GOVERNMENT OF MALAYSIA

STANDARD FORM OF DESIGN AND BUILD CONTRACT

PWD FORM DB (Rev. 1/2010)

Hak Cipta Terpelihara Kerajaan Malaysia

 CONDITION OF CONTRACT

FOR DESIGN AND BUILD CONTRACT

PWD FORM DB (Rev. 1/2010)

This form has been approved 'by Attorney General's Chamber

 TABLE OF CONTENTS

Clause Page

1.0 DEFINITIONS AND INTERPRETATIONS 2

2.0 CONSIDERATION 4
3.0 SCOPE OF CONTRACT 4
4.0 REPRESENTATIONS, WARRANTIES AND UNDERTAKINGS OF THE 5
CONTRACTOR
5.0 COMPLIANCE WITH THE LAW IN PERFORMING THE WORKS 6
6.0 CUSTODY AND SUPPLY OF CONTRACT 7
7.0 SUFFICIENCY OF CONTRACT DOCUMENTS 8
8.0 RIGHTS OF P.O. 9
9.b CONTRACTOR'S PROJECT MANAGER 10
10.0 PERFORMANCE BOND 10
11.0 INSURANCE OF WORKS 11
12.0 POSSESSION OF SITE 12
13.0 PERFORMANCE OF THE WORKS 13
14.0 DESIGN 16
15.0 MATERIALS, GOODS AND WORKMANSHIP 19
16.0 RESTRICTION AND PROCEDURE ON USE OF IMPORTED MATERIALS AND 20
GOODS
17.0 CONSTRUCTIONAL PLANT, EQUIPMENT, VEHICLES AND MACHINERIES 21
18.0 NON-REMOVAL OF MATERIALS AND GOODS ON SITE 21
19.0 SITE BOUNDARIES AND $ETTING OUT 22
20.0 ANTIQUITIES 23
21.0 INSPECTION OF SITE 23
22.0 ACCESS TO THE SITE 24
23.0 VARIATIONS 24
24.0 VALUATION OF VARIATIONS 25
25.0 PROVISIONAL SUMS 25
26.0 EMPLOYMENT OF WORKMEN 26
27.0 COMPLIANCE WITH EMPL YMENT ACT 1955, ETC 26
28.0 EPIDEMICS AND MEDICAL ATTENDANCE 26
29.0 DAYS AND HOURS OF WORKING 27
30.0 WAGES, BOOKS AND TIME SHEETS 27
31.0 DEFAULT IN PAYMENT OF WAGES 28
32.0 DISCHARGE OF WORKMEN 28
33.0 EMPL YEESS' SOCIAL SECURITY ACT 1969 28
34.0 INDEMNITIES TO GOVERNMENT IN RESPECT OF CLAIMS BY WORKMEN 29

1
 Clause Page

35.0 CONSULTANTS 29
36.0 DIRECT PAYMENTS TO CONTRACTOR'S CONSULTANTS 30
37.0 SUB-CONTRACTTING AND ASSIGNMENT OF CONSULTANT'S 32
RESPONSIBILITY
38.0 GOVERNMENT'S INDEMNITY IN RESPECT OF INJURY TO PERSONS AND 32
DAMAGE TO PROPERTY
39.0 INSURANCE AGAINST INJURY TO PERSONS AND DAMAGE TO 33
PROPERTY
40.0 SUB-CONTRACTING AND ASSIGNMENT 34
41.0 BUMIPUTERA PARTICIPATION 35
42.0 TESTING AND COMMISSIONING OF MECHANICAL, ELECTRICAL AND 36
OTHER SERVICES
43.0 SECTIONAL COMPLETION 36
44.0 COMPLETION OF THE WORKS 37
45.0 DAMAGES FOR NON-COMPLETION .38
46.0 PARTIAL OCCUPATION /TAKING OVER BY GOVERNMENT 39
47.0 DEFECTS AFTER COMPLETION 39
48.0 UNFULFILLED OBLIGATIONS 40
49.0 DELAY AND EXTENSION OF TIME 41
50.0 PROCEDURE FOR CLAIMS 42
51.0 INTELLECTUAL PROPERTY RIGHTS, ROYALTUIES, ETC. 42
52.0 MAINTENANCE OF WORKS AND SERVICES 43
53.0 INTERIM PAYMENTS 44
54.0 FINAL ACCOUNT AND FINAL CERTIFICATE 45
55.0 EFFECT OF P.D'S CERTIFICATES AND PAYMENT BY GOVERNMENT 46
56.0 DEDUCTION FROM MONEY DUE TO CONTRACTOR 46
57.0 ADVANCE PAYMENT 46
58.0 PROVISIONAL BILLS OF QUANTITIES 47
59.0 SUSPENSION 48
60.0 EVENTS AND CONSEQUENCES OF DEFAULT BY THE CONTRACTOR 49
61.0 TERMINATION ON CORRUPTION, UNLAWFUL OR ILLEGAL ACTIVITIES 52
62.0 TERMINATION ON NATIONAL INTEREST 52
63.0 PAYMENTS UPON SUSPENSION OR TERMINATION ON NATIONAL 53
INTEREST
64.0 EVENTS AND CONSEQUENCES OF DEFAULT BY THE GOVERNMENT 53
65.0 CERTIFICATE OF TERMINATION COSTS 54
66.0 SURVIVING RIGHTS 55
67.0 FORCE MAJEURE 55

11
Clause Page

68.0 ARBITRATION 56
69.0 SAFETY AT SITE 57
70.0 TECHNOLOGY TRANSFER 58
71.0 ENVIRONMENTAL MATTERS 58
\
72.0 LAW GOVERNING THIS CONTRACT 59
73.0 COMPLIANCE WITH THE LAW 59
74.0 AMENDMENT 59
75.0 CONFIDENTIALITY 59
76.0 STAMP DUTY 60
77.0 NOTICES 60
78.0 TIME 61
79.0 SEVERABILITY 61

ll1
LIST OF APPENDICES

APPENDIX 1 APPENDIX TO THE CONDITION OF CONTRACT

APPENDIX 2 GOVERNMENT'S REQUIREMENTS
APPENDIX 3 CONTRACTOR'S PROPOSAL
APPENDIX 4 CONTRACT SUM ANALYSIS
APPENDIX 5 CONTRACT SCHEDULE OF RATES
APPENDIX 6 CERTIFIED COPY OF BANK GUARANTEE FOR PERFORMANCE BOND
APPENDIX 7 LIST OF GOVERNMENT MULTIMODAL TRANSPORT OPERATORS
APPENDIX 8 DETAILED DESIGN AND SPECIFICATIONS

iv
 CONTRACT NO: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Of 20 ,,____,.-

EXPENDITURE to be met from Head ________ Year of _ _ _ _ __

Sub-head _ _ _ _ _ _ __

THIS CONTRACT is made on the _ _ _ day of _ _ _ _ _ _ 20 _ _ __

BETWEEN

THE GOVERNMENT OF MALAYSIA (hereinafter referred to as "the Government") of the one part;

AND

_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ (hereinafter referred to as "the Contractor''), [a

company incorporated in Malaysia under the Companies Act 1965 (Com. No. _ _ _ __, ] with its
registered office at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ of
the other part.

(The Government and the Contractor shall hereinafter individually be referred to "Party" or collectively as the
"Parties")

WHEREAS

A. The Government is desirous of obtaining the design, construction, equipping* and maintenance*
of
----------------------------------
_ _ _ _ _ _ _ _ _ _ _ _# (hereinafter referred to as the Works'} at
for which Works the Government has issued to the Contractor its
requirements and instructed the Contractor to design the Works and to submit proposals_
including drawings and specification for carrying out the Works.

B. The Contractor has examined the site and has submitted proposals including drawings and
specification for carrying out the Works.

C. The Contractor has made an estimate of the sum which he will require for carrying out that which
is necessary for completing all the Works in accordance with the Conditions of Contract and has
submitted an analysis of that sum (hereinafter referred to as 'the Contract Sum Analysis').

D. The Government has examined the Contractor's Proposals and the Contract Sum Analysis and
subject to the Conditions of Contract, is satisfied that they appear to meet the Government's
Requirement.+

* Delete if not c;1pplicable

# State the title of intended-works. .
+ Where the Government has accepted a divergence in the Proposals submitted by the Contractor
from the Government's Requirements, the divergence should be effected by deletion or substitution
•.in the Government's Requirements before the contract documents are signed.
 NOW IT IS HEREBY AGREED AS FOLLOWS:

1.0 DEFINITIONS AND INTERPRETATIONS

1.1 Definitions

In this Contract, unless the context otherwise requires, the following words and phrases in this
Contract and the Appendices shall have the meaning given below:

(a) "Appendices" means Appendix 1, 2, 3, 4, 5, 6**, 7, and 8 tot.his Contract;

(b) "Contract" means this Contract including all the appendices attached
hereto;

(c) "Contractor'' means the person or persons, sole proprietor, partnership, firm
or company whose tender for the Works has been accepted
and who has or have signed this Contract and includes the
Contractor's personal representatives, heirs, successors,
executors, administrators, servant and agent;

(d) "Contractor's Proposals" means the proposals submitted by the Contractor for carrying
out the Works, including all drawings which comprises of
preliminary design and specifications as appended herewith
and Detailed Design and Specifications as submitted by the
Contractor from time to time;

(e) "Contract Period" means the contract period specified in the Letter of
Acceptance;

(f) "Contract Sum" means the sum stipulated in clause 2.2 of this Contract;

(g) "Contract Sum Analysis" means the sum stated in Appendix 4 which is prepared by the
Contractor as the estimate which he will require for carrying
out that which is necessary for completing all the Works in
accordance with this Contract;

(h) **"Contract Schedule of Rates" means the schedule of rates agreed between the Contractor
and the GovernmetH prior to the execution of the Contract, for
the purpose of va.luation of variations under the Contract;

** Delete if Contract Schedule of Rates is not applicable

2
 (i) "Date for Completion" means the date fixed and stated in Appendix 1 or any date
fixed under clause 49 as provided under clause 44.1;
U) "Date for Possession" means the date stated in Appendix 1;
(k) "Date of Tender" means the date fixed for submission of Tender as stated in
Appendix 1;

{I) "Day work" means the Day work price as specified in Appendix [ ];

(m) "Defects Liability Period" means the period stated in Appendix 1 or if none stated the
period is twenty four (24) months from the date of practical
completion certified by the P.D as provided under clause 44.2;

(n) Government's Requirements means instructions given by the Government to the Contractor
which contain information relating to the criteria, performance
specification and outcome expected of the Works in order for
the Contractor to prepare its propos.als;

(o) "On-cost Charges" means the cost and expense reasonably incurred by the
Government to perform the Contractor's obligations which the
Contractor has failed to perform and is calcuiated by applying
the percentage for On-cost Charges as stated in Appendix 1 to
the amount incurred;

(p) "Site" means the land and other places on, above, under, in or
through which the Works are to•--Oe executed and any other
lands or places provided or approved by the Government for
working space or any other purpose as may be specifically
designated under this Contract or subsequently agreed by the
P.D as forming part of the Site;

(q) 'Project Director or P.D" means •............................................................... and his

successors in office;

(r) "P.D's Representative" • means any person delegated by the P.D to perform any or all
of the duties of the P.D;

(s) "Variation Order" means an instruction issued by the P.D in the form as set out
in Appendix [ ] pursuant to clause 23.2; and
(t) 'Works" means the works briefly described in Recital A and referred to
in the Government Requirements and the Contractor's
Proposals and shall include both permanent and temporary
works.·

State the official designation of the officer responsible for the overall direction of the Works.

3
 1.2 Interpretation

(a) Unless otherwise specifically stated, any reference to Clauses and Appendices in this
Contract and the Appendices to any clause means that clause of this Contract.

(b) This Contract and the Appendices are to be read as a whole and the effect or operation
of any clause in this Contract or item in or entry in the Appendices shall, unless otherwise
specifically stated, be read subject to any relevant qualification or modification in any
other clauses in this Contract or item or entry in the Appendices.

(c) The terms "concurrence" and "approval" wherever used in this Contract means written
consent or approval by the Government or the P .D as the case may be, pursuant to a
written request or submission made by the Contractor;

(d) The term "instructed" wherever used in this Contract means instructed in writing by the
P.D (including subsequent confirmation of previous verbal instruction by the P .D).

(e) Words importing the singular shall also include the plural and vice versa.

(f) The headings are for convenience of reference only and shall not be deemed to be part
of this Contract or be taken into consideration in the interpretation or construction of this
Contract.

(g) The English text of this Contract shall be the authentic text and prevail over any
translations made on this Contract.

2.0 CONSIDERATION

2.1 For the consideration mentioned in clause 2.2, the Contractor shall upon and subject to the
clauses of this Contract both complete the design for the Works ana carry out construction and
completion of the Works.

2.2 The Government hereby covenants to pay to the Contractor the sum of Malaysian Ringgit:

____________ i.e. RM _ _ _ _ _ _ _ (hereinafter referred to as 'the

Contract Sum') or such other sum as shall become payable hereunder at the times and in the
manner specified in the Conditions of Contract.

3.0 SCOPE OF CONTRACT

3.1 The Contractor shall subject to the provisions of the Contract and save in so far as it is legally or

4
 physically impossible, -

(a) plan, design, construct, complete, test and commission the Works in accordance with
the Contract; and

(b) provide all design, services, labour, materials, Contractor's equipment, temporary works,
transport to and from and in or about the Site and everything whether of a temporary or
permanent nature required in and for such planning, design, construction, completion,
testing and commissioning so far as the necessity for providing the same is specified in
or reasonably to be inferred from the Contract.

3.2 The Contractor shall design, construct and complete the Works in accordance with the Contract
and where not expressly provided otherwise in the Contract, to the best advantage of the
Government and in accordance with good management and best industry practice, as
determined by the Government.

3.3 The Contractor shall take all appropriate measures expected of a competent contractor using due
care and skills of a professional person providing similar service or works to ensure that the
Works comply with the terms and conditions of this Contract.

3.4 The Contractor shall at all times perform its obligations specified in clause 3.1 in such manner as
will always safeguard and protect the Government's interest and take all necessary and proper
steps to prevent abuse and in accordance with the provisions of this Contract.

4.0 REPRESENTATIONS, WARRANTIES AND UNDERTAKINGS OF THE CONTRACTOR

4.1 Representations and Warranties

The Contractor represents and warrants to the Government that as at the execution date and
through out the Contract Period-

(a) the Contractor is a corporation validly existing under the laws of Malaysia*;

(b) the Contractor has obtained a valid registration with the Construction Industry
Development Board;

(c) the Contractor has the corporate power to enter into and perform his obligations under
this Contract and to carry out the transactions and to carry on his business as
contemplated by this Contract*;

(d) the Contractor has taken all necessary corporate actions to authorize the entry into and
performance of this Contract and to carry out the transactions contemplated by this
Contract*;

applicable only if the Contractor is a company registered under the Companies Act 1965.

5
 (e) neither the execution nor performance by it of this Contract nor any transactions
contemplated by this Contract will violate in any respect any provision of-

(i) its Memorandum and Articles of Association; or

(ii) any other document or agreement which is binding upon it or its asset*;.

(f) no litigation, arbitration, tax claim, dispute or administrative proceeding is presently

current or pending or, to its knowledge: threatened, which is likely to have a material
adverse effect upon it or its ability to perform its financial or other obligations under this
Contract; •

(g) this Contract constitutes a legal, valid and binding obligation of the Contractor and is
• enforceable in accordance with its terms and conditions; and

(h) it has necessary financial and technical capability, skills and expertise to undertake the
Works,

and the Contractor acknowledges that the Government has entered into this Contract in reliance
on its representations and warranties as aforesaid.

