DAB decision rejecting the Contractor’s claim)
Members:
275
i [Name of the Chairman, ASC] ………………………………….
ii [Name of the Member, ASC] ………………………………….
iii [Name of the Member, ASC] ………………………………….
Agreed
…………………………
[Name of the Contractor’s representative]
[Position of the Contractor’s representative]
[Name of the Contractor]
Minutes prepared by:
………………………….
[Name][Position][Organization]
Notice of Arbitration
Contract : Contract No. [Contract No.]for[Name of the Contract] dated [Date of the
Contract]
Arbitration Agreement:
Arbitration Agreement is consisted of following Sub-Clauses/provisions in the Contract:
(a) the dispute shall be finally settled under the Rules of Arbitration of the
International Chamber of Commerce,
(b) the dispute shall be settled by three arbitrators appointed in accordance with
these Rules, and
(c) the arbitration shall be conducted in the language for communications defined in
Sub-Clause 1.4 [Law and Language].
276
The arbitrator(s) shall have full power to open up, review and revise any certificate,
determination, instruction, opinion or valuation of the Engineer, and any decision of the
DAB, relevant to the dispute. Nothing shall disqualify the Engineer from being called as
a witness and giving evidence before the arbitrator(s) on any matter whatsoever
relevant to the dispute.
Neither Party shall be limited in the proceedings before the arbitrator(s) to the evidence
or arguments previously put before the DAB to obtain its decision, or to the reasons for
dissatisfaction given in its notice of dissatisfaction. Any decision of the DAB shall be
admissible in evidence in the arbitration.
Arbitration may be commenced prior to or after completion of the Works. The obligations
of the Parties, the Engineer and the DAB shall not be altered by reason of any
arbitration being conducted during the progress of the Works.
3. Item 7 of the Annex 3 of the Contractor’s letter P230605– GF/CHG dated 5th October
2007.
Provisions in Item 7 of the Annex 3 of the Contractor’s letter P230605– GF/CHG dated
5th October 2007 have superseded Sub-Clause 20.6 of Particular Conditions and Sub-
Clause 20.6 of General Conditions of Contract.
Sub-Clause 20.6 of General Conditions of Contract has been amended in the Particular
Conditions and subsequently amended again in the Item 7 of the Annex 3 of the
Contractor’s letter P230605– GF/CHG dated 5th October 2007 (page 14 of the Contract
document) accepting the award of the Contract and in Item 7 of the Annex 3 of the
Claimant (Employer)’s letter of acceptance T&C/WWDP/RM&JE/221/C1/2006 dated 27th
September 2007 (page 23 of the Contract document) to read as “The dispute shall be
finally settled in terms of the Arbitration Act No.11 of 1995 and the arbitration should be
under the UNCITRAL Rules and take place in Colombo, Sri Lanka.”
(a) Sub-Clause 20.4 [Obtaining Dispute Adjudication Board's Decision] and Sub-
Clause 20.5 [Amicable Settlement] shall not apply, and
(b) the dispute may be referred directly to arbitration under Sub-Clause 20.6
[Arbitration].
277
If there are versions of any part of the Contract which are written in more than one
language, the version which is in the ruling language stated in the Appendix to Tender
shall prevail.
The language for communications shall be that stated in the Appendix to Tender. If no
language is stated there, the language for communications shall be the language in
which the Contract (or most of it) is written.
2. When the Works in the Contract, was about 90% completed, lead partner of the Joint
Venture constituting the Respondent [Name of the Contractor], was adjudicated
bankrupt thus creating complication in management of the contract due to controlling of
the lead partner’s bank accounts by trustees appointed by the court as all bank
accounts which were used for transactions related to the Contract, were owned by the
lead partner. Also all sub contracts and supply contracts have not been signed with the
Joint Venture, but with the lead partner, making the execution of the project more
complicated if not impossible. When the Claimant was trying to help the Respondent by
acceding to some of his requests for extra-contractual concessions to complete the
Works (such as reducing the amount of performance guarantee), the Respondent
attempted to terminate the Contract with effect from 31st October 2013, invoking
provisions under Sub-Clause 16.2 of the General Conditions of Contract, alleging that
the Claimant became insolvent. The Claimant while rejecting the Respondent’s
entitlement to terminate the Contract under the Sub-Clause 16.2 of GCC, terminated
the Contract with effect from 15th November 2013 by notifying in accordance with sub
paragraph (b) of Sub-Clause 15.2 [Termination by Employer] of the General Conditions
of Contract, as the Respondent abruptly stopped execution of the Works with effect
from 31st October 2013 and as it was clear that the Respondent was not going to
continue the performance of the Contract until completion. Therefore a dispute has
arisen with regard to whether the Claimant or the Respondent is entitled for termination
of the Contract.
