Home Owner S JCT Contract
Home Owner S JCT Contract
Home Owner S JCT Contract
(two copies one each for the customer and the contractor)
Enquiry letter (a sample for sending to potential contractors)
Guidance notes
About us
We are the Joint Contracts Tribunal (JCT), a well-known and independent organisation representing
all parts of the construction industry. Our members are listed below.
We produce a variety of construction contracts which are widely used throughout the industry. Our
building contract for a home owner/occupier who has not appointed a consultant to oversee the
work is a well-established part of this range and is designed to be fair to both sides.
Members
British Property Federation Limited
Construction Confederation
Local Government Association
National Specialist Contractors Council Limited
Royal Institute of British Architects
The Royal Institution of Chartered Surveyors
Scottish Building Contract Committee Limited
Building contract
for a home owner/occupier
who has not appointed a consultant to oversee the work
Guidance notes
Use this contract if you, the customer, deal directly with a builder working on your home. It is not
generally suitable for large projects where you may need to employ a consultant to act for you.
Important note: if you need a consultant to oversee the work, the building contract in this
folder will not be suitable. In this case you can use our Building contract for a home
owner/occupier who has appointed a consultant to oversee the work.
You may want to consider the following information before you decide to go ahead with the work.
You should also know about your right to cancel.
Customers
Choose a builder with a good local reputation. Personal recommendations from friends and
neighbours can be very useful.
You can also get a list of builders in your area from the following.
Construction Confederation
55 Tufton Street
Westminster
London
SW1P 3QL
Phone: 0870 8989 090
Website: www.thecc.org.uk
Decide exactly what you want the builder to do before you ask him to quote for the work.
This will avoid misunderstandings later on.
Get quotations from more than one builder three quotations are quite usual. But remember
that the cheapest quote may not always turn out to be the best value for money.
Check whether the builder belongs to a trade association and ask him to show you that
associations conditions of membership and code of conduct.
Dont be hurried into a decision. If the builder isnt prepared to take time to discuss your
work and give you his advice, then you should think about going elsewhere. A good
reputable builder will always want to do his best for you, right from the start.
Builders sometimes ask customers to make payments in advance, before they do the work.
Only consider making payments in advance for goods that need to be specially made off site
before work can start on your home.
Before you sign the contract make sure that you and the builder have filled in all the details in
Part 1 of the contract, which deals with the arrangements for the work.
Before you sign the contract, find out about the adjudication scheme referred to in K2
on page 6. Details of the adjudication scheme are available at www.jctcontracts.com
and from the organisations running the scheme. Adjudication is meant to be a fast and
relatively cheap way of settling disputes. The adjudicators decision will be binding unless
you or the builder challenge it in a court. (If the adjudicators decision is challenged in a
court you may have to pay other costs.)
If you have buildings or contents insurance, tell your insurers about the building work. If you
do not tell your insurers, they may not pay out if you make a claim.
You should ask the builder to confirm that he has insurance cover before starting the work. To
keep to the contract, the builder must have insurance to cover the building work, the materials
on site for the work, and his public liability to persons and property (cover against injuries to
people and damage to property).
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
If you need to give instructions on a change to the work, or to tell the builder about any faults in
the work, give details in writing.
If the builder does not keep to the relevant local authoritys building approvals, and the builder
cannot put the matter right, the local authority will hold you responsible.
For further guidance contact your local authoritys planning and building control departments
or view their website.
Builders
Be as courteous and helpful as possible when you receive an enquiry from the customer.
Its in your own interests to do so.
If you decide to give a quotation, remember that you must base it on the terms of the building
contract.
If you are chosen to do the work, make sure that you and the customer are both quite clear
about what is to be done, when, and the price for it. Fill in the necessary information in
Part 1 of the contract (the arrangements for the work) and Schedule 1.
Remember that what may simply be another job to you, could be a worrying, anxious time
for the customer.
If you want to start before building regulation approval is given, you must give the local authority
a building notice at least 48 hours before you start work.
Remember that, by law, for 6 years after finishing the work you will remain responsible for any
faulty work that arises because you failed to keep to the contract.
Both of you
Make sure you are both quite clear about which of you will produce a specification or drawings,
if they are needed.
Make sure you have both read and understood the terms in Part 2 of the contract before you
sign it.