4.2 Undertakings of the Contractor•

The Contractor undertakes that -

(a) it shall comply with all requirements, statutory or otherwise, regulating or relating to the
conduct, trade, business or profession of a contractor, and the Contractor shall be fully
and solely liable for all costs incurred thereby;

(b) it shall pay all taxes that may be imposed on the profits made in respect of this Contract
in accordance with the applicable laws; and

(c) it shall ensure that all his employees, including non-Malaysian personnel, comply with all
relevant laws to which they are subject to, including payment of income tax, which in.
respect thereto the Contractor shall make such deductions from the salaries of his
employees as may be lawfully imposed by the relevant authority.

5.0 COMPLIANCE WITH THE LAW IN PERFORMING THE WORKS

5.1 The Contractor shall comply with all respects (including the giving of all notices and the paying of
all fees required) with any law, regulation or by-law, or any order or directive issued by any public
authority or public service company (hereinafter referred to as "Statutory Requirements"), relating
to the Works or, in the case of a public authority or public service company, with whose systems
the same are or will be connected. The Contractor shall keep the Government indemnified
against all penalties and liability of every kind of breach of any such Statutory Requirements Th~
Contractor shall submit to the P.D all documentation received by the Contractor in complying with
the Statutory Requirements.

• applicable only if the Contractor is a company registered under the· Companies Act 1965.

6
 5.2 If the Contractor or the P.D finds any divergence between the Statutory Requirements and either
the Government's Requirements (including any Variation), or the Contractor's Proposals, he shall
. immediately give to the other written notice specifying the divergence. In either case, the
Contractor shall inform the P.D in writing of his proposed amendment for removing the
divergence, and with the P.D's consent (which shall not be unreasonably delayed or withheld) the
Contractor shall entirely athis own cost save as provided in clause 5.5 and clause 5.6 complete
the design and construction of the Works in accordance with the amendment and the P.D shall
note the amendment on the Contract Documents.

5.3 If in any emergency, compliance with clause 5.1 requires the Contractor to supply materials or
execute work before receiving the P.D's consent under clause 5.2, the Contractor shall supply
such materials and execute such works as are reasonably necessary to secure immediate
compliance with the Statutory Requirements. The Contractor shall forthwith inform the P.D of the
emergency and of the steps that he is taking under this clause.

5.4 The Contractor shall pay and indemnify the Government against Hability in respect of any fees,
levy, charges, rates or taxes (excluding capital contribution) legally demandable under any written
law, regulation or by-law of any local authority or of any statutoty undertaker in respect of the
Works. No adjustment shall be made to the Contract Sum in respect of the amount of any such
fees, levy, charges, rates or taxes.

5.5 If after the Date of Tender, there is a variation in the Statutory Requirements affecting the Works
which necessitates some amendment to the Contractor's Proposals, such amendments shall be
treated as if it were an instruction of the P.D under clause 23.2 affecting a Variation.

5.6 If after the date of Tender, there is a decision made by a relevant authority which necessitates
any amendment to the Contractor's Proposals, such amendment shall be treated as if it were an
instruction of the P.D under clause 23.2 affecting a Variation to this Contract, PROVIDED THAT
such amendment is not precluded in the Government's Requirements.

6.0 CUSTODY AND SUPPLY OF CONTRACT

6.1 The Contract shall be prepared in two (2) original copies. The original copies of the Contract shall
remain in the custody of the P.D and the Contractor.

6.2 Immediately after the execution of this Contact the Contractor shall furnish without charge to the
Government, unless the Government shall have been previously so provided, with at least ten
(10) certified true copies.

6.3. The Contractor shall, without further charge to the Government, provide the P.D with two copies
of the construction drawings, specifications, details, levels and setting out dimension which the
Contractor prepares or uses for the purposes of the Works.

6.4 The Contractor shall keep one certified true copy of the Contract and other documents referred to
in clause 6.3 at the Site so as to be available to the P.D at all reasonable times.

7
 6.5 After the practical completion of the Works but within three (3) months after that date the
Contractor shall without further charge to the Government supply for the retention and use of the
P.D two (2) sets of drawings stored in CD-ROMs and four (4) sets of such drawings, documents,
information and manuals showing or describing the Works as built, and concerning the
maintenance and operation of the Works, including any installations comprised in the Works, as
may be specified in the Contract.

6.6 It is expressly agreed between parties that all maps, drawings, reports, specifications,
calculations, designs, and all _other relevant documents pertaining to this Contract shall be the
absolute property of the Government and shall not be 8tilized or retained by the Contractor for
any purpose other than with the permission of the Government.

6.7 The Contractor's plans and specifications shall use the S.I. Units (System International D'Unites)
of measurement, commonly known as the metric system as this is the requirement of all
approving authorities in Malaysia.

7.0 SUFFICIENCY OF CONTRACT DOCUMENTS

7.1 The Contractor shall provide everything necessary for the proper execution of the Works until its
completion according to the true intent and meaning of the Contract taken together whether the
same may or may not be particularly shown or described provided the same can be reasonably
inferred therefrom.

7.2 The Appendices are to be taken as mutually explanatory of one another but in the event of any
ambiguity or discrepancy the same shall be explained by the P.D to the Contractor who shall
rectify the discrepancy at his own cost and expense.

7.3 If there remain ambiguities or discrepancies between the Government's Requirements and the
Contractor's Proposal, the Government's Requirements shall prevail without adjustment of the
Contract Sum. Provided that if in the opinion of the P.D the Contractor's Proposal is better than
the Government's Requirements in terms of grade, technical specifications and materials the
Contractor's Proposal and drawings shall prevail.

7.4 Any ambiguities or discrepancies within the Government's Requirements shall be explained and
resolved by the P.D who shall thereupon issue to the Contractor appropriate instructions.

7.5 Where there is a discrepancy within the Contractor's Proposals or drawings, the Contractor shall
inform the P.D in writing of his proposed amendment to remove the discrepancy and (subject
always to compliance with Statutory Requirements) the P.D shall decide between the discrepant
items or otherwise may accept the Contractor's proposed amendment and the Contractor shall
be obliged to comply with the decision or acceptance by the P.D without cost to the
. Government.

7.6 The Government gives no warranty in any manner whatsoever for any information provided by

8
 the Government in the Contract as to their accuracy or sufficiency or as to how the same shall be
interpreted and the Government shall not be liable if such information is inaccurate or insufficient.
The Contractor shall not be relieved from its obligations to ensure that such information is
accurate and sufficient for the purposes of this Contract.

8.0 RIGHTS OF P.D

8.1 The Contractor shall, subject to clauses 8.4 and 23.2, forthwith comply with all instructions issued
to him by the P.D in regard to any matter in respect of which the P.D is expressly empowered by
this Contract to issue instructions. •

8.2 All instructions, notifications, consent or approvals issued by the P.D shall be in writing.
However, the P.D may, where necessary, issue oral instructions, notifications, consent or
approvals and such oral instructions, notifications, consent or approvals shall be followed in
writing not later than seven (7) days thereafter.

8.3 Such written instructions, notifications, consent or approval shall be left at the office of the
Contractor at the Site or sent to the Contractor's principal place of business.

8.4 If within seven (7) days after receipt of a written notice from the P.D requiring compliance with an
instruction the Contractor does not comply therewith, then the P.D may employ and pay other
persons to execute any work whatsoever which may be necessary to give effect to such
. instruction and all costs incurred in connection with such employment including On-cost Charges
shall be deducted by him from any monies due or to become due to the Contractor under this
Contract, failing which such de,ductions shall be recovered from the Performance Bond or as a
debt due from the Contractor.

8.5 In the event there is any change in the person who is named as P.D during the continuance of
this Contract, such successor shall not disregard or overrule any decision, approval, concurrence
or direction given to the Contractor in writing by his predecessor unless he is satisfied that such
action will not cause any pecuniary loss to the Contractor.

8.6 Notwithstanding any provision in this Contact, it is hereby agreed that:

(a) the power of the P.D to issue instructions requiring a variation under clause 23.2 shall be
subject to the financial limits as set out in Appendix 1 hereto. If the instruction for a
variation under clause 23.2 is more than the financial limits as set out in Appendix 1, the
P.D shall obtain the prior written approval of the relevant authorities of the Government;
and
{b) the right to take action and/or initiate proceedings on behalf of the Government in respect
of any matter which arises out of the provisions of Clauses, 60, 61, 62, 67 or 68 shall be
exercised by the Officer named in Appendix 1.
8.7 If any of the P.D's instructions which is issued pursuant to this clause 8 require the Contractor to
make any changes to the design in order to ensure that the Government's Requirements are
fulfilled, such changes shall not constitute a variation within the meaning of clause 23.

9
 8.8 The Contractor shall not be entitled to claim for extension of time or any extra cost or expense or
whatsoever arising from compliance with the provisions of clause 8.

9.0 CONTRACTOR'S PROJECT MANAGER

9.1 The Contractor shall at all times retain at the Site a competent, efficient, suitably qualified, and
experienced Project Manager who must be of good character and capable of receiving
instructions and communicating in Bahasa Malaysia and English.

9.2 Any instruction given to such Project Manager referred to in clause 9.1 by the P.D shall be
deemed to have been given to the Contractor.

10.0 PERFORMANCE BOND

10.1 The Contractor shall, as a condition precedent to the commencement of any work deposit with
the Go~mment a Performance Bond substantially in the form as set out in Appendix [ ] issued by
an approved licensed bank or financial institution incorporated in Malaysia in favour of the
Government for a sum equivalent to five percent (5%) of the Contract Sum to secure the due
performance of the Contractor's obligations under this Contract. The Performance Bond sha.11
remain valid and effective from the date of issuance until twelve (12) months after the expiry of
the Defect Liability Period or the issuance of the Certificate of Completion of Making Good
Defects, whichever is the later.

10.2 If the Contractor fails to submit the said Performance Bond in the form as specified under clause
10.1 by the Date for Possession, the Contractor shall be deemed to have opted for a
Performance Bond in the form of a performance guarantee sum instead whereby deductions of
ten percent (10%) shall be made from every interim payments until the total amount deducted is
equivalent to a five percent (5%) of the Contract Sum. The amount deducted shall be retained by
the Government up to twelve (12) months after the expiry of the Defect Liability Period or the
issuance of the Certificate of Completion of Making Good Defects, whichever is the later.

10.3 Notwithstanding clause 10.2, the Contractor may submit a Performance Bond in the manner
specified in clause 10.1 at any time after deductions of the interim payments are made pursuant
to clause 10.2. In such an event the Government shall refund the Contractor the amount which
has been deducted up to the date of submission of the Performance Bond.

10.4 Notwithstanding anything contained in this Contract, if the Contractor fails to perform any of his
obligations under the Contract and such failure is not remedied in accordance with this Contract,
the Government shall be entitled to call upon the Performance Bond, wholly or partially.

10.5 If a payment is made to the Government pursuant to any claim _under the Performance Bond, -
(a) in the case of a Performance Bond in the form specified under clause 10.1, the

10
 Contractor shall issue to the Government further security in the form of additional
Performance Bond; or
(b) in the case of a Performance Bond in the form of a performance guarantee sum under
clause 10.2, the Government may further deduct from any monies due by the
Government to the Contractor,
an amount not less than the amount so paid to the Government on or prior to the date of such
payment so that the total sum of the Performance Bond shall be maintained at all times at the
value specified in clause 10.1 or clause 10.2, whichever is applicable.

10.6 The Performance Bond (or any balance thereof remaining for the credit of the Contractor) may be
released or refunded to the Contractor on the completion of making good of all defects,
shrinkages or other faults which may appear during the Defects Liability Period and upon the
issuance of the Certificate of Completion of Making Good Defects for the whole of the Works
under clause 47.

10.7 Notwithstanding clauses 10.2 and 10.4, in the event this Contract is terminated under clauses 60
and 61 the said Performance Bond or any balance thereof shall be forfeited.

11.0 INSURANCE OF WORKS

11.1 The Contractor shall, in the joint names of the Government and Contractor, insure against loss
and damage by fire, lightning, explosion, storm, tempest, fiood, ground subsidence, bursting or
overflowing of water tanks, apparatus or pipes, aircraft and other aerial devices or articles
dropped therefrom, riot and civil commotion, all works executed and all unfixed materials and
goods delivered to, placed on or adjacent to the Works and intended thereof (but excluding
temporary buildings, plant, tools and equipment owned or hired by the Contractor or any sub-
contractor) to the full value thereof together with the cost of the design work of the Contractor
(plus any amount which may be specifically stated in Appendix 1) and shall keep such works,
materials and goods so insured until the practical completion of the whole of the Works but
subject to any partial termination of insurance permitted under this Contract in cases of sectional
completion or Partial Occupation by the Government. Such insurance policy or policies shall
provide expressly for payment in the first place to the Government of any insurance monies due
under the policy or policies. •

11.2 The said insurance with or without an excess clause as specified in Appendix 1 shall be effected
with an insurance company approved by the P.D and the Contractor shall deposit with the P.D
the policy or policies and the receipts for the premium paid for such insurance. Where an excess
clause is specified in Appendix 1, the Contractor shall bear the amount of such excess.

11.3 In the event the Contractor fails to renew such insurance as are necessary under this clause, the
Government or the P.D on its behalf may renew such insurance and pay the premium in respect
thereof and deduct the amount so expended including On-cost Charges from any money due or
to become due to the Contractor under this Contract, and failing which such premium shall be
recovered from the Performance Bond or as a debt due from the Contractor.

11.4 Upon the occurrence of any loss or damage to the Works or unfixed materials or g9ods prior to
the completion of the Works from any cause whatsoever, the Contractor shall notwithstanding

11
 that settlement of any insurance claim has not been completed, with due diligence restore,
replace or repair the same, remove and dispose of any debris and proceed with the carrying out
and completion of the Works. All money if and when received from the insurance under this
clause shall be paid in the first place to the Government and then (less only such amounts as are
specifically required in Appendix 1 or elsewhere in the Contract Documents) be released to the
Contractor by installments on the certificate for payment issued by the P.O., calculated as from
the date of receipt of the money in proportion to the extent of the work of restoration, replacement
or repair and the removal and disposal of debris previously carried out by the Contractor. The
Contractor shall not be entitled to any payment in respect of the work of restoration, replacement
or repair and the removal and disposal of debris other than the money received under the said
insurance.

11 .5 The Contractor shall ensure that any insurance policy effected hereto shall only be cancelled by
the insurer after the expiry of thirty (30) days from the date of receipt by the Government of a
written notice from the insurer advising of such impending cancellation PROVIDED THAT the
Contractor has been issued with the Certificate of Completion of Making Good Defects in
accordance with clause 47.

11.6 The Contractor shall not at any time permit or cause to be done any act, matter or thing which
may result in any insurance effected by virtue of this Contract being vitiated or rendered void or
voidable or whereby the rate of the premium on any insurance effected shall be liable to be
increased.

12.0 POSSESSION OF SITE

12.1 No work on this Contract shall commence unless and until the Performance Bond stipulated
under clause 10.1 and such insurance policies as specified under clause 39 shall have been
deposited with the Government. Provided that for the purposes of this cl;:iuse only (but for no
other), if the Contractor shall produce to the Government or the P.D the Performance Bond, if
opted for by the Contractor, and the original cover notes of the said insurance policies and the
receipts of premiums paid, it shall be sufficient discharge of his obligations under this clause.