3. Upon the termination of the Contract, the Claimant demanded the [Name of the Bank]
which issued the Respondent’s Performance Guarantee, to pay the amount guaranteed
under the said Performance Guarantee. [Name of the Bank] Bank, instead of paying the
guaranteed amount, advised the Claimant (Employer) to return the Performance
Guarantee to the Respondent. Since the said Performance Guarantee is an
unconditional on-demand guarantee which states “we undertake to pay you, upon your
first written demand, and without cavil or argument, any sum or sums within the limits of
USD 9,065,048.50 as aforesaid, without your needing to prove or to show grounds or
reasons for your demand or the sum specified therein”, the said bank should have paid
the Claimant upon his demand to pay. It is clear that the said bank’s refusal to honour
the Performance Guarantee was on the instructions from the Respondent. Therefore
278
another dispute has arisen with regard to the payment of amount guaranteed under the
Performance Guarantee.
The Claimant requests the Arbitral Tribunal to direct the Respondent to refrain from
disposing any Goods (including materials, Contractor’s Equipment and Temporary Works)
without the specific approval of the Claimant in order to maintain the status quo, in
accordance with [insert rules of procedure as may be relevant to the Contract Agreement for
example] Article 26 of the UNCITRAL Arbitration Rules.
Relief/Remedy Sought:
1. The Claimant requests the Arbitral Tribunal to declare that the Claimant’s termination in
accordance with sub paragraph (b) of Sub-Clause 15.2 [Termination by Employer] of the
General Conditions of Contract, with effect from 15th November 2013 is Contractually
valid and to declare that the Respondent’s purported termination under the Sub-Clause
16.2 [Termination by Contractor] of the General Conditions of Contract, with effect from
31st October 2013 is Contractually invalid.
2. The Claimant requests the Arbitral Tribunal to declare that the Respondent (Contractor)
has breached the Contract by instructing its bank ; Danske Bank to refuse payment
guaranteed under the Performance Security, when the Claimant (Employer) demanded
the said payment and the Claimant further requests the Arbitral Tribunal to direct the
Respondent :
279
a. to instruct his bank ( ) to pay the Claimant an amount of [ ] as the amount
guaranteed under the Performance Guarantee: or
a. the Claimant (Employer) is entitled to complete the Works itself and/or arrange for
any other entities to do so
b. The Claimant (Employer) and entities arrange by it are entitled to use any Goods
(including materials, Contractor’s Equipment and Temporary Works), Contractor's
Documents and other design documents made by or on behalf of the Contractor.
4. The Claimant requests the Arbitral Tribunal to direct the Respondent (Contractor) to:
a. Refrain from disposing any Goods without the specific approval of the Claimant
b. Hand over all Goods (including materials, Contractor’s Equipment and Temporary
Works) required by the Claimant in completing the Works.
a. Pay the Claimant losses and damages suffered or to be suffered by it and any
additional/extra costs incurred or to be incurred by it in completing the Works.
b. Indemnify the Claimant of all claims for losses and damages suffered by third parties,
road authorities and utility agencies by rectifying such losses/damages or paying
compensation for such damages in lieu of rectification.
6. The Claimant) requests the Arbitral Tribunal to direct the Respondent (Contractor) to
pay the Claimant costs of this arbitration
Appointment of Arbitrators
We hereby appoint [Names of proposed Arbitrator] as one of the co-arbitrators [if it’s a
sole arbitrator state so] in accordance with [insert rules of procedure for example] the Item
4(c) of [Article 3 and Article 9 of the UNCITRAL Rules and we hereby request you to appoint
a co-arbitrator in accordance with the Item 2(d) of Article 4 and Article 9 of the UNCITRAL
Rules as may be relevant to the Contract Agreement.
Thanking you.
Yours faithfully,
cc:
1. [Head of the Entity], [the organization]
2. Hon. Attorney General
3. [Project Director]
4. [Team Leader, Supervision Consultants]
280
5. [Funding Agency]
6. [Name of the Arbitration Institution (only if an Arbitration Institution is involved]
281
SL/CA 69/ 02 – STATEMENT OF CLAIM
To:
In the Matter of an Arbitration between [ name of entity] (Claimant) and [Name of the
Contractor] (Respondent) under ([insert rules of procedure relevant to the Contract
Agreement( rules
Contract : Contract No. [ insert Contract No.]for[Name of the Contract] dated [Date of the
Contract]
Background:
1. The Contract for [Name of the Contract], was awarded to [Name of the Contractor] and
the Contract was signed on [Date of the Contract]. The Contractor has provided his
Performance Guarantee from [Name of the Bank] of [Country of the Bank] through its
branch in Sweden. The Works in the Contract was commenced in 1st February 2008 and
progressed without any interruptions but behind the agreed schedule.