The builder must keep to building regulations and health and safety laws. If the customer has
any concerns, he should discuss these with the builder.
If the customer agrees to pay by instalments, the stages when instalments are due should relate
to stages of the work, (for example, brickwork complete, plastering complete, roofing complete,
alterations to ground floor) rather than timescales. Only stages that can be clearly defined should
be used. If there is not enough space in section E on page 4 of the contract, continue on a
separate sheet of paper. The sheet of paper should then be signed by the customer and
builder and attached to the contract.
If you have any disagreements while the work is being done, first try to sort them out between
you before considering going to adjudication or to the courts.
If youve both made all the arrangements mentioned in the contract, and have followed all its
terms properly, you can look forward to a successful outcome to the work.
Right to cancel
The customer can cancel the contract within 7 days of signing it. See condition 9 in Part 2.
There is a cancellation form at the back of the contract.
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
ii
4/8/09
09:05
Page 2
Building contract
for a home owner/occupier
who has not appointed a consultant to oversee
the work
Customer
4/8/09
09:05
Page 3
Customers name
Address
Phone number
Address of the premises where the work will be done, if different from the above
Contractors name
Address
Phone number
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
4/8/09
09:05
Page 4
Part 1
A The work to
be done
2 A full description of the work to be done is given in the documents ticked below. They are called
the work details and have been drawn up and agreed between the customer and the contractor.
Contractors quotation
Date of quotation:
Drawings
Identifying numbers:
Specification
Date of specification:
(Both the customer and the contractor should initial the documents and the customer should keep
the originals with his copy of this contract.)
B Planning permission,
building regulations
and party walls
1 The contractor will apply for any planning permission, building regulations approval and party
consents that may be needed unless the customer indicates otherwise by ticking a box or
boxes below.
The customer will apply for the following.
Planning permission
2 The contractor will not start work at the premises before any planning permission and party
wall consents that are needed have been received. The contractor can start work before
building regulations approval is received, but he must let the local authority know at least
48 hours before he starts.
C Using facilities
on the premises
The customer has ticked below the facilities which he will allow the contractor to use free of charge.
Electricity
Telephone/fax
Washroom/toilet
Water
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
D Price
4/8/09
09:05
Page 5
2 The contractor will itemise the price and show the items on which VAT is charged, and at
what rate.
3 The price includes the contractors costs for applying for planning permission, building regulations
approval and party wall consents (unless the customer is applying for these, see B1). If the work
does not go ahead the customer will pay the contractors costs for making those applications.
4 The price also includes the contractors costs of dealing with any unexpected problems which
he could have discovered by carrying out a careful inspection before the price was agreed.
5 If the customer changes the work details the price will be increased or reduced depending
on the changes made. (See condition 4.)
6 The price for the work shown in the work details, together with all the increases or decreases
made to it, will be the total price.
E Payment
1 The customer should tick one of the boxes below to show how he will pay the contractor.
(See conditions 6(a) and 6(b).)
The customer will pay either:
95% of the total price for the work (as explained at D6 above) when the contractor finishes
all the work; or
the agreed instalments shown below (together with any price adjustment for changes to the
work) when the relevant stage of the work is finished.
Stage
Instalment
(The total of any amounts written above should equal 95% of the amount shown at D1.)
2 The customer will not have to pay the remaining 5% of the total price until 14 days after the
contractor has put right all the faults he is responsible for, and which arose 3 months after
the work was finished. (See condition 6(c).)
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
4/8/09
09:05
Page 6
1 The customer should tick one of the boxes below to show the working period. The working period
is the agreed length of time for doing the work.
The contractor will start the work no later than
/
G Product guarantees
The contractor will give the customer any guarantees issued by the manufacturers of products
installed in the work.
H Insurance
Working hours
am and
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
Occupation and
security of the
premises
4/8/09
09:05
Page 7
1 The customer has ticked a box below to show whether the premises will be lived in while the work
is being done.
The premises will be lived in
2 If the premises are unoccupied at any time while the work is being done the contractor will take
practical and common-sense precautions to deter intruders entering.
K Disputes
1 The customer or the contractor can start court proceedings to settle any disputes.
2 The customer or the contractor can have disputes decided within 21 days by an adjudicator
appointed under an adjudication scheme for this contract. The adjudication scheme is run by
The Royal Institution of Chartered Surveyors (RICS), the Royal Institute of British Architects (RIBA),
or the National Specialist Contractors Council (NSCC). This is as well as the right to go to court.