12.2 Unless the Contract Documents provide otherwise, the Contractor shall be entitled on or before
the Date for Possession to access to and possession of the Site or such part of the Site to enable
the Contractor to commence Works. The Contractor's access to and possession of the Site or
such part of the Site shall not be exclusive but shall be subject to the Government's rights. The
Contractor shall thereupon forthwith commence the Works (but subject to clause 12.1) and
regularly and diligently proceed with and complete the Works on or before the Date for
Completion. The Date for Completion of the Works as referred to under clause 44 shall be
calculated from the said Date for Possession.

12.3 Notwithstanding clause 12.2, possession of Site may be given in sections or in parts and may be
imposed with any restriction as specified in the Appendices or in this Contract.

12.4 In the event of any delay in giving possession of the Site or in giving any section or part of the
Site, whether or not provided in Appendix 1, the P.D may issue instructions to revise the 'Date
for Possession', and the 'Date for Completion' shall be accordingly revised under clause 49.1 (g).
The Contractor however shall not be entitled to claim for any loss, expense or damage caused by
such delay nor shall he be entitled to terminate this Contract

12
 12.5 Notwithstanding clause 12.4, should the delay in giving possession of the whole Site exceed
ninety (90) days from the Date for Possession, tile P.D shall notify the Contractor of the causes
of such delay. Within fourteen (14) days of receipt of such notification, the Contractor may inform
the P.D in writing of his decision which is either -

(a) agree to proceed with the Works when the whole Site is made available, in which case
sub-clause 12.4 shall apply and the Contractor shall not claim any loss or damage
caused by such delay; or
(b) terminate this Contract, without prejudice to any other rights or remedies that the
Government and the Contractor may have as a result of the termination.

12.6 Notwithstanding clause 12.4, should the delay in giving possession of any section or part of the
Site (whether or not provided in clause 12.3) exceeds ninety (90) days from the Date of
Possession or the date the Contractor is scheduled to commence work on that section or part of
the .Works in accordance with the approved programme of Works referred to in clause 13.5, as
the case may be, the P.D shall notify the Contractor of the causes of such delay. Within fourteen
(14) days of receipt of such notification, the Contractor may inform the P.D in writing of his
decision which is either -
(a) agree to proceed with the Works when the section or part of the Works is made available,
in which case clause 12.4 shall apply and the Contractor shall not be entitled to claim any
loss or damage caused by the delay; or
(b) request for the relevant section or part of the Works to be omitted from the Contract. If
the P.D. agrees to such request then the relevant section or part shall be duly omitted
and deemed to be a variation to the Contract. Such variation shall not vitiate the Contract.
If the P.D does not agree to such request then the Contractor shall be entitled to claim for
any loss or expense caused by the delay which exceeds ninety (90) days.

13.0 PERFORMANCE OF THE WORKS

13.1 Submission of Supervision Reports

(a) The Contractor shall submit supervision reports on the following:

(i) works properly done on Site;

(ii) progress of the Works;
(iii) any tests done on the Site;
(iv) safety measures at the Site;
(v) environmental impact assessment of the Works; and
(vi) any other matter as required by the Government,

to the P.D each month, or at any other time as required by the P.O.

(b) All such reports which are to be submitted by the Contractor shall be duly verified and
certified by the Consultants of the Contractor.

13
 (c) The submission of such reports under this clause shall be a condition precedent to any
interim payment that the Contractor shall be entitled under clause 53 of this Contract. In
the event that the Contractor fails to comply with the reqLJirement of this clause, the
Government shall be entitled to withhold the interim payment that the Contractor would
otherwise be entitled to.

(d) The submission of reports by the Contractor pursuant to this clause shall not in any way
absolve the Contractor of any of its liability under this Contract.

13.2 Quality Assurance System

(a) To the extent required by the Contract the Contractor shall institute a quality assurance
system, and for this purpose the Contractor shall submit to the P.D the Contractor's plan
for the quality assurance systems for his approval before the commencement of the
Works.

(b) The parties hereby agree that compliance with such approved quality assurance system
shall not relieve the Contractor from any of his other duties, obligations or liabilities under
the Contract and neither shall the P.D or the Government be liable in any manner
whatsoever notwithstanding the approval by the P.D of the said system.

13.3 Contractor to be Responsible for the Works, Materials, etc.

(a) From the commencement of the Works to the date of the issuance of the Certificate of
Practical Completion for the whole of the Works the Contractor shall, save as in clause
13.3(b), take full responsibility for the care of the Works and for materials, plant and
equipment for incorporation therein and shall at his own cost replace, repair and make
good any damage, loss or injury to the same so that at completion the Works shall be in
good order and condition and in conformity in every respect with the requirements of the
Contract and the P.D's instructions. The Contractor shall also be liable for any damage to
the Works occasioned by him in the course of any operations carried out by him for the
purpose of complying with his obligations under clause 47 hereof.

(b) • If the P.D issues a C~rtificate of Practical Completion or Certificate of Partial Occupation
for any Section or part of the permanent works the Contractor shall cease to be
responsible for the care of that Section or part from the date of issuance of that
Certificate of Practical Completion or Certificate of Partial Occupation when the
responsibility for the care of that Section or part shall pass to the Government. Provided
always that the Contractor shall remain responsible for any damage to such completed
work caused by or as a result of his other activities on the Site.

(c) The Contractor shall take full responsibility for the care of any outstanding work and
materials, plant and equipment for incorporation therein which he undertakes to finish
during the Defects Liability Period until such outstanding work has been completed.

13.4 Accident, failure, etc., to the Works

(a) If any accident, failure or other event occurs due to any cause whatsoever to, or in

14
 connection with the Works or any part thereof either during the execution of the Works or
during the Defects Liability Period, the Contractor shall immediately report the accident,·
failure or event to the P.D. Unless otherwise directed by the P.D generally or in any
particular respect conduct a full investigation into the said accident, failure or event in
order to determine the cause or reason for the accident, failure or event and submit a
report to the Government and the P.D together with his proposals for remedial works in
respect thereof.

(b) The Contractor shall not, however, cause remedial work to be carried out in respect
thereof until directed to do so by the P.D in writing. And upon being so directed the
Contractor shall proceed with the remedial works within fourteen (14) days from the date
of such direction.

(c) Where the Government, its employee or any person or body appointed or 15 authorised
by it carried out any investigation in relation to any accident, failure or other event which
has occurred to, in or in connection with the Works or any part thereof for the purpose of
determining the cause or reason for the said accident, failure or event, the Contractor
shall render all such necessary assistance and facilities as may be required by the
Government, its employee or such person or body including the giving of access to all
specification, designs, records or other available information relating to the Works.

(d) If by reason of any accident, or failure, or other event occurring to in or in connection with
the Works, ot any part thereof either during the execution of the Works or during the
Defects Liability Period, any remedial or other work or repair shall, in the opinion of the
P.D be urgently necessary for the safety of the Works or the public and the Contractor
fails to immediately do such work or repair, the Government may employ and pay other
persons to carry out such work or repair as the P.D may consider necessary. If the work
or repair so done by the Government is work which, in the opinion of the P.D, the
Contractor was liable to do at his own expense under the Contract, all costs and charges
properly incurred by the Government in so doing shall be recoverable from the Contractor
by the Government, or may be deducted by the Government from any monies due or
which may become due to the Contractor. Provided always that the P.D shall, as soon
after the occurrence of any such emergency as may be reasonably practicable, notify the
Contractor thereof in writing.

13.5 Programme of Works

(a) Within fourteen (14) days from the receipt of the Letter of Acceptance the Contractor shall
submit to the P.D for his approval -

(i) a programme showing the order in which he proposes to carry out the Works
having regard to the provisions of clause 12.3; and
(ii) a general description in writing, of the arrangements and methods of construction
which the Contractor proposes to adopt for the carrying out of the Works. -

(b) The P.D shall within twenty-one (21) days after receipt of the Contractor's programme:

15
 (i) approve the programme in writing; or
(ii) reject the programme in writing with reasons and/or request modifications; and/or
(iii) request the Contractor to supply further information to clarify or substantiate the
programme or to satisfy the P.D as to its reasonableness having regard to the
Contractor's obligations under the Contract,

PROVIDED THAT if none of the above actions is taken within the said period of twenty-
one (21) days the P.D shall be deemed to have approved the programme as submitted.

(c) The Contractor shall upon receipt from the P.D any request under clause 13.5(b)(ii) or (iii)
resubmit a modified programme or provide further information as requested.

(d) If at any time it should appear to the P.D that the actual progress of Works does not
conform to the approved programme referred to hereinbefore the Contractor shall
produce, at the request of the P.O., a revised programme showing the modifications to
the approved programme necessary to ensure completion of.the whole Works within the
time for completion provided for in clause 44 hereof or extended time granted pursuant to
clause 49 hereof.

(e) The submission to and approval by the P.D or the P.D's representative of such
programme or the furnishing of such particulars shall not relieve the Contractor of any of
his duties or responsibilities under this Contract.

14.0 DESIGN

14.1 Design

(a) The Contractor shall be fully responsible for the design, execution and maintenance of
the Works/portion of the Works for which his design/alternative design have been·
accepted by the Government. The Contractor further guarantees to the Government that
the design, materials and workmanship of the Works or portion of the Works complies
with the Government's Requirements as well as are suitable and fit for purpose and
independent of fault.

(b) Any reference to the design which the Contractor has prepared or shall prepare or issue
for the Works shall include the reference to any design which the Contractor has caused
or shall cause to be prepared or issued by others.

(c) Where any part of the Works has been designed by or on behalf of the Government, and
that design has been included in the Government's Requirements, the Contractor shall
check the design and accept responsibility for it, and shall ensure that such design shall
be suitable, functional, safe and compatible with the design and specifications of the
Works, having first obtained the approval of the P.D for any modificatiqns which the
Contractor considers to be necessary. Notwithstanding thereto, the Contractor shall
remain liable for the Works.

16
 (d) Where the Contractor has to integrate its design and Works to the existing structure, the
Contractor shall ensure that design and works shall be suitable, functional, safe, and
compatible with fhe existing structure and fit for the purpose and meet the Government's
Requirements.

(e) The Contractor shall take full and unequivocal responsibility for the functionality,
suitability, compatibility and safety of the design and for the adequacy, stability and safety
of all site operations and methods of construction.

(f) Where any Act of Parliament, Regulation or By-law requires that a separate check of the
design or a test shall be carried out prior to the construction of any permanent and
temporary Works. The Contractor shall arrange and carry out such check or test at his
•own costs.

(g) The approval or acceptance of the Contractor's design by the Government under this
Contract shall not absolve the Contractor from its responsibility and the Contractor shall
be liable and shall fully indemnify and keep the Government indemnified for any design
defects, damage, inadequacies or insufficiency of such design.

(h) The Contractor warrants to the Government that the Works shall be carried out in
accordance with -

(i) the terms and conditions of this Contract;

(ii) the specifications and standards as approved by the Government;

(iii) all by-laws and local authority building regulations;

(iv) sound engineering practice or other relevant best industry practice;

and that such design shall in all respects fits and conforms with the purposes of the
Works as described in the Government's Requirements.

[Note: Please substitute where appropriate: building, road, structure, and services.]

14.2 Design Guarantee

(a) The Contractor shall deposit to the Government a '""Design Guarantee as per Appendix
_ as a security to the Contractor's obligations under this Contract. The Design
Guarantee shall be effective for the duration of five (5) years commencing from the date
of practical completion ("the Design Guarantee Period").

17
 (b) If any defect or damage shall occur to the Works or any part thereof as a result of any
defect, fault, insufficiency or inadequacy in the design including workmanship, material or
equipment arising from design default during the Design Guarantee Period, the
Government shall issue to the Contractor a notice specifying the default and requiring the
Contractor to remedy the same within the period specified at the Contractor's own cost
and expense. If the same is not remedied, the Government shall be entitled, without
prejudice to any other rights or remedies it may possess against the Contractor under this
Contract or at law, to claim and recover from the Contractor any payment for any loss
and/or damages suffered or any other expenses incurred as a result thereof. •

(c) Notwithstanding the above, the Government may elect to remedy the defect, fault,
insufficiency or inadequacy in the design as at the time such defect, fault, insufficiency,
inadequacy is established and the Government shall be entitled to deduct the amount up
to the limit of sum certified by the P.D to be the sum required to remedy the same from
any money due or to become due to the Contractor under this Contract, and failing which
such sum shall be recovered from the Performance Bond or as a debt due from the
Contractor.

14.3 Design Guarantee Bond

(a) The Contractor shall provide to the Government a banker's guarantee issued by an
approved licensed bank/financial institution of the sum of Ringgit
................................................ , . .. . (RM .................... ) (hereinafter referred to as
"the Design Guarantee Bond") substantially in the form as in Appendix upon or before the
issuance of the Certificate of Practical Completion of the Works as a security for the
Contractor's obligations and warranties under clause 14. Such Design Guarantee Bond
shall remain valid for a period of five (5) years from the date of practical completion of the
Works.

(b) If any defect or damage shall occur to the Works or any part thereof as a result of any
defect, fault, insufficiency, imperfection, shrinkages or inadequacy in the designs
including workmanship, materials or equipment which has become defective- then the
approved licensed bank / financial institution issuing the Design Guarantee Bond
pursuant to clause (a) above shall pay to the Government, on demand by the
Government in writing and notwithstanding any objection by the Contractor or any other
third party, the sum of .............................................. being equal to 5% of the cost of
the Works or such part thereof as may be demanded.

(c) If the Design Guarantee Bond is not deposited with the Government in accordance with
clause (a) above, the Government shall have the right to claim from the Performance
Bond the sum of RM ............................................. being equal to 5% of the cost of
the Works or such part thereof as may be demanded.

(d) If a payment is made to the Government pursuant to clause (b), the Contractor shall
ensure that further security in the form of an additional Design Guarantee Bond for an
amount no less than the amount so paid to the Government shall be issued to
theGovernment prior to or upon the date of such· payment. If any of the issued Design
Guarantee Bond were to expire prior to the validity period, a replacement Design·
Guarantee Bond shall be issued to the Government on or prior to the date of expiry of the
first mentioned Design Guarantee Bond in an amount not less than the amount of that

18
 Design Guarantee Bond.

15.0 MATERIALS, GOODS AND WORKMANSHIP

15.1 Compliance with Government's Requirements

(a) All materials, goods and workmanship shall, so far as procurable, be of the respective
kinds and standards described in the Government's Requirements, or, if not therein, as
specifically described in the Contractor's Proposals or specifications referred to in clause
6.3: PROVIDED THAT the Contractor shall not substitute anything so described without
the P.D's consent in writing, which consent shall not be unreasonably delayed or
withheld. No such consent shall relieve the Contractor of his other obligations.

(b) The Contractor shall upon the request of the P.D provide him with the relevant certificates
or.vouchers to prove that the materials and goods comply with clause 15.1.

15.2 Inspection and Testing of Materials, Goods and Workmanship

(a) Further to the Contractor's obligations under clause 14.1 (e), the Contractor shall submit
to the P.D for his approval proposals for inspecting the design and setting out of the
Works and testing the materials and workmanship to ensure that the Contractor's
obligations under the Contract are fulfilled.

(b) The Contractor shall carry out the inspection and tests approved under clause 15.2(a) or
elsewhere in the Contract and such further tests as the P.D may reasonably require,
including to open up for inspection any work covered up or to carry out any test of any
materials or goods (whether or not already incorporated in the Works or any executed
Works).

(c) The P.D may issue instructions to the Contractor to remove from the Site or rectify any
work, goods which are not in accordance with this Contract at his own cost.

(d) The Contractor shall, as may be required by the P.D from time to time, provide such
assistance, instruments, machines, labour and materials as are normally required for the
purpose of examining, measuring and testing of any work, as well as the quality, weight
or quantity of the· materials used; and shall supply samples of materials before
incorporation in the Works for testing.

(e) Unless the Contract otherwise provides, the cost of making any test shall be borne by the
Contractor if such test is:

(i) proposed by the Contractor under clause 14.1 (e) or clause 15.2(a); or

19
 (ii) clearly intended by or provided for in the Contract.

(f) Notwithstanding anything in clause 15.2(e), if the Contractor carries out any further test
as required by the P.D pursuant to clause 15.2(b) and the result of such test shows the
workmanship or materials is not in accordance with the provisions of the Contract, then
the cost of such test shall be borne by the Contractor. But if the result of such test shows
the workmanship or materials comply with the provisions of the Contract, then the cost of
such test shall be borne by the Government.

16.0 RESTRICTION AND PROCEDURE ON USE OF IMPORTED MATERIALS AND GOODS

16.1 The Contractor shall use local goods/materials as listed in the 'Senarai Bahan/Barangan Buatan
Tempatan' issued by IKRAM QA Services Sdn. Bhd. And/or issued by SIRIM QA Services Sdn.
Bhd., whichever is relevant. If the Contractor fails to comply with this requirement,· the
Government may reject the goods/materials which are found to be not in compliance with this
requirement.
16.2 For local goods/materials not listed as aforesaid, such goods/materials may be allowed if prior
testing and certification from IKRAM QA Services Sdn. Bhd. Or SIRIM QA Services Sdn. Bhd.,
whichever is relevant, has been obtained. Where such testing cannot be carried out by !KRAM
QA Services Sdn. Bhd. Or SIRIM QA Services Sdn. Bhd. The Contractor may, with the P.D's
prior approval, have the testing done by another agency.

16.3 Under no circumstances shall the Contractor be permitted to incorporate or supply imported
materials, plant, equipment, vehicles or other goods into the Works or forming part of the scope
of the Works except those approved by the Government, prior to the execution of the Contract.
The Contractor shall at his own cost entirely substitute any materials, plant, equipment, vehicles
or other goods proposed to be imported but not approved by the Government, with suitable local
materials, plant, equipment, vehicles or other goods, including making any necessary
subsequential changes or adjustment to the design of the Works to accommodate such
substitution, all to the concurrence of the P.D Such substitution, any necessary subsequential
changes to the design of the Works and the P .D's concurrence thereto shall not prejudice or
affect the Contractor's obligation and liability to guarantee the design under clause 14.

16.4 The Contractor shall ensure that the procurement of approved imported materials, plant,
equipment, vehicles or other goods are obtained directly from the country of origin based on
F.O.8. or other similar basis. The transportation and insurance of such imported materials, plant,
equipment, vehicles or other goods from the country of origin to the Site shall be arranged by the
Contractor through the Government's Multi Modal Transport Operators (hereinafter referred to as
MTO) as listed in Appendix 7. The Contractor shall allow in his tender all costs and time required
in complying with the requirements of this clause including the cost required for the services
provided by the MTO.

16.5 The Contractor shall submit documentary evidence of compliance with this clause. to the P.D
within one (1) month from the date of each delivery to the Site of such materials, plant,
equipment, vehicles or other goods.

20
 17.0 CONSTRUCTIONAL PLANT, EQUIPMENT, VEHICLES AND MACHINERIES

17.1 The Contractor shall pay all port dues including (but not by way of limitation) wharfage dues,
pilotage fees, anchorage, berthage and mooring fees, quarantine dues, loading porterage and
overtime fees for constructional plant, equipment, vehicles and machineries for use directly in
connection with the construction, completion of the works brought into and 21 ispatched from
Malaysia by the Contractor (or in his name by agents).

17.2 The Contractor shall furnish to the P.D all such shipping documents, invoices and other
documentation as may be required by the Customs Authorities in connection with the importation
of goods, materials, constructional plant, equipment, vehicles and machineries.

17 . 3 In the case of constructional plant, equipment, vehicles, and machineries imported on the
Contractor's behalf by importing agents and the like both the shipping documents and the
invoices of the original suppliers or manufacturers must indicate clearly that the consignment is
for the Contractor's account.

17.4 The procedure in respect' of the requirements of the foregoing shall be determined by the
Customs Authorities. The Contractor shall make written application to the P.D and shall provide
the relevant documentation of all constructional plant, equipment, vehicles and machineries to be
imported into Malaysia not less than forty-five (45) days before the arrival of the said
constructional plant, equipment, vehicles and machineries.

17.5 The Contractor shall pay all charges and other expenses in connection with the landing and
shipment of all constructional plant materials and other things of whatsoever nature brought into
or 21 ispatched from Malaysia for the purpose of the Contract.

17.6 The Contractor shall make his own arrangement in obtaining clearance through the Customs of
constructional plant, equipment, vehicles and machineries. However, if required, the P.D's
assistance may be sought.

17.7 Under this Contract the Contractor shall be required to furnish all lists of constructional plant,
equipment, vehicles and machineries to the P.D whether the constructional plant, equipment,
vehicles and machineries are hired or acquired.

18.0 NON~REMOVAL OF MATERIALS AND GOODS ON SITE

18.1 Exclusive Use for the Works

(a) All equipment, temporary works, materials for temporary works or other goods or
materials provided by the Contractor shall, when brought onto the Site, be deemed to be
exclusively intended for the execution of the Works.

21
 (b) The Contractor shall not without the written consent of the P .D (which consent shall not
unreasonably be withheld where the items in question are no longer immediately required
for the purposes of the completion of the Works) remove such equipment, temporary
works, materials for temporary works or other goods or materials or any part of the same
except for the purpose of moving it within the Site.

18.2 Passing of Proprietary Rights and Vesting

Proprietary rights and ownership in goods or materials which form part of the Works, equipment,
temporary works and materials for temporary works, shall pass to the Government when payment
•is made for the same in accordance with clause 53 and such property shall be deemed to be the
property of the Government.

18.3 Government not liable for Oamage

The Government shall not at any time be liable for loss or damage to any of the equipment,
temporary works, materials for temporary works or other goods or materials nor for any_ loss,
expense, costs, damages, liability or claim arising from the presence of use of the equipment,
temporary works, materials for temporary works or other goods or materials except and to the
extent that the same is due to any act or neglect of the Government or of any person for whom
the Government is responsible.

18.4 Incorporation of clause in sub-contract

The Contractor shall, when entering into any sub-contract for the execution of any part of the
Works, incorporate in such sub-contract (by reference or otherwise) the provisions of this clause
in relation to equipment, temporary works, materials for temporary works or other goods or
materials brought onto the Site by the sub-contractor.

19.0 SITE BOUNDARIES AND SETTING OUT

19.1 The P.D shall define the boundaries of the Site and shall determine any levels, boundary stones
and any other points of reference which may be required by the Contractor for the execution of
the Works. The P.D shall also furnish the Contractor such information to enable the Contractor to
set out the Works at ground level.

19.2 Notwithstanding clause 19.1, the Government gives no warranty in any manner whatsoever for
the information either as to their accuracy or sufficiency or as to how the same shall be
interpreted and the Contractor, when he makes use of and interprets the same shall do so at his
own risk and the Government shall not be liable if such information is inaccurate or insufficient.

19.3 The Contractor shall use and interpret the information at his own risk and shall be responsible for
the true and proper setting out of the Works and for the correctness of the positions, levels,
dimensions and alignments of all parts of the Works and for the provisions of all necessary
instruments, appliances and labour in connection therewith.

19.4 If at any time during the progress of the Works any error in the position, levels, dimensions or
alignments of any part of the Works is discovered, the Contractor shall, at his own expense,
rectify such error notwithstanding that the error arises from inaccurate or insufficient information
given by th·e Government. ,·

22
 19.5 The Contractor shall provide the P.D at no cost such information relating to the setting out as may
be required by the P:D from time to time.

20.0 ANTIQUITIES

20.1 All fossils, coins, antiquities and other objects of interest or value which may be found on the Site
or in excavating the same during the progress of the Works shall become the absolute property of
the Government and upon discovery of such an object the Contractor shall forthwith -

(a) not disturb the object and shall cease work if and in so far as the continuance of the work
would endanger the object or prevent or impede its excavation. or its removal;

(b) take all steps which may be necessary to preserve the object in the exact position and
condition in which it was found; and

(c) inform the P.D of the discovery and precise location of the object.

20.2 The P.D shall issue instructions in regard to what is to be done concerning the object reported by
the Contractor und.er clause 20.1 and (without prejudice to the generality of his power) such
instructions may require the Contractor to permit the examination, excavation or removal of the
object by a third party. Any such third party shall for the purpose of clause 39 be deemed to be a
person for whom the Government is responsible and not to be a sub-contractor.

20.3 If compliance with the provisions of clause 20.1 or with an instruction issued under clause 20.2
has involved the Contractor in direct loss and/or expense for which he would not be reimbursed
by a payment made under any other provisions of this Contract then the amount of such loss
and/or expense shall be added to the Contract Sum.

21.0 INSPECTION OF SITE

21.1 The Contractor shall be deemed to have inspected and examined the Site and its surroundings
and to have satisfied himself and allowed in the Contract Sum as to the following:

(a) the nature of the ground and subsoil;

(b) the form and nature of the Site;

(c) the extent and nature of the work, materials and goods necessary for the completion of
the Works;

(d) the means of communication with and access to the Site;

(e) the accommodation he may require; and

(f) in general to have obtained for himself all necessary information as to risks,

23
 contingencies and all circumstances influencing and affecting his tender.

21.2 Any information or document forwarded by the Government to the Contractor shall not relieve the
Contractor of his obligations under the provisions of this clause.

22.0 ACCESS TO THE SITE

22.1 The P.D, and any person 24authorized in writing by him shall be entitled at all times to enter and
inspect the Site, factories, workshops or other places of the Contractor or any sub-contractor or
supplier where any equipment, materials, goods or work are being manufactured, fabricated,
assembled, prepared or stored for this Contract.

22.2 Where any such equipment, materials, goods or works are being prepared or stored in the
factories, workshops or other places of a sub-contractor or supplier, the Contractor shalf, by a
term in the sub-contract, so far as possible secure a similar right of access to those factories,
workshops or other places for the P.D and any person 24authorized by him, and shall take all
reasonable steps required of him by the P.D to enforce or assist in enforcing such right. •

22.3 The Contractor shall, in accordance with the requirements of the P.D, afford all reasonable
access and facilities to any person engaged by the Government for purposes of executing any
work on or near the Site. •

23.0 VARIATIONS

23.1 The term 'variation' means a change in the Government's Requirements which makes necessary
the alteration or modification of the design, quality or quantity of the Works as described by or
referred to therein and affects the Contract Sum, including:

(a) the addition, omission or substitution of any work,

(b) the alteration of the kind or standard of any of the materials, goods to be used in the
Works; and

(c) tlie removal from the Site of any work executed or materials or goods brought thereon by
the Contractor for the purposes of the Works other than work, materials or goods which
are not in accordance with this Contract.

23.2 The P.D may issue instructions effecting a variation by way of a Variation Order. The Contractor
shall forthwith comply with the Variation Order. No variation instructed by the P.D under this
clause shall in any way vitiate or invalidate the Contract but the fair and reasonable value (if any)
of all such variations shall be taken into account in ascertaining the amount of the Contract Sum,
unless such variation is necessitated by the Contractor's default. PROVIDED THAT any variation
which alters or modifies the design of the Works shall be with the consent of the Contractor,
whose consent shall not be unreasonably delayed or withheld.

23.3 Notwithstanding clause 23.2, if in the opinion of the P.D the variation is necessary for the purpose

24
 of suitability, functionality and safety of the Works, the Contractor shall effect the variations. For
the purpose oftnis clause, what constitutes "suitability, functionality and safety of the Works" shall
be solely determined by the P.D and such determination shall for all intents and purposes be final
and conclusive. Notwithstanding thereto the Contractor shall remain responsible for the design of
the works as provided under clause 14.

23.4 Where a variation under clause 23.3 results in extra cost, the said extra cost shall be borne by
the Contractor. However, if the variation results in a reduction in cost, the Contract Sum shall be
accordingly reduced.

23.5 Any variations made under this clause shall not relieve the Contractor of his obligations under
clause 14.1(a).

24.0 VALUATION OF VARIATIONS

24.1 The valuation of additional or substituted work shall be consistent with the value of works of
similar character set out in the Contact Sum Analysis or Contract Schedule of Rates, making due
allowance for any change in the conditions under which the work is carried out or any significant
change in the quantity of the work so set out. Where there is no work of a similar character set
out in the Contract Sum Analysis or Contract Schedule of Rates a valuation shall be made by the
P.O.

24.2 The valuation of the omission of work shall be in accordance with the values in the Contract Sum
Analysis or Contract Schedule of Rates.

24.3 Any valuation of work under clause 24.1 and 24.2 shall include allowance for any necessary
addition to or reduction of the Site administration, Site facilities and temporary works.

24.4 Where an appropriate basis of a valuation of additional or substituted work is Day work, the
valuation shall comprise the prime cost of such work plus 15% which shall include the provision
of Site administration, Site facilities and temporary works and for profit. PROVIDED THAT as a
condition precedent to any right to any payment the Contractor shall produce vouchers specifying
the time daily spent upon the work, the workmen's names, the plant and the materials employed
to the P.D for verification not exceeding seven (7) days after the work has been executed.

24.5 The valuation made under this clause shall not include any claims for direct loss or expense
notwithstanding that such variation affects the regular progress of the Works.

24.6 Upon determination of the valuation of the variation, the Contract Sum shall be revised
accordingly by way of addition or deduction.

25.0 PROVISIONAL SUMS

25.1 The term Provisional Sum included in the Contract Documents means a sum for work to be

25
 executed or the supply of materials or goods which cannot be entirely foreseen, defined or
detailed before the Date of Tender and the P.D shall issue instruction to the Contractor in regard
to the expenditure of such Provisional Sum.

25.2 The value of works which are executed by the Contractor in respect of a Provisional Sum shall be
ascertained in accordance with clause 24. At the settlement of the accounts the value of such
work executed by the Contractor shall be set against the Provisional Sum and the balance shall
be added to or deducted from the Contract Sum. If the Provisional Sum is not used either wholly
or partly, the unused amount shall be deducted from the Contract Sum.

26.0 EMPLOYMENT OF WORKMEN

26.1 The Contractor shall employ in the execution of the Contract only Malaysian citizens as 1r✓orkmen.
If in any particular trade or skill required to complete this Contract, the Contractor can show to the
satisfaction of the P.D that Malaysian citizens are not available, then the Contractor may employ
non-Malaysian citizens subject to the approval of the relevant authorities.

26.2 The Contractor shall on the commencement of the Works furnish to the Jabatan Tenaga Kerja of
the state in which this Contract is performed all particulars connected with this Contract and such
returns as may be called for from time to time in respect of labour employed by him and his sub-
contractors (including 'labour only' sub-contractors) on the execution of this Contact in
accordance with the requirements of the Employment Act 1955, Employment (Restriction) Act
1968, and Internal Security (Registration Of Labour) Regulation 1960 or any subsequent
modification or re-enactment thereof. The Contractor shall maintain on the Site at all times during
the progress of the Works an up-to-date register containing particulars of all workers employed by
him.

26.3 The Contractor shall cause his sub-contractors including 'labour-only' sub-contractors to comply
with clause 26.

27.0 COMPLIANCE WITH EMPLOYMENT ACT 1955, ETC.

The Contractor shall comply and shall cause his sub-contractors including 'labour only' sub-contractors to
comply with all the requirements of the Employment Act 1955, Employment (Restriction) Act 1968,
Employees Provident Fund Act 1991, the Industrial Relations Act 1967 and any other law relating to the
employment of workmen, or any subsequent modification or re-enactment thereof. PROVIDED THAT the
Contractor shall not be entitled to any claim for additional costs and payments whatsoever in respect of
his compliance with this clause.

28.0 EPIDEMICS AND MEDICAL ATTENDANCE

28.1 The Contractor shall maintain the Site in clean and sanitary condition and shall comply with the
requirements of all relevant laws and with any instructions and requirements issued by the

26
 relevant authorities. In the event of any outbreak of illness of an epidemic nature, the Contractor
shall comply with and carry out such regulations, orders and requirements as may be made by
the Government or the local medical or health authorities for the purpose of dealing with and
overcoming the same.

28.2 The Contractor shall ensure that sufficient first aid kits are made available at suitable locations on
the Site and shall instruct an adequate number of person in their use. The names of the persons
so instructed shall be made known to all employees of the Contractor.

29.0 DAYS AND HOURS OF WORKING

29.1 No work shall be done on:

(a) the weekly day of rest;

(b) any public holiday which is recognized in the state where this Contract is being carried
out; or

(c) between the hours of six in the evening and six in the following morning,

without the prior written consent of the P.D and such consent shall not be unreasonably withheld
or delayed.

29.2 In the event that the written application of the Contractor is approved by the P.D under clause
29.1, the Contractor shall comply with all requirements of the Employment Act 1955 in regard
thereto and shall bear all cost for compliance therewith including payment of wages.

30.0 WAGES, BOOKS AND TIME SHEETS

30.1 The Contractor shall keep and shall cause his sub-contractors (including 'labour only' sub-
contractors) to keep proper wages books and time sheets showing the amount of wages paid to
and the number of hours worked by every workman employed by him and his sub-contractors
as aforesaid in and for the performance of this Contract.

30.2 The Contractor shall produce such wages books and time sheets on demand for inspection by
any persons duly 27uthorized by the P.D.

30.3 The Contractor shall furnish the P.D or his duly 27uthorized representative such information
relating to the wages and conditions of employment of such workmen as the P.D may from time
to time require.

27
 31.0 DEFAULT IN PAYMENT OF WAGES

31.1 In the event of default being made in the payment of-

(a) wages; and/or

(b) Employees Provident Fund Contributions,

of any workman employed by the Contractor or his sub-contractors, including 'labour only' sub-
contractors in and for the performance of this Contract then the P.D shall make payment to the
Director General of Labour and/or Employees Provident Fund Board, as the case may be.

31.2 Such payment made by the P.D under clause 31.1 and On-cost Charges shall be deducted from
any money due or to become due to the Contractor under this Contract, and failing which such
payment shall be recovered from the Performance Bond.

32.0 DISCHARGE OF WORKMEN

32.1 The Contractor shall employ in and about the execution of the Works only such persons as are of
good character, careful, skilled anc:l experienced in their respective vocations and trades.

32.2 The P.D shall be at liberty to object to and require the Contractor to remove immediately from the
Site any person employed by the Contractor in or about the execution of the Works who in the
opinion of the P.D misconducts himself or is incompetent or negligent in the proper performance
of his duties and whose continued presence is undesirable or unacceptable. Such person shall
not again be employed upon the Works without the prior written permission of the P.D;

32.3 Any person so removed from the Works shall be replaced without delay by a substitute approved
by the P.D; PROVIDED THAT the Contractor shall not be entitled to any claim for any expense
whatsoever incurred by him in respect of any direction given by the P.D under this clause.

33.0 EMPLOYEES' SOCIAL SECURITY ACT 1969

33.1 Without prejudice to his liability to indemnify the Government under clause 14, the Contractor
shall register or cause to register all local workmen employed in the execution of the Works and
who are subject to registration under the Employees' Social Security Scheme ("the SOCSO
Scheme") in accordance with the Employees' Social Security Act 1969 or any subsequent
modification or re-enactment of the said Act. For the purpose of this clause, the term "local
workmen'' shall include workmen who are Malaysian citizens and those who have permanent
resident status.

33.2 The Contractor shall submit his Code Number and Social Security Numbers of all workers on the
Site required to be covered under the Employees' Social Security Act 1969 to the P.D for

28
 checking.

33.3 The Contractor shall make payment of all contributions from time to time on the first day on which
the same ought to be paid and until the end of the Defects Liability Period and it shall be the duty
of the Contractor to produce to the P.D contribution cards or stamp vouch-ers as evidence of
payment of such contribution, whether demanded or not.

33.4 If the Contractor fails to comply with the terms of this clause, the Government or the P.D on its
behalf may without prejudice to any other remedy available to Government for breach of any of
the terms of this Contract:

(a) withhold an amount from any money which would otherwise be due to the Contractor
under this Contract and which in the opinion of the P.D will satisfy any claims for
compensation by workmen that would have been borne by SOCSO had the Contractor
not made default in maintaining the contribution; and/or

(b) pay such contributions as have become due and remain unpaid and deduct the amount
of such contributions including On-Cost Charges from any money due or become due to
the Contractor under this Contract, and failing •which such contributions shall be
recovered from the Performance Bond or as a debt due from the Contractor.

34.0 INDEMNITIES TO GOVERNMENT IN RESPECT OF CLAIMS BY WORKMEN

34.1 The Contractor shall be liable for and shall indemnify and keep indemnified the Government and
its officers or servants from all liabilities arising out of claims by any and every workmen
employed in and for the performance of this Contract for payment of compensation under or by
virtue of the Workmen's Compensation Act 1952 and the Employees' Social Security Act, 1969 or
any other law amending or replacing such law and from all costs and expenses incidental and
consequential thereto.

34.2 The Contractor shall effect and maintain throughout the Contract Period an Employer's Liability
Insurance or Workmen Compensation Insurance or any other applicable insurance for its
personnel, servants, agents or employees required under the laws of Malaysia.

35.0 CONSULTANTS

35.1 The Contractor shall enter into an agreement with each consultant and shall deposit eight (8)
copies of the Contract entered to the P.D as a condition precedent before the P.D approve the
first interim payment.

35.2 The Contractor shall only employ local consultants for the design and supervision of the Works
and the management of the Project. Under no circumstances will the Contractor be permitted to
employ foreign consultants except where there are no local consultants with the required
expertise and special exemption had been obtained from the Government, prior to the execution
of the Contract.

35.3 The Contractor shall submit a complete list of consultants to be employed for the Works stating
their job and their obligations. The Contractor shall ensure that the consultants are efficient,

29
 suitably qualified and experienced and are registered with their respective professional Boards.

35.4 The Contractor shall not employ any other professionals (other than those named in his proposal)
without the prior consent of the P.D The Contractor's attention is also drawn to the fact that the
said consultants shall be retained throughout the Contract Period for the supervision of the Works
arid they shall not be discharged without the consent of the P.O. All as-built drawings required for
the Works shall be certified by the relevant consultant.

35.5 Any action, decision, instruction or consent taken, made or given by the Government or the P.D
as the case may be under this clause shall not in any way whatsoever relieve the Contractor of
any of his obligations under this Contract.

36.0 DIRECT PAYMENTS TO CONTRACTOR'S CONSULTANTS

36.1 Payment to Consultants

(a) For purposes of payment to the consultant, the Contractor and the Consultant shall enter
into an Irrevocable Deed of Assignment for the assignment of any money due to the
Consultant to be paid directly by the Government. The Irrevocable Deed of Assignment
shall provide for an escrow account to be opened jointly by the Contractor and consultant
at a bank licensed in Malaysia.

(b) The Contractor shall submit to the Government the escrow account number and the
Government shall pay the amount recommended by the consultant to the P.D as the
amount payable to the consultants directly into the said escrow account. Any payment
made by the Government into the escrow account shall be deemed to be a payment
under this Contract. Any dispute between the Contractor and th.e consultant in relation to
the amount· due to the escrow account shall not affect the continuous payment by the
Government into the escrow account pursuant to this Contract and the Government shall
not be a party to any such dispute.

(c) The Contractor shall recommend to the P.D the amount payable to the consultants. The
P.D in issuing Interim Certificates under clause 53 or the Final Certificate under clause 54
of the Contract shall state separately the amount of interim or final payment due to each
consultant which amount subject to clause 36.1 (d), shall be paid by the Government
direct to the consultant. The amount paid by the Government direct to the consultant shall
be deemed to be a payment to the Contractor by the Government under and by virtue of
this Contract, provided that if the P.D received written notice of dissatisfaction from the
consultant not later than two (2) weeks before the issuance of the next interim certificate
or final certificate regarding the amount certified by the Contractor then the P.D may
certify and the Government may make direct payment to the consultant in accordance
with the clause 36.1.

(d) The amount payable to the consultant by the P.D shall include fees for basic services and
supervision as specified in the Consultancy Agreement. Supervision fees shall be paid for
supervision of Works carried out during the Contract Period and approved extended
period subject to clause 50. Any additional costs for supervision of Works beyond the

30
 approved period shall be borne by the Contractor.

(e) Subject to the relevant provisions in the Consultancy Agreement, the Contractor shall be
entitled to be paid and the Government may pay to the Contractor out of any money
otherwise due to a Consultant:

(i) any amount which the Government or the P.D on its behalf in exercise of any
right under this Contract has deducted from any money due to the Contractor
and such deduction is in respect of some act or default solely of the Consultant,
his servants or agents;
• (ii) any amount agreed by the Consultant as due to the Contractor, or any amount
awarded in arbitration or litigation in favour of the Contractor which arises out of
or under the Consultancy Agreement; and
(iii) the amount of any claim for loss and/or expense actually incurred by the
Contractor by reason of any breach or failure to observe the provisions of the
Consultancy Agreement by the Consultant.

Any amount paid to the Contractor in accordance with this clause shall be deemed to be
a payment to the Consultant under the Consultancy Agreement.

(f) Nothing in this clause nor anything else contained in this Contract shall render the
Government in any way liable to any Consultant nor relieve the Contractor from his
obligations and liabilities under the Contract.

36.2 Responsibilities of Contractor to Consultants

(a) In and for the purpose of this Contract, the Contractor shall be fully responsible to ensure
that the Consultants shall conform with the terms and conditions of this Contract and
shall be fully responsible for the acts, defaults or breach of any terms and/or conditions of
this Contract by the Consultants on their part in the same way as for his own or those of
other sub-contractors or suppliers engaged by himself, and the Government shall in no
circumstances be liable to the Contractor for the default of any Consultant.

(b) In the event of repudiation or abandonment of his consultancy services by any

Consultant, or the determination by the Contractor of the employment of the Consultant
for any reason whatsoever under the Consultancy Agreement or as directed by the P.D,
the Contractor shall with the consent of the P.D (such consent shall not be unreasonably
withheld) employ another competent consultant to complete the consultancy services.
Provided that in any of such events the Contractor is entitled to be paid the same sum for
the services to be executed, as would have been payable had the original Consultant
completed the consultancy services without any default on his part.

(c) All notices with regard to termination of the Consultancy Agreement shall not be issued
without the prior consent of the P.O. Where in the opinion of the P.D the Consultant has
defaulted due to any reason as provided for under the Consultancy Agreement, the PD
may instruct the Contractor to determine the employment of the Consultant, and the

31
 Contractor shall forthwith determine the employment of the Consultant.

37.0 SUB-CONTRACTTING AND ASSIGNMENT OF COUNSULTANT'S RESPONSIBILITY

37.1 The Contractor shall ensure that the Consultant employed for the design and supervision of the
Works shall not assign or sub-contract the said design and supervision responsibility to other
Consultant without prior written consent of the P.O.

37.2 Any such consent, if given, shall not relieve the Contractor from any liability or obligation under
. this Contract and he shall be responsible for the due observance by such sub-consultant, of all
the terms, stipulations and conditions under this Contract.

37.3 Notwithstanding any sub-contract or assignment made pursuant to this clause, the Contractor
shall be fully responsible for the acts, defaults or neglects of any sub-consultant, his agents,
servants or workmen as if they were the acts, defaults or neglects of the Contractor.

37.4 It shall be a condition in any sub-contract or assignment which has been consented to by the P.D
that upon termination of the Consultant's employment by the Contractor, the employment of the
sub-consultant under the sub-contract or assignment shall terminate immediately. No claim
whatsoever shall be made by the Consultant and/or sub-consultant against the Government for
any work done.

38.0 GOVERNMENT'S INDEMNITY IN RESPECT OF INJURY TO PERSONS AND DAMAGE TO

PROPERTY

38.1 The Contractor shall perform all of its obligations under this Contract at its own risk and releases,
to the fullest extent permitted by law, the Government and their agents and servants from all
claims and demands of every kind resulting from any accident, damage, injury or death arising
from the carrying out of the Works, except where such accident, damage, injury or death is
caused or contributed to by any act or omission or negligence of the Government or its agents
and servants. The Contractor expressly agrees that in the absence of any such act, omission or
negligence as aforesaid, the Government shall have no responsibility or liability whatsoever in
relation to such accident, damage, injury or death. •

38.2 The Contractor shall indemnify and keep indemnified the Government from and against all
actions, suits, claims or demands, proceedings, losses, damages, compensation, costs (including
legal cost), charges and expenses whatsoever to which the Government shall or may be or
become liable in respect of or arising from-

(a) the negligent use, misuse or abuse by the Contractor or its personnel, servants, agents
or employees appointed by the Contractor;

(b) any loss or damage to property or injury of whatsoever nature or kind and howsoever or
wherever sustained or caused or contrib_uted to by carrying out of the Works by the
Contractor Jo any person and not caused by the negligence or willful act, default or
omission of the Government, its agents or servants; or

32
 (c) any loss, damage or injury from any cause whatsoever to property or persons affected by
• the Works to the extent to which the same is occasioned or contributed to by the act,
omission, neglect, breach or default of the Contractor or personnel, servants, agents or
employees.

38.3 The Contractor agrees that the obligations under this clause shall continue after the expiry or
earlier termination of this Contract in respect of any act, deed, matter or thing happening before
such expiration or termination of this Contract.

38.4 The Contractor shall indemnify, protect and defend, at its own cost and expense, the Government
and its agents and servants from and against all actions, claims and liabilities arising out of acts
done by the Contractor in the performance of this Contract.

39.0 INSURANCE AGAINST INJURY TO PERSONS AND DAMAGE TO PROPERTY

39.1 Without prejudice to his liability to indemnify the Government under clause 38, the Contractor
shall as a condition precedent to the commencement of any work under this Contract, effect and
maintain such insurances whether with or without an excess amount as specified in Appendix 1
as are necessary to cover the liability of the Contractor and all sub-contractors.

39.2 Such insurance shall be in respect of personal injuries or death, damage or loss to property,
movable or immovable, arising out of or in the course of or by reason of the execution of the
Works and caused by any negligence, omission, breach of contract or default of the Contractor or •
any sub-contractor, or of any servants or agents of the Contractor or of any such sub-contractor.
Where an excess amount is specified in Appendix 1 the Contractor shall bear the amount of such
excess. The policy or policies of insurance shall contain a cross liability clause indemnifying each
of the jointly insured against claims made on him by the other jointly insured.

39.3 The Contractor shall effect and maintain insurances during the execution of the Works as well as
during the Defects Liability Period for such amount of indemnity as may be specified in Appendix
1 in respect of any expense, liability, loss, claim or proceedings which the Government may incur
or sustain by reason of damage to any property (including the Works and any other property of
the Government) caused by collapse, subsidence, vibration, weakening or removal of support or
lowering of ground water arising out of or in the course of or by reason of the carrying out of the
Works except damage arising from an Event of Force Majeure under clause 66.2.

39.4 Such insurance as referred to under clause 39.1 and 39.2 shall be effected with an insurance
company approved by the Government and maintained in the joint names of the Government and
Contractor, from the period of the date of possession of site until the date of issuance of
Certificate of Completion of Making Good Defects. The Contractor shall ensure that such
insurance shall also cover the Government, the Contractor and all sub-contractors, for any claim
occasioned by the Contractor or any sub-contractor in the course of any operations carried out by
him or any sub-contractor for the purpose of complying with his obligations under clause 47
hereof. It shall be the duty of the Contractor to produce the relevant policy or policies of the
insurance together with receipts in respect of premiums paid to the P.D, whether demanded or
not.

33
 39.5 If the Contractor or any sub-contractor fails to renew such insurance as are necessary under this
clause, the Government or the P.[) on its behalf may renew sUch insurance as aforesaid and may
deduct a sum equivalent to the amount in respect of premiums paid including On-cost Charges
frorri any money due or to become due to the Contractor under this Contract, failing which such
premiums shall be recovered from the Performance Bond or as a debt due ftom the Contractor.

39.6 The Contractor shall ensure that any insurance policy effected shall only be cancelled by the
insurer after the expiry of thirty (30) days from the date of receipt by the Government of a written
notice from the insurer advising of such impending cancellation PROVIDED THAT the Contractor
has been issued with a Certificate of Completion of Making Good Defects in accordance with
clause 47.

39.7 The Contractor shall not at any time permit or cause to be done any act, matter or thing which
may result in any insurance effected by virtue of this Contract being vitiated or rendered void or
voidable or whereby the rate of the premium on any insurance effected shall be liable to be
increased.

40.0 SUB-CONTRACTING AND ASSIGNMENT

40.1 The Contractor shall not without the prior written consent of the P.D (which consent shall not be
unreasonably delayed or withheld) sub:. contract the design for all or any portion of the Works.
Where the P.D consents to any sub- contract under this clause, such consent shall not in any
way absolve the obligations of the Contractor under clause 14.1 (a).

40.2 The Contractor shall not sub-contract the whole or any substantial part of the Works without the
prior written consent of the P.D (which consent shall not be unreasonably delayed or withheld).
Any such consent, if given, shall not relieve the Contractor from any liability or obligation under
this Contract and he shall be responsible for the due observance by such sub-contractors, of all
the terms, stipulations and conditions under this Contract.

40.3 Notwithstanding any sub-contract made pursuant to clauses 40.1 and 40.2, the Contractor shall
be fully responsible for the acts, defaults or neglects of any sub-contractor, including 'labour only'
sub-contractors, his agents, servants or workmen as if they were the acts, defaults or neglects of
the Contractor; PROVIDED THAT the provision of labour on a piecework basis shall not be
deemed to be a sub- contract under this clause.

40.4 It shall be a condition in any sub- contract which has been consented to by the Government that
upon termination of the Contractor's employment under the Contract, the employment of the sub-
contractor under the sub-contract shall terminate immediately. No claim whatsoever shall be
made by the Contractor and/or sub-contractor against the Government for any work done or
materials or goods supplied.

40.5 If the Contractor sub-contracts the Works, in whole or in part, to any person without getting prior
written consent of the P.D as provided under this clause, the P.D shall have the right to instruct
the Contractor to forthwith terminate such sub-contract and the Contractor shall be liable for all
costs and expense relating to such termination.

34
 40.6 The Contractor shall not assign the Contract or any part thereof; or any benefit or interest therein
or thereunder without the prior written consent ofthe P.O.

41.0 BUMIPUTERA PARTICIPATION

41.1 The Contractor shall employ Bumiputera organizations or professionals to carry out specific
portion of the Works on a sub-contract basis as defined under clause 40 and the amount of all
these participation shall be at least 30% of the total Contract Sum.

41.2 It is also required that:

(a) the Bumiputera organisations shall be from the list of registered contractors maintained
by the Contractors Service Centre of the Ministry of Entrepreneurial Development
Malaysia or the list of registered suppliers and professional firms maintained by the
Ministry of Finance Malaysia, whichever is applicable;

{b) within fourteen (14) days from the receipt of the Letter of Acceptance, the Contractor
shall submit to the P.D for his approval a list of works, supply or services which he
proposes to sub-contract to Bumiputera organisations in accordance with this clause.
The P.D shall, within twenty-one (21) days after receipt of this list, - .

(i) approve the list in writing; or

(ii) reject the list in writing, with reasons and/or request modifications; and/or
(iii) request the Contractor to supply further information to clarify or substantiate the
list;

PROVIDED THAT if none of the above actions is taken within the said period of twenty-
one (21) days the P.D shall be deemed to have approved the list as submitted.

41.3 If the Contractor fails to fulfill the requirements of this clause, the Government reserves the right
to-
(a) reallocate any portion of the Works to Bumiputera organisations for which the Contractor
shall remain fully responsible for any delay or failure on the part of the Bumiputera
organisations; or

(b) take action against the Contractor by suspension or cancellation of the Contractor's
registration as a "Government Contractor".

41.4 Any action, decision, instruction or consent taken, made or given by the Government or the P.D,
as the case may be, under this clause shall not in any way whatsoever relieve the Contractor of
any of his obligations under this Contract.

35
 42.0 TESTING AND COMMISSIONING OF MECHANICAL, ELECTRICAL AND OTHER SERVICES

42.1 Where the Works require the installation of any mechanical, electrical and other systems, the
Contractor shall carry out testing and commissioning of the installation to prove that the
equipment has been properly adjusted and calibrated to produce the required guaranteed
performance and that the system as a whole conforms to the specifications.

42.2 Upon completion of the installation work at the Site the Contractor shall arrange for all necessary
tests to be carried out on the equipment and installation as required by applicable laws .. The
Contractor shall also perform all other tests which may be specified elsewhere in this Contract.
The costs of all tests including the provision of necessary equipment, tools, materials, labour and
all other expenses shall be deemed to be included in the Contract Sum.

42.3 In the event the equipment or system fails to achieve the required guaranteed performance or
does not conform to the specifications, the Contractor shall take all necessary measures to
ensure that the equipment or system installed pass all the necessary tests. The installation work
shall not be considered as complete until the equipment or systems have achieved the required
guaranteed performance and have conformed to the specifications.

42.4 The Contractor shall submit a test programme to and notify the P.D when these tests are to be
conducted so that the P.D or his representatives may be present to witness such tests.

42.5 The Contractor shall also carry out further adjustments to the controls whilst the building is
occupied and the installation is in use, during the Defects Liability Period. No additional cost shall
be charged in carrying out these adjustments.

42.6 A complete record of the tests and results of such tests (whether successful or otherwise) shall
be kept up-to-date by the Contractor. At the conclusion of all the tests, these records shall be
collated and two bound sets are to be provided to the P.D.

42.7 On successful testing of the complete installation, the Contractor shall arrange to commission the
equipment in the presence of the P.D or his representatives. The Contractor shall demonstrate
the correct operation of all mechanical and electrical aspects of the equipment, the correct
operations of all controls and prove that the installation is complete.

43.0 SECTIONAL COMPLETION

Where different completion dates for different sections or parts of the Works are stated and identified in
Appendix 1 or elsewhere in the Contract Documents and different and separate Liquidated and
Ascertained Damages are provided for each section or part of the Works, the provisions of this Contract
in regard to -

(a) clause 44 (Completion of the Works);

36
 (b) clause 45 (Damages for Non-completion);

(c) clause 47 (Defects After Completion); and

(d) clause 49 (Delay and Extension of Time),

but not clause 10, clause 11 and clause 54 shall, in the absence of any express provision to the contrary
elsewhere in the Contract Documents apply mutatis mutandis as if each such section or part was the
subject of a separate and disti.nct contract between the Government and the Contractor.

44.0 COMPLETION OF THE WORKS

44.1 Subject to any requirement as to the completion .of any section or part of the Works under
clauses 12.3 and 43 before the completion of the whole of the Works, the Contractor shall
complete the whole of the Works on or before the Date for Completion or such extended time as
may be allowed under clause 49.

44.2 • When the whole of the Works have reached practical completion according to the provisions of
this Contract and to the satisfaction of the P.D, and the Contractor has obtained a temporary
certificate of fitness for occupation / certificate of completion and compliance, wherever
applicable, the date of such completion shall be certified by the P.D and such date shall be the
date of the commencement of the Defects Liability Period as provided in clause 47. The
certificate issued under this clause shall be referred to as the 'Certificate of Practical Completion'.

44.3 If the Contractor considers that the Works have achieved practical completion, the Contractor
shall notify the P.D in writing to that effect. •

44.4 Within 14 days of receipt of such notice, the P.D shall carry out testing/ inspection of the Works.
Pursuant to such inspection/testing, the P.D shall - -

(a) issue the Certificate of Practical Completion to the Contractor if in his opinion the whole
Works have reached practical completion and have satisfactorily passed any
inspection/test carried out by the P.D subject to the Contractor giving a written
undertaking to complete any outstanding work during the Defects Liability Period. The •
date of such completion shall be certified by the P.D and such date shall be the date of
the commencement of the Defects Liability Period as provided in clause 4 7 .2 hereof; or

(b) give instruction to the Contractor specifying all defective works which are required to be
completed by the Contractor before the issuance of the Certificate of Practical
Completion. •

44.5 If the P.D has given instruction pursuant to clause 44.4(b), no Certificate of Practical Completion
shall be issued to the Contractor until the Contractor has effectively carried out the remedial
work within reasonable period to the satisfaction of the P.O.

44.6 The Works shall only be regarded as practically complete if-

37
 (a) the Works have been completed in accordance with the terms and conditions of this
Contract;

(b) the Government can have full, proper and beneficial use of the Works for their intended
purpose, notwithstanding that there may be works of a very minor nature still to be fully
executed provided that such works do not prevent or diminish the full, proper and
beneficial use as aforesaid;

(c) the Contractor has given to the P.D an undertaking to complete any outstanding work of
a very minor nature;

(d) the Works have passed any commissioning tests required in this Contract;

(e) the Works shall be made available to the Government in a condition which is fit for
occupation; and

(f) all the essential services, including access roads, landscape (if applicable), car parks (if
applicable), drains, sanitary, water and electricity installation, fire hydrant, sewerage and
refuse disposal equipment and, fire lifts where required, have been provided.

44.7 Notwithstanding the provision of clauses 45 and 49, time shall be the essence of this Contract.

45.0 DAMAGES FOR NON-COMPLETION

45.1 If the Contractor fails to complete the Works by the Date for Completion or within any extended
time granted pursuant to clause 49, the P.D shall forthwith issue a Certificate of Non-Completion
to the Contractor.

45.2 Without prejudice to the Government's right to terminate this Contract, when the P.O. issues the
Certificate of Non-Completicfn, the Government shall be entitled to recover from the Contractor,
Liquidated and Ascertained Damages calculated at the rate stated in Appendix 1 from the period
of issuance of the Certificate of Non-Completion to the date of issuance of Certificate of Practical
Completion or the date of termination of this Contract. The P.D may deduct such damages from
any money due or to become due to the Contractor, failing which such damages shall be
recovered from the Performance Bond or as a debt due from the Contractor. The P.D shall inform
the Contractor of such deduction.

45.3 The Liquidated and Ascertained Damages stated in Appendix 1 shall be deemed to be a
reasonable amount of loss which the Government will suffer in the event that the Contractor is in
breach of this clause. The Contractor by entering into this Contract agrees to pay to the
Government the said amount(s) if the same become due without the need of the Government to
prove his actual damage or loss.

45.4 The payment or d.eduction of such Liquidated and Ascertained Damages shall not relieve the
Contractor from its obligation to complete the Works or its obligations and liabilities under the
Contract.

38
 46.0 PARTIAL OCCUPATION/ TAKING OVER BY GOVERNMENT

46.1 If at any time or times before the whole of the Works have reached practical completion, the
Government with the consent of the Contractor shall take possession of and occupy any part or
parts of the same (any such part being hereinafter in this clause referred to as 'the relevant part'),
then notwithstanding anything expressed or implied elsewhere in this Contract -

(a) within seven (7) days from the date on which the Government shall have taken
possession of the relevant part the P.D shall issue a Certificate of Partial Occupation in
respect of the relevant part stating the estimated value of the said relevant part, and for
all the purposes of this clause (but for no other) the value so stated shall be deemed to
be the total value of the said relevant part; ••

(b) for the purposes of clauses 44 and 47 hereof, the relevant part shall be deemed to have
reached practical completion and the Defects Liability Period in respect of the relevant
part shall be deemed to have commenced on the date on which the Government shall
have taken possession and occupied thereof;

(c) at the end of the Defects Liability Period of the relevant part and •if in the opinion of the
P.D any defect, imperfection, shrinkage or any other fault whatsoever in respect of the
relevant part which he may have required to be made good under clause 47, shall have
been made good by the Contractor, the P.D shall issue a certificate to that effect;

(d) the Contractor shall insure and keep insured the Works in the manner as stipulated under
clause 11 and the Contractor shall give notice to the insurer of such partial occupation
notwithstanding the partial occupation by the Government of the relevant part; and

(e) the Liquidated and Ascertained Damages specified under clause 45 for any period of
delay after' such certification of the practical completion of the relevant part·under clause
44.1, shall be reduced in the proportion which the total value of the relevant part bear to
the Contract Sum. •

46.2 It is expressly agreed that nothing contained in the preceding paragraphs shall entitle the
Contractor to the release of the Performance Bond or any part thereof; the intention being that the
said Performance Bond or any part thereof shall be released or refunded only upon the
completion of making good all defects, imperfections, shrinkages or other faults which may
appear during the Defects Liability Period and upon the giving of the Certificate of Completion of
Making Good Defects for the whole of the Works under clause 47 hereof.

47.0 DEFECTS AFTER COMPLETION

47.1 The Contractor shall, during the Defects Liability Period complete with due expedition or within
such time as may be specified by the P.D, any work outstanding at the Date of Practical
Completion (whether or not the Contractor has undertaken to do so).

39
 47.2 The Contractor shall, at any time during the Defects Liability Period as stated in Appendix 1
hereto (or if none stated the period is twenty-four (24) months from the date of practical
completion of the Works) make good any defect, imperfection, shrinkage or any other fault
whatsoever which may appear and which are due to design, materials, goods, workmanship or
equipment not in accordance with this Contract, as specified by the P.D in a written instruction to
the Contractor.

47.3 Notwithstanding sub-clause 47.1 above, any defect, imperfection, shrinkage or any other fault
whatsoever which may appear during the Defects Liability Period to be made good by the
Contractor, shall be specified by the P.D in the Schedules of Defects of which the first schedule
shall be delivered to the Contractor within fourteen (14) days and the final schedule shall be
delivered not later than twenty-eight (28) days after the expiration of the Defects Liability Period.
The defects, imperfections, shrinkages or any other fault whatsoever specified in the Schedules
of Defects shall be made good by the Contractor at his own costs and to be completed within a
reasonable time but in any case not later than three (3) months after the receipt of the final
schedule. Provided that the P .0 shall not be allowed to issue any further instruction requiring the
Contractor to make good any defect, imperfection, shrinkage or any other fault whatsoever after
the issuance of the said Schedule of Defects or after twenty eight (28) days from the expiration
of the said Defects Liability Period, whichever is the later.

47.4 If the Contractor shall fail to comply with either clause 47.1 or clause 47.2 or both within the time
so specified, the materials or works so affected may be made good in such manner as the P.D
may think fit, in which case the costs incurred including On-cost Charges shall be deducted from
any money due or to become due to the Contractor under this Contract and failing which such
costs shall be recovered from the Performance Bond or as a debt due from the Contractor.