2. When the Works in the Contract, was about 90% completed, lead partner of the Joint
Venture constituting the Respondent (Contractor), [Name of the Contractor], was
adjudicated bankrupt thus creating complication in management of the contract due to
controlling of the lead partner’s bank accounts by trustees appointed by the court as all
bank accounts which were used for transactions related to the Contract, were owned by
the lead partner. Also all sub contracts and supply contracts have not been signed with
the Joint Venture, but with the lead partner, making the execution of the project more
complicated if not impossible. When the Claimant (Employer) was trying to help the
Respondent (Contractor) by acceding to some of his requests for extra-contractual
concessions to complete the Works (such as reducing the amount of performance
guarantee), the Respondent (Contractor) attempted to terminate the Contract with effect
from 31st October 2013, invoking provisions under Sub-Clause 16.2 of the General
Conditions of Contract, alleging that the Claimant (Employer) became insolvent. The
Claimant (Employer), while rejecting the Respondent (Contractor)’s entitlement to
terminate the Contract under the Sub-Clause 16.2 of GCC, terminated the Contract with
effect from 15th November 2013 by notifying in accordance with sub paragraph (b) of
Sub-Clause 15.2 [Termination by Employer] of the General Conditions of Contract, as
the Respondent (Contractor) abruptly stopped execution of the Works with effect from
282
31st October 2013 and as it was clear that the Respondent (Contractor) was not going
to continue the performance of the Contract until completion. Therefore a dispute has
arisen with regard to whether the Claimant (Employer) or the Respondent (Contractor) is
entitled for termination of the Contract.
3. Upon the termination of the Contract, the Claimant (Employer) demanded the [Name of
the Bank] which issued the Respondent’s (Contractor’s) Performance Guarantee, to pay
the amount guaranteed under the said Performance Guarantee. [Name of the Bank]
Bank, instead of paying the guaranteed amount, advised the Claimant (Employer) to
return the Performance Guarantee to the Respondent (Contractor). Since the said
Performance Guarantee is an unconditional on-demand guarantee which states “we
undertake to pay you, upon your first written demand, and without cavil or argument,
any sum or sums within the limits of USD 9,065,048.50 as aforesaid, without your
needing to prove or to show grounds or reasons for your demand or the sum specified
therein”, the said bank should have paid the Claimant (Employer) upon his demand to
pay. It is clear that the said bank’s refusal to honour the Performance Guarantee was on
the instructions from the Respondent (Contractor). Therefore another dispute has arisen
with regard to the payment of amount guaranteed under the Performance Guarantee.
5. The Claimant (Employer) requests the Arbitral Tribunal to direct the Respondent
(Contractor) to refrain from disposing any Goods (including materials, Contractor’s
Equipment and Temporary.
283
Claimants (Employer) Position:
6. The Claimant (Employer) wishes to assert that the Respondents purported termination
is not contractually valid as his allegation to the effect that Employer became
insolvent/bankrupt, base on which he tried to terminate the contract was not legally valid
as:
a. In accordance with the Sri Lankan law only a court has authority to declare an
entity become insolvent/bankrupt.
b. There is no provision in the Sri Lankan law, NWSDB, as a state entity, to become
insolvent/bankrupt.
7. The Claimant (Employer) rejects the Respondents allegation that Claimant had failed to
respond to his request for Employer’s financial arrangements as the Claimant
responded to that request through the letter [Letter No.] dated [Date] which is attached
to this statement as WB/01. Furthermore, the Claimant wishes to point out that he has
proved that his financial arrangements were intact by making an interim payment to the
Respondent subsequent to his request to provide Employer’s financial arrangements.
8. The Claimant (Employer), without prejudice to his above position, asserts that, even if
the Claimant failed to provide evidence for his financial arrangements, termination of the
Contract base on that grounds require Respondent to give 14 day notice prior to such
termination, which the Respondent failed to carry out.
9. The Claimant (Employer) reiterates that the Respondents purported termination of the
Contract was contractually and legally invalid as shown above.
10. The Claimant (Employer) emphasizes that his termination of the Contract was the
legally and contractually valid termination as it was valid grounds in accordance with the
Contract.
Relief/Remedy Sought:
11. The Claimant (Employer) requests the Arbitral Tribunal to declare that the Claimant’s
(Employer’s) termination in accordance with sub paragraph (b) of Sub-Clause 15.2
[Termination by Employer] of the General Conditions of Contract, with effect from 15th
November 2013 is Contractually valid and to declare that the Respondent’s
(Contractor’s) purported termination under the Sub-Clause 16.2 [Termination by
Contractor] of the General Conditions of Contract, with effect from 31st October 2013 is
Contractually invalid.