3 The contractor agrees that if he wants a dispute to be decided by adjudication, he will not apply to
the National Specialist Contractors Council.
4 If the customer or the contractor chooses adjudication to decide disputes, they both accept that
the cost, rules and procedures involved will become part of this contract.
Free details of the cost, rules and procedures for adjudication are available from the following.
The Royal Institution of Chartered Surveyors
Dispute Resolution Service
Surveyor Court
Westwood Way
Coventry, CV4 8JE
Phone: 020 7222 7000
Fax: 020 7334 3802
E-mail: drs@rics.org.uk
Royal Institute of British Architects
Adjudication Administrator
66 Portland Place
London, W1N 4AD
Phone: 020 7307 3649
Fax: 020 7307 3754
E-mail: adjudication@inst.riba.org
National Specialist Contractors Council
Royal London House
22-25 Finsbury Square
London, EC2A 1DX
Phone: 0844 249 5351
Fax: 0844 249 5352
E-mail: enquiries@nscc.org.uk
Customers signature
Contractors signature
Date
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
4/8/09
09:05
Page 8
Part 2
The conditions
Contractors
responsibilities
(a) Carry out the work set out in the work details carefully and competently.
(b) Use materials which are of satisfactory quality and suitable for their intended purpose.
The materials will be new unless the customer agrees otherwise in writing.
(c) Start and finish the work within the working period or any extension made to it.
(d) Be at the premises regularly to carry out the work during the agreed working hours.
(e) Not sub-contract any of the work without the customers permission.
(f) Store away his tools and equipment and ladders at the end of each working day.
(g) Regularly dispose of any rubbish from the work.
(h) Be responsible for any damage he may cause to the premises and its contents or to
neighbouring properties.
(i) Leave the working areas in a clean and tidy condition after finishing the work.
(j) Keep to all his legal duties and responsibilities.
2
Customers
responsibilities
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
4/8/09
09:05
Page 9
Only the customer can change the work details. Changes will be dealt with as follows.
(a) If the changes increase the amount of work shown in the work details and the contractor agrees
the changes, he will quote a price for the extra work and time involved. The customer will then
decide whether to go ahead with the changes.
(b) If the changes reduce the amount of work shown in the work details the contractor will make
an appropriate reduction in the price.
(c) If the changes alter the cost of any items in the work details without increasing or reducing
the amount of work involved, an appropriate adjustment of the price will be made to reflect
those changes.
Extending the
working period
(a) The customer will extend the working period by a fair and reasonable amount if the contractor:
(i) has to spend extra time on the work because of changes made to the work details; or
(ii) cannot finish the work on time for reasons beyond his control, including any delay caused
by the customer.
(b) The contractor can claim any reasonable costs arising from the working period being extended
because of any delay caused by the customer.
Payment
(a) When all of the work is finished (if the customer is not paying by instalments), or when each
stage of the work is finished (if the customer is paying by instalments), the contractor will
invoice the customer for the amount due after taking account of any price increase or decrease
for changes made to the work details. The invoice will be itemised and show the rate of VAT
charged on each item.
(b) The customer will pay 95% of the amount of the invoice no later than 14 days after receiving
the invoice from the contractor.
(c) The customer will pay the remaining 5% of the total price no later than 14 days after the
contractor has put right all the faults which:
(i) he is responsible for; and
(ii) the customer promptly reported as having appeared at any time between the date the work
was started and 3 months after it was finished.
Contractors
continuing
responsibility
For 6 years after carrying out the work the contractor will remain responsible for any faults in the
Bringing the
contract to an end
As well as the customers cancellation rights set out in condition 9 below, the following also apply.
work (other than fair wear and tear) which are caused by him.
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
Bringing the
contract to an end
continued
4/8/09
09:05
Page 10
(b) If the customer ends this contract he will only have to pay any money due to the contractor when
the work has been finished by another contractor.
(c) If the customer:
(i) does not pay an amount due, without having good reason; or
(ii) prevents or obstructs the contractor from carrying out the work;
and does not correct the matter within 7 days of receiving a written warning from the contractor,
the contractor can end this contract by giving the customer written notice. The contract will end
as soon as that notice is given.