47.5 If any defect, imperfection, shrinkage or any other fault whatsoever is such that, in the opinion of
the P.O, it shall be impracticable or inconvenient to the Government to have the Contractor to
remedy the same, the P.D shall ascertain the diminution in the value of the Works due to the
existence of such defects, imperfections, shrinkages or any other fault whatsoever. The amount
of such diminution shall be recov.erable by the Government from the Contractor as a debt due to
the Government under this Contract, and failing which such diminution shall be recovered from
the Performance Bond. •

47.6 When in the opinion of the P.D the Contractor has made good the defects, imperfections,
shrinkages or any other fault.whatsoever which he is required to make good under clauses 47.1
or 47.2, or both, the P.D shall issue a certificate to that effect, and the date stated in such
certificate shall be the date on which the Contractor has completed making good such defects,
imperfections, shrinkages or any other fault whatsoever. The said Certificate shall be referred to
as the 'Certificate of Completion of Making Good Defects'.

48.0 UNFULFILLED OBLIGATIONS

Notwithstanding the issue of the Certificate of Completion of Making Good Defects under clause 47.6,
the Contractor and the Government shall remain liable for the fulfillment of any obligation arising under
the provisions of the Contract, prior to the issuance of the said certificate, which remains unfulfilled at the
time such certificate is issued. For the purpose of determining the nature and extent of any such
obligation, the Contract shall be deemed to remain in force between the Parties.

40
49.0 DELAY AND EXTENSION OF TIME

49.1 Upon it becoming reasonably apparent that the progress of the Works is delayed, the Contractor
shall forthwith give written notice to the P.O. as to the causes of delay and relevant information
with supporting documents enabling the said officer to form an opinion as to the cause and the
length of delay. If in the opinion of the P.D. the completion of the Works is likely to be delayed or
has been delayed beyond the Date for Completion stated in Appendix 1 or beyond any extended
Date for Completion previously fixed under this clause -

(a) by an occurrence of an Event of Force Majeure as provided under clause 66;

•{b) by reason of directions given by the P.D, consequential upon disputes with neighbouring
owners provided the same is not due to any act, negligence or default of the Contractor
or any sub-contractor;

(c) by reason of exceptionally inclement weather conditions;

{d) by reason of P.D's instructions issued under clauses 7.5, 15.2(b), 20.2 or 23.2 provided
that such instructions are not issued due to any act, negligence, default or breach of this
contract by the Contractor or any sub contractor;

(e) by reason of the Contractor not having received in due time necessary instructions,
decisions, information, concurrence or consent from the P.D which the P.D is obliged to
provide or give under the Contract for which the Contractor shall have specifically applied
in writing on a date which having regard to the Date for Completion stated in Appendix 1
or to any extension of time then fixed under this clause, was neither unreasonably distant
from nor unreasonably close to the date on which it was necessary for the Contractor to
. receive the same; or

(f) by delay in receipt of any necessary permission or approval of any statutory body or local
authority which the Contractor has taken all practicable steps to avoid or reduce; or •

(g) by reason of delay in giving possession of the Site as provided under clause 12.4 and/or
12.5; or

{h) by delay on the part of artists, tradesmen or others engaged by the Government in
executing work not forming part of this Contract;

(i) by the Contractor's inability for reason beyond his control and which he could not
reasonably have foreseen at the date of closing of tender of this Contract to secure such
goods, materials and/or services as are essential to the proper carrying out of the Works;
or

41
 02 by reason of suspension of the Works as provided under clause 59,

then the P.O. may, if he is of the opinion that an extension of time should be granted, so soon as
he is able to estimate the length of the delay beyond the date or time aforesaid issue a Certificate
of Delay and Extension of Time giving a fair and reasonable extension of time for completion of
the Works.

PROVIDED THAT the Contractor has taken all reasonable steps to avoid or reduce such delay
and shall do all that may reasonably be required to the satisfaction of the P.D to proceed with the
Works.

PROVIDED FURTHER THAT the Contractor shall not be entitled to any extension of time where
the instructions or acts of the Government or the P.D are necessitated by or intended to cure any
default of or breach of contract by the Contractor.

49.2 If during the regular progress of the Works or any part thereof has been materially affected by
reason of delays as stated under clause 49.1(b), (d), (e), {h) and O) hereof (and no other), and
the Contractor has incurred or is likely to incur direct loss and/or expense beyond that reasonably
contemplated and for which the Contractor would not be reimbursed by a payment made under
any other provision in this Contract, then the Contractor shall be entitled to claim for such direct
loss and/or expense incurred, subject always to clause 50.

50.0 PROCEDURE FOR CLAIMS

50.1 Notwithstanding any other provision of the Contract, if the Contractor intends to claim any
additional payment pursuant to any clause of this Contract, the Contractor shall within sixty (60)
days of the occurrence of such event or circumstances or instructions give notice in writing to the
P.D of his intention for such claim.

50.2 As soon as is practicable but not later than ninety (90) days after practical completion of the
Works, the Contractor shall submit full particulars of the claims under clause 50.1 together with
all supporting documents, vouchers, explanations, calculations, records and receipts for payment
made which may be necessary to enable the claims to be ascertained by the P.O. Upon expiry of
the ninety (90) days period, the P.D shall proceed to _ascertain the claims based on such
documents submitted by the Contractor. The amount of such claims ascertained by the P.D shall
be added to the Contract Sum.

50.3 If the Contractor fails to comply with clause 50.1 and clause 50.2, he shall not be entitled to such
claim and the Government shall be discharged from all liability in connection with the claim.

51.0 INTELLECTUAL PROPERTY RIGHTS, ROYAL TIES, ETC.

51.1 Any intellectual property rights arising out of design, plans, calculations, drawings, developed or
used for or incorporated in the Works shall vest in and become the sole property of the
Government free and clear of all liens, claims and encumbrances. The Contractor shall not

42
 during or at any time after completion on the Works or after the expiry or termination of this
Contract, in any way, question or dispute the ownership of the Government.

51.2 The Contractor agrees to grant to the Government free from all royalties, fees and other
charges, all licenses in respect of intellectual property rights now or hereafter owned or
controlled by the Contractor or in respect of which the Contractor has or will have the right to
grant licenses of any design, plans, calculations, drawings, developed or used for or
incorporated in the Works or any part thereof.

51.3 All royalties or other sums payable in respect of the design, plans, calculations, drawings which
are subject to copyright (other than the design, plans, calculations or drawings provided by the
P.D) which are used in the Works shall be deemed to have been included in the Contract Sum.

51.4 The Contractor shall defend and indemnify the Government from and against all claims, costs,
damages, charges and proceedings whatsoever for or on account of infringement of any
intellectual property rights in respect of any design, plans, calculations, drawings, documents,
plant, equipment,· machinery, material, methods or processes developed or used for or
incorporated in the Works except where such infringement results from compliance with the P.D's
instructions pursuant to clause 23.

51.5 Where any infringement results from compliance with the P.D's instructions pursuant to clause
23, any royalties, damages or other monies which the Contractor may be liable to pay to the
persons entitled to such intellectual property rights shall be reimbursed by the Government.

51.6 The Contractor shall indemnify the Government from and against all claims, proceedings,
damages, costs and expense which may be brought or made against the Government as a result
of the use of such intellectual property rights or infringement by the Contractor of the same.

51.7 Except where otherwise specified, the Contractor shall pay all tonnage and other royalties, rent
fees and other payments or compensation (if any) for getting stone, sand, gravel, clay or other
materials required for the Works.

52.0 MAINTENANCE OF WORKS AND SERVICES

52.1 The Contractor shall maintain the whole of the Works and Services as listed in the scope of
maintenance of works contained in the Government's Requirements for a period of twenty-four
(24) months from the date of the Practical Completion of the Works (hereinafter referred to as the
"Maintenance Period") and guarantee the same to be in good working conditions at all times. This •
maintenance shall include services and equipment provided by the manufacturer of the
equipment installed and all materials and workmanship supplied by the Contractor.

52.2 The Contractor hereby expressly undertakes to remedy and supply/replace all defective parts or
items caused by normal wear and tear, inclusive of all consumable items at his own cost during
the said twenty-four (24) months so that the whole of the Works and Services is maintained in the

43
 best efficient working order. This maintenance shall include regular and systematic checking,
cleaning, servIcIng, testing, calibration and services as recommended by • the
manufacturer/supplier as required by the relevant authorities and necessary adjustment to the
equipment. The Contrac,::tor shall also provide alternative/temporary substitutes to the equipment
and services as required in the event of a breakdown of the plant. Any spare parts required for
replacement shall be made readily available during the Maintenance Period.

52.3 Replacement made or required to be made during the Maintenance Period shall be subjected to
a similar Maintenance Period from the date of replacement, provided that such Maintenance
Period shall not exceed 24 months from the expiry date of the first Maintenance Period as
aforesaid. •

52.4 When in the opinion of the P.D the Contractor has satisfactorily completed the maintenance of
the Works and Services as required under this clause, the P.D shall issue a certificate to that
effect, and the date named in such certificate shall be the date on which the Contractor has
completed the same. The said Certificate shall be referred to as the "Certificate of Completion of
Maintenance".

53.0 . INTERIM PAYMENTS

53.1 Interim payments shall be made by the Government based on the P.D's monthly valuation of the
Works done and properly executed and of any goods or unfixed materials delivered to or adjacent
to the Site intended for use or to be incorporated .into the Works PROVIDED THAT it shall be a
condition precedent to the first interim payment, for the Contractor to submit to the Government
copies of the Consultancy Agreement as provided under clause 35.1. •

53.2 The Contractor shall submit to the P.D, at such times and in such form as the P.D may prescribe,
written application for Interim Payments showing the amounts which in the Contractor's opinion
are due under the Contract Payments. The submission shall include the following:

(a) the value of Works done and properly executed;

(b) the amount of any valuation of variations or of the instructions by the PD (clause 24 );
(c) the amount in regard to the expenditure of Provisional Sums executed or expended
(clause 25);
(d) the value of any goods or unfixed materials delivered to or adjacent to the Site intended
for use or to be incorporated into the Works; and
(e) the supervision reports as required by the P.D under clause 13.1.

53.3 The P.D shall within twenty-eight (28) days from the date of receipt of the application for Interim
Payments, inspect and verify the Works, and make a valuation of the same and issue an Interim
Payment Certificate stating the amount due to the Contractor from the Government PROVIDED
1HAT the total value in each monthly valuation shall not be less than the sum referred to in
Appendix 1.
53.4 The amount stated as due in an Interim Payment Certificate shall be the estimated total value of
the Works done and properly executed and up to ninety (90) percent of the value of any goods or

44
 unfixed materials delivered to or adjacent to the Site intended for use or to be incorporated into
the Works Up to and inc:Tuaing the date the valuation was made, less any payments (including
Advance Payment) previously paid under this Contract. PROVIDED THAT such Certificate shall
only include the value of the. said goods or unfixed materials as and from such time as they are
reasonably and properly and not prematurely delivered to or adjacent to the Site and adequately
protected against weather, damage or deterioration.

53.5 Within a number of days as stated in Appendix 1 (or if none stated then within thirty (30) days of
the issuance of any such Interim Payment Certificate) the Government shall pay the Contractor
the amount certified as due to the Contractor in the said Certificate.

54.0 FINAL ACCOUNT AND FINAL CERTIFICATE

54.1 Within three (3) months after issuance of the Certificate of Completion of Making Good Defects or
the Certificate of Completion of Maintenance (if any) whichever is the later, the Contractor shall
submit to the P.D a statement of the final account showing in detail the value in accordance with
the Contract, of the Works carried out together with all further sums which the Contractor
considers to be due to him after giving credit to the Government for all amounts previously paid
by the Government and for all sums to which the Government is entitled under the Contract up to
the date of the Certificate of Completion of Making Good Defects or the Certificate of Completion
of Maintenance, as the case may be. The Final Account shall be supported by all documentation
substantiating the value of the same.

54.2 Upon expiry of the three (3) months period as specified in clause 54.1, the P.D shall proceed to
verify the Final Account based on such documents submitted by the Contractor. The P.D shall
issue a certificate (hereinafter referred to as "the Final Certificate") stating the amount which in
his opinion is finally due under the Contract from the Government to the Contractor or from the
Contractor to the Government, as the case may be, after giving credit to the Government for all
amounts previously paid by the Government and for all sums to which the Government is entitled
under the Contract not later than three (3) months thereafter.

54.3 If the Contractor does not submit the final account within the three (3) months referred to in
clause 54.1 the P.D may on the expiry of the said three (3) months give notice in writing to the
Contractor that if the final account is not submitted by the Contractor within two (2) months from
the date of the written notice the P.D may himself prepare the Final Account.

54.4 Subject to any deductions authorized by the Contract any balance properly stated in the Final
Certificate shall as from the 30 th day after the issuance of the same become conclusive as to the
balance due between the parties and be a debt payable as the case may be by the Government
to the Contractor or by the Contractor to the Government.

54.5 Where the Government exercises any right of deduction from monies due or to become due to
the Contractor, the P .D shall inform the Contractor in writing the reason of that deduction .

. 54.6 No final payment due to the Contractor shall be made unless and until the Contractor shall have
satisfied the P.D by means of a Statutory Declaration made by or on behalf of the Contractor that

45
 the workmen who have been employed by the Contractor on the Works, including workmen
emplo-yed 6y •sub..:contractors, whether nominated or otherwise (including 'labour only' sub~
contractors) have received all wages due to them in connection with such employment, and that
all dues or contributions under the Employment Act 1955, the Employee's Social Security Act
1969, the Employee's Provident Fund Act 1991 and any other laws relevant to the employment of
workmen, have been paid.

55.0 EFFECT OF P.D'S CERTIFICATES AND PAYMENT BY GOVERNMENT

No certificate of the P.D or any approval, written or otherwise, by the P.D or the Government or payment
by the Government under any provision of this Contract shall be considered as conclusive evidence as to
the sufficiency of any design, works, materials or goods to which it relates, nor shall it relieve the
Contractor from any or all of his obligations under this Contract and/or his liability to amend and make
good all defects, imperfections, shrinkages, or any other faults whatsoever as provided by this Contract.
In any case, no certificate of the P.D shall be final and binding in any dispute between the Government
and the Contractor if the dispute is brought whether before an arbitrator or in the Courts.

56.0 DEDUCTION FROM MONEY DUE TO CONTRACTOR

The Government or the P.D on its behalf shall be entitled to deduct any money owing from the Contractor
to the Government under this Contract from any sum which may become due or is payable to the
Contractor under this Contract or any other contracts to which the Government and Contractor are parties
thereto. The P.D in issuing any certificate under clauses 53 and 54, shall have regard to any such sum so
chargeable against the Contractor, PROVIDED THAT this provision shall not affect any other remedy to
which the Government may be entitled for the recovery of such sums.

57.0 ADVANCE PAYMENT

57.1 The Contractor shall be entitled to an advance payment on the Contract amounting to 25% of the
value of the Contract Sum less Provisional Sums (hereinafter referred to as the "Builder's Work')
but swbject to a maximum of RM10 millicin on compliance with the following conditions:

(a) on return of the Letter of Acceptance duly signed by the Contractor together with the
Performance Bond (if any), insurance policies, confirmation from SOCSO Authorities and
the receipts for all premium paid;
(b) production of a Banker's/Insurance/Finance Company Guarantee in the approved format
equal in value to the advance proposed to be paid;
(c) Submission of the Banker's Guarantee / Insurance Guarantee / Financial Company
Guarantee not later than 3 months from the date of possession of Site.

57.2 The advance payment shall be recouped when the cumulative total value of the Builder's Work
executed and certified (including the amount certified for materials on site) reaches (25%) twenty
five percent of the total contract value of Builder's Work, by way of a fixed percentage deduction
from the total certified value of the Builder's Work executed (including the amount certified for

46
 materials on site) during the period covered by an Interim Payment Certificate, in all the
subsequent Interim Payment Certificates on the basis that the advance payment made shall be
fully recovered in the Interim Payment Certificate in which the cumulative total certified value of
the Builder's Work executed (including the amount certified for materials on site) reaches
seventy-five (75) percent of the total contract value of the Builder's Work*. The deduction shall be
calculated as follows: •

$D = 200 ~ percent of $P
B
Where$ D = cumulative deduction to be made in Interim
Payment Certificate,
$A = total amount of advance paid,
$B = total contract value of Builder's Work
$P = gross certified value of Builder's Work executed
(including the amount certified for materials on site)
or agreed cumulative scheduled payments in
excess of 25% of $ B

57.3 The liability under the advance guarantee shall be terminated upon realization by the
Government of the full sum of advance paid. However if the full sum of the advance paid cannot
be realized before the completion date of the contract or any authorised extension thereof or the
case of the contract been determined before the date of the determination, then the balance of
the advance repayable to the Government shall be recovered from the advance guarantee.

58.0 PROVISIONAL BILLS OF QUANTITIES

(a) Where the Contract includes any Bills of Quantities, which is stated as "provisional", it
shall fully describe the qualities of Works that need to be executed in respect of any:
specified items. Where quantities are stated as "provisional" such quantities are the
estimated quantities of the Works but they are not to be taken as the actual and correct
quantities of the Works to be executed by the Contractor in fulfillment of his obligations
under the Contract.

(b) Where the quantities of any part of the Works are stated as "provisional" in the Bills of
Quantities the amount to be paid to the Contractor in respect of the said part of the Works
upon completion of this contract shall be ascertained by remeasurement as they are
actually executed. Provided Always that if the remeasurement resulted in an increase in
costs, then the Government shall not be liable for such increase in costs if it is due to the
fault, error, omission or negligence of the Contractor or his Consultants in preparing the
said "provisional" Bills of Quantities. Such costs shall be fully borne by the Contractor.
However, if the remeasurement of the said "provisional" quantities results in a reduction
in cost the Contract Sum shall be accordingly reduced.

(c) The rates in the "provisional" in the Bills of Quantities shall determine the valuation of the
Works of similar character and executed under similar conditions as work priced therein.
The said rates, where work is not of similar character or executed •under similar
conditions as aforesaid, shall be the basis of rates for the same so far as maybe

47
 reasonable, failing which a fair valuation thereof shall be made by the P.D.

59.0 SUSPENSION

59.1 Suspension and Resumption of Works

(a) The P.D. may at any time instruct the Contractor to suspend part or all of the Works.

(b) Upon receipt of such written instruction, the Contractor shall suspend part or all of the
Works for such time and in such manner as specified in the instruction and shall duly
protect, store and secure the Works or such part of the Works against any deterioration,
loss or damage.

(c) During the suspension period, the Contractor shall continue to perform his obligations
under this Contract which are not affected by the instruction to suspend, including the
obligation to effect and maintain insurances and performance bond.

(d) The P.D may instruct the Contractor to resume the Works at any time thereafter. Upon
receipt of such instruction the Contractor shall resume the Works and the parties shall
jointly examine the Works affected by the suspension. The Contractor shall make good
any deterioration or defect in or loss of the Works which has occurred during the
suspension. . The Contractor shall also take all necessary actions to mitigate the
expenses incurred.

59.2 Extension of time

(a) If the Contractor suffers delay and/or incurs expenses in complying with the instruction
under clause 59.1 (a), and in resumption of the Works; arid if such delay and/or expenses
was not foreseeable by the Contractor, the Contractor shall give notice for extension of
time under clause 49 and the provisions thereof shall apply accordingly. PROVIDED
THAT the Contractor shall not be entitled to such extension if the suspension is due to a
cause attributable to the Contractor and the Contractor shall not be entitled to payment of
loss and expense if he -

(i) fails to take measures specified in clause 59.1 (b); and

(ii) fails to take all necessary action to mitigate the expenses incurred.

(b) In the event such suspension shall continue for a period exceeding 12 months, the
parties shall then discuss whether to mutually terminate the Contract or suspend the
Works for a further period.

48
59.3 Consequences of mutual termination

If this Contract is mutually terminated under this clause -

(a) clause 60.1 (c)(i) shall apply; and

(b) payment obligations including all costs and expenditure incurred by the Government and
the Contractor shall be ascertained in accordance with clause 63.

60.0 EVENTS AND CONSEQUENCES OF DEFAULT BY THE CONTRACTOR

60.1 Default of Obligations

(a) Events of Default

In the event the Contractor -

(i) fails to commence Works at the Site within two (2) weeks after the Date for
Possession;
(ii) suspends or abandons the carrying out of the Works or any part thereof for a
continuous period of ..... ( ... )days;
(iii) fails to proceed regularly and diligently with the performance of his obligations
under the Contract;
(iv) fails to execute the Works in accordance with the Contract;
(v) persistently neglects to carry out his obligations under the Contract;
(vi) refuses or persistently neglects to comply with a written notice from the P.D in
relation to any defective work or equipment, materials or goods or which. do not
meet the requirements of the Contract;
(vii) fails to comply with the provisions of clause 4 ;
(viii) fails to obtain the prior written consent of the P.O. required under clause 40; or
(ix) fails to comply with any terms and conditions of this Contract,

then the Government may give written notice to the Contractor specifying the default, and
requiring the Contractor to remedy such default within fourteen (14) days of the receipt of
the default notice or any period determined by the Government.

(b) Termination

If the Contractor fails to remedy the breach within such period, the Government shall
have the right to forthwith terminate this Contract by giving a written notice to that effect.

49
(c) Consequences of Termination

If this Contract is terminated under clause 60.1 (b ),

(i) the Contractor shall -

(A) forthwith cease all operations on the Works;

(8) carry out any protection works so as to secure the Site, equipment,
goods and materials therein against any deterioration, loss or damage
and to do all things necessary so as to leave the Site in a clean and tidy
condition;
(C) remove its personnel and workmen from the Site;
(D) vacate the Site within the time specified by the P.D and remove all
temporary buildings, plant, tools, equipment, goods and unfixed
materials which have not been paid by the Government, as specified by
the P.O. Failing which, the Government may (but without being
responsible for any loss or damage) remove and sell any such property
belonging to the Contractor, holding the proceeds, less all cost incurred,
to the credit of the Contractor;
(E) either-
(aa) terminate all third party contracts enter_ed into by the Contractor
for the purposes of this Contract;
(bb) assign to the Government, if so required by the Government, at
no cost or expense to the Government, the benefit of any
agreement for the supply of materials or goods and/or for the
execution of any work for the purposes of this Contract; or
(cc) allow such third party to enter into a contract with the
Government or any other person deemed necessary by the
Government for the purpose of completing the Works,
PROVIDED THAT the Government shall not be obliged to pay any third
party for any materials or goods delivered or any work executed or
services for the purposes of this Contract (whether before or after the
date of termination) for which the Government has paid but the
Contractor has failed to make payment to the third party ;
(F) at no cost to the Government, hand over to the Government all plans,
designs, drawings, specifications and other relevant documents relating
to the Works;
(G) pay to the Government any losses and damages suffered as a result of
the termination of this Contract in the manner provided under clause 64;
and
(H) not be released from any of its obligations or liabilities under this
Contract.

(ii) the Government shall -

50
 (A) call upon the Performance Bond or forfeit the performance guarantee
sum, and/or call upon the Design Guarantee Bond;
(B) enter and repossess the Site;
(C) be entitled to carry out and complete the Works on its own or employ
any other person to carry out and complete the Works; and
(D) be entitled to claim against the Contractor for any losses and damages
suffered as a result of the termination of this Contract in the manner
provided under clause 64.

(iii) For the avoidance of doubt, the Parties hereby agree that the Contractor shall not
be entitled to any form of losses including loss· of profit, damages, claims or
whatsoever upon termination of this Contract under this clause.

60.2 General Default

(a) Events of Default

If at any time during the contract period -

(i) the Contractor becomes bankrupt;

(ii) the Contractor becomes insolvent or compounds with or enters into an
arrangement or compositions with its creditors;
(iii) an order is made or resolution is effectively passed for the winding-up of the
Contractor (except for the purpose of restructuring or amalgamation with the
written consent of the Government, which consent shall not be unreasonably
withheld);
(iv) a provisional liquidator, receiver or manager of its business or undertaking duly
appointed, or possession taken by or on behalf of creditors or debenture holders
secured by a floating charge of any property comprised in or subject of the said
floating charge; or
(v) execution is levied against a substantial portion of the Contractor's assets,

then the Government shall have the right to terminate this Contract forthwith by giving
notice to that effect

(b) Consequences of Termination

(i) In the event of termination of this Contract under clause 60.2, clause 60.1 l(i) and
(ii) shall apply.
(ii) For the avoidance of doubt, the Parties hereby agree that the Contractor shall not
be entitled to any form of losses including loss of profit, damages, claims or

51
 whatsoever upon termination of this Contract under this clause.

61.0 TERMINATION ON CORRUPTION, UNLAWFUL OR ILLEGAL ACTIVITIES

61.1 Termination

Without prejudice to any other rights of the Government, if the Company, its personnel, servants
or employees is convicted by a court of law for corruption or unlawful or illegal activities in relation
to this Contract or any other contract that the Contractor may have with the Government, the
Government shall be entitled to terminate this Contract at any time, by giving immediate written
notice to that effect to the Contractor.

61.2 Consequences of Termination

Upon such termination under clause 61.1 -

(a) the Government shall be entitled to all losses, costs, damages and expenses including
any incidental costs and expenses incurred by the Government arising from such
termination;

{b) clause 60.1(c)(i) and (ii) shall apply; and

(c) For the avoidance of doubt, the Parties hereby agree that the Contractor shall not be
entitled to any form of losses including loss of profit, damages, claims or whatsoever
upon termination of this Contract.

62.0 TERMINATION ON NATIONAL INTEREST

62.1 Termination

(a) Notwithstanding any prov1s1on of this Contract, the Government may terminate this
Contract by giving not less than thirty (30) days written notice to that effect to the
Contractor (without any obligation to give any reason thereof) if the Government
considers that such termination is necessary for national interest, national policy or
national security.

{b) For the purposes of this clause, what constitutes "national interest", "national policy" and"
national security'', shall be solely made and determined by the Government and such
determination shall for all intent and purposes be final and conclusive and shall not be
open to any challenge whatsoever.

62.2 Consequences of Termination

Upon such termination under clause 62.1 -

(a) payment obligations including all costs and expenditure incurred by the Government and
the Contractor shall be ascertained in accordance with clause 63; and

(b) clause 60.1(c)(i) and clause 60.1(c)(ii)(B) and (C) shall apply.

52
 63.0 PAYMENTS UPON SUSPENSION OR TERMINATION ON NATIONAL INTEREST

63.1 If this Contract is terminated under clause 59 or clause 62, the amount to be paid (in so far as
such amounts or items have not already been covered by payments on account made to the
Contractor) shall be the following:

(a) the value of all works carried out up to the date of termination;

(b) the amounts payable in respect of any preliminary items so far as the Work or service
comprised therein has been carried but or performed and a proper proportion of any such
items which have been partially carried out or performed;

(c) the cost of materials or goods reasonably ordered for the Works which have been
delivered to the Contractor or of which the Contractor is legally liable to accept delivery
(such materials or goods becoming the property of the Government upon swch payment
being made to the Contractor);

(d) a sum being the amount of any expenditure reasonably incurred by the Contractor in so
far as such expenditure has not been recovered by any other payments referred to in this
sub-clause; and

(e) the reasonable cost of any protection works and removal of equipment and site facilities
pursuant to termination as provided under this Contract,

PROVIDED THAT such amount to be paid by the Government shall be confined only to those
items as are clearly and expressly stated in paragraphs (i)-(v) above.

63.2 For the avoidance of doubt, the Parties hereby agree that the Contractor shall not be entitled to
any form of losses including loss of profit, damages, claims or whatsoever other than stipulated
under clause 63.1 (a)-(e). The Parties further agree that the amount agreed above by the
Government shall constitute as a full and final settlement between the Parties.

64.0 EVENTS AND CONSEQUENCES OF DEFAULT BY THE GOVERNMENT

Default of Obligations

(a) Events of Default

If the Government without any reasonable Cause fails to perform of fulfill any of its obligation
which adversely affects the Works,

then the Contractor may issue a notice specifying the default by the Government and requiring
the Government to remedy the same within the period specified therein taking into account the
nature of the remedy to be carried out by the Government or such other period as may be agreed
by both Parties from the date of receipt of such notice.

53
 (b) Termination

If the Government fails to remedy the default period specified in such notice issued under Clause
64.0 (a) within the stipulated period time therein, the Contractor shall have the right to forthwith
terminate this Contract by giving a written notice to that effect.

(c) Consequences of Termination

If this Contract is terminated under Clause 64.0(b)-

(i) the Government shall pay to the Contractor -

(a) the value of the Works carried out up to the date of termination;

(b) the amounts payable in respect of any preliminary items so far as the Work or
service comprised therein has been carried out or performed and a proper
proportion of any such items which have been partially carried out or performed;

(c) the cost of materials or goods reasonably ordered for the Works which have
been delivered to the Contractor or of which the Contractor is legally liable to
accept delivery (such materials or goods becoming the property of the
Government upon such payment being made to the Contractor); and

(d) a sum being the amount of any expenditure reasonably incurred by the
Contra<::tor in so far as such expenditure has not been recovered by any other
payments referred to in this sub-clause.

(ii) For the avoidance of doubt, the Parties hereby agree that the Contractor shall not be
entitled to any other form of losses including loss of profit, damages, claims or
whatsoever upon termination of this Contract.

65.0 CERTIFICATE OF TERMINATION COSTS

65.1 As soon as the arrangements for the completion of the Works made by the Government enable
the P.D to make a reasonably accurate assessment of the ult.imate cost to the Government of
completing the Works following the termination of the Contractor's employment and the
engagement of other contractors or persons, and the amount of direct loss and/or damage
caused to the Government due to the termination has been ascertained by the P.D then the P.D
may issue a certificate (hereinafter referred to as the "Certificate of Termination Costs") stating
the Completion Cost (hereinafter defined) and the Final Contract Sum (hereinafter defined).

65.2 The Completion Cost comprises the following sums, costs or expenditure:

(a) the sums previously paid to the Contractor by the Government;

(b) the sums paid or payable to other contractors or persons engaged by the Government to
complete the Works;
(c) any sums paid to sub-contractors or suppliers under clause 60.1 (c)(i)(E);
(d) any costs or expenditure incurred or to be incurred including On-cost Charges incurred
by the Government in completing the Works; and

54
 (e) the amount of direct loss and/or damage caused to the Government due to the
termination.

65.3 The Final Contract Sum comprises the following amounts or sums:

(a) the amount which would have been payable under the Contract on completion in
accordance with the Contract, allowing for any variations or other matters which would
have resulted in an adjustment of the original Contract Sum; and
(b) any other sums which the Government might be entitled under the terms of the Contract
to deduct from the original Contract Sum,

had the Contractor's employment not been terminated.

65.4 The Certificate of Termination Costs shall state the difference between the Final Contract Sum
and the Completion Cost. If the Final Contract Sum is less than the Completion Cost, the
difference shall be a debt payable by the Contractor to the Government and if greater the
difference shall be a debt payable by the Government to the Contractor.

65.5 The Certificate of