12. The Claimant (Employer) requests the Arbitral Tribunal to declare that the Respondent
(Contractor) has breached the Contract by instructing its bank ; Danske Bank to refuse
payment guaranteed under the Performance Security, when the Claimant (Employer)
demanded the said payment and the Claimant (Employer) further requests the Arbitral
Tribunal to direct the Respondent (Contractor):
a. to instruct his bank (Danske Bank) to pay the Claimant (Employer) an amount of USD
9,065,048.50 as the amount guaranteed under the Performance Guarantee: or
284
b. to pay the Claimant (Employer) an amount of USD 9,065,048.50
13. The Claimant (Employer) requests the Arbitral Tribunal to declare that :
a. the Claimant (Employer) is entitled to complete the Works itself and/or arrange for
any other entities to do so
b. The Claimant (Employer) and entities arrange by it are entitled to use any Goods
(including materials, Contractor’s Equipment and Temporary Works), Contractor's
Documents and other design documents made by or on behalf of the Contractor.
14. The Claimant (Employer) requests the Arbitral Tribunal to direct the Respondent
(Contractor) to:
a. Refrain from disposing any Goods without the specific approval of the Claimant
(Employer).
b. Hand over all Goods (including materials, Contractor’s Equipment and Temporary
Works) required by the Claimant (Employer), in completing the Works.
15. The Claimant (Employer) requests the Arbitral Tribunal to direct the Respondent
(Contractor) to :
b. Indemnify the Claimant (Employer) of all claims for losses and damages suffered by
third parties, road authorities and utility agencies by rectifying such losses/damages
or paying compensation for such damages in lieu of rectification.
16. The Claimant (Employer) requests the Arbitral Tribunal to direct the Respondent
(Contractor) to pay the Claimant (Employer) costs of this arbitration
17. Any other relief the Arbitral Tribunal may think reasonable.
Chairman/[Counsel]
[The Entity]
cc:
[Name of the Contractor] (Respondent)
285
SL/CA 69/ 03 – STATEMENT OF DEFENCE OF THE RESPONDENT
STATEMENT OF DEFENCE
To:
In the Matter of an Arbitration [insert name of organization] (Claimant) and [Name of the
Contractor] (Respondent)
Contract : Contract No. [Contract No.] [Name of the Contract] dated [Date of the
Contract]
Introduction:
1. The Respondent (Employer) wish to inform that he would respond to each and every
paragraph of the Claimant’s Statement of Claim (SOC), referring to paragraph numbers
but using his own series of paragraph numbers.
2. If the Respondent needs to refer to any supporting documents which is not marked by
the Claimant, those documents would be marked and attached to the attached
Statement of Defence. In case the Respondent needs to rely on a document already
submitted by the Claimant, the Respondent will refer to that document using the serial
number assign to that document by the Claimant.
3. The Respondent admits the content of Paragraph 1 of the SOC that a Contract for
[Name of the Contract], was awarded to the Claimant and a valid contract exists
between the Claimant and the Respondent.
4. Responding to the Paragraphs 1 to 3 of the SOC, the Respondent rejects the Claimants
assertion that there was a delay of 30 days in handing over the possession of the site to
the Claimant
286
5. While rejecting the contention of the Claimant in Paragraph 4 of the SOC that he is
entitled for an EOT of 30 days, the Respondent emphasize that the delay was due to
unavailability of adequate resources for which the Claimant was responsible.
6. The Respondent wishes to point out that the Claimant is trying to mislead the Honorable
Tribunal by providing wrong information in Paragraph 5 of the SOC that he has notified
the Engineer and as evidence we submit the Engineer’s letter [Ref: No.] dated 11th
December 2012 marked as NWSDB/02.
7. Accordingly the Respondent out rightly reject the Claimant’s contention in Paragraph 6
of the SOC that he is entitled for an EOT and/or associated prolongation costs.
Counter Claims:
Relief/Remedy Sought:
9. 1. The Respondent requests the Honourable Arbitral Tribunal to declare that the:
a) The Claimant is not entitled for any EOT and/or prolongation costs with regard
to his claims referred for this arbitration.
b) The Claimant is not entitled for any other costs whatsoever including costs of
this arbitration and any interest for delayed payments
2. The Respondent requests the Honourable Arbitral Tribunal to direct the Claimant:
cc:
[Name of the Contractor] (Claimant)
To:
287
[Name of the Co-arbitrator] Co-arbitrator
In the Matter of an Arbitration between [name of the entity] (Claimant) and [Name of the
Contractor] (Respondent)
Contract : Contract No. [Contract No.]for[Name of the Contract] dated [Date of the
Contract]
1) The Claimant denies all and singular the averments contained in the Statement of
Defence save and except for those that are hereinafter specifically admitted.
5) The Claimant further states that it is unaware of the correctness of the matters stated
under paragraphs [……] contained in the Statement of Defence and puts the Claimant to the
strict proof thereof.
d) For costs and any other relief as to this Tribunal may deem fit, just and
equitable.
288