(d) If the contractor ends this contract the customer will pay him, within 14 days of the contract
ending, for work properly carried out, for any materials made specially for the work and for
any other of the contractors materials on the premises which he allows the customer to keep.
Right to cancel
(a) The customer can cancel this contract for any reason by giving the contractor notice in writing
within 7 days of signing the contract.
(b) The customer can use the cancellation form attached as Schedule 1 at the back of this contract to
cancel this contract, but does not have to. On that cancellation form, the contractor should fill in:
(i) the name and address of the person the cancellation form should be sent to; and
(ii) the contract reference number or code, or any other details that identify the contract.
(c) The customer can send the written notice by post or email, or can deliver it in person. The notice
should be sent or delivered to the name and address set out in the cancellation form at the back
of this contract.
(d) The written notice will be considered to have been given on the day it is posted or sent by email,
whether or not the contractor actually receives it.
(e) If the customer cancels this contract under this condition 9, the contractor will refund any money
the customer has paid to the contractor in connection with this contract, except in the
circumstances set out in condition 9(f) below.
(f) The customer may have to pay for goods or services provided before he cancels this contract if
he has agreed, in writing, to the contractor providing the goods or services before the end of the
seven-day cancellation period referred to in condition 9(a) above. The customer may have to pay
for the following types of goods and services provided before cancellation.
(i) Services of any kind
(ii) Goods needed in an emergency
(iii) Goods that are personalised or made to the customers specification, and any services
relating to those goods
(iv) Perishable goods (goods which decay or go bad quickly)
(v) Goods that have been used or incorporated into the land
(g) If the customer cancels this contract, any related credit agreement (for example, a credit
agreement the contractor has provided or arranged in connection with this contract) will
automatically be cancelled.
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
10 Insolvency
4/8/09
09:05
Page 11
(a) If the customer or the contractor becomes insolvent (unable to pay their debts), this contract
will come to an end unless the insolvency practitioner involved makes a suitable arrangement
to allow the contract to continue.
(b) If this contract comes to an end because the contractor becomes insolvent, the customer will
not have to pay any amount then due to the contractor until the work has been finished by
another contractor.
(a) The customer and the contractor can claim from each other the costs and expenses which
result from either of them failing to keep to this contract.
(b) This contract does not rule out or limit any other legal remedies which may be available to
the customer or the contractor.
(c) Only the customer and the contractor can take action to enforce the terms of this contract.
10
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
Schedule 1
4/8/09
09:05
Page 12
Cancellation form
If you want to cancel the contract you must do so in writing and deliver or send it to the person
named below. You can use this form if you want to, but you do not have to.
To
(contractor to insert name and address of the person the notice may be given to.)
I want to cancel my contract
(contractor to insert reference number, code or other details to identify the contract).
Customers signature
Date
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
11
4/8/09
09:05
Page 1
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
12
The Joint Contracts Tribunal Limited 2009. Published by Thomson Reuters (Legal) Limited (Registered in England & Wales,
Company No 1679046) trading as Sweet & Maxwell Ltd, 100 Avenue London, London NW3 3PF
First published August 2005. Revised July 2009.
6/7/09
16:35
Page 1
Enquiry letter
To: (contractors name and address)
The terms and conditions which will apply are set out in the Building Contract for a home owner/occupier who
has not appointed a consultant to oversee the work, issued by the Joints Contracts Tribunal. Copies of this
contract are available from bookshops, please visit www.jctcontracts.com for a list of stockists.
Building contract for a home owner/occupier who has not appointed a consultant to oversee the work
The Joint Contracts Tribunal Limited 2009
(two copies one each for the customer and the contractor)
Enquiry letter (a sample for sending to potential contractors)
Guidance notes
About us
We are the Joint Contracts Tribunal (JCT), a well-known and independent organisation representing
all parts of the construction industry. Our members are listed below.
We produce a variety of construction contracts which are widely used throughout the industry. Our
building contract for a home owner/occupier who has not appointed a consultant to oversee the
work is a well-established part of this range and is designed to be fair to both sides.
Members
British Property Federation Limited
Construction Confederation
Local Government Association
National Specialist Contractors Council Limited
Royal Institute of British Architects
The Royal Institution of Chartered Surveyors
Scottish Building Contract Committee Limited
Building contract
for a home owner/occupier
who has not appointed a consultant to oversee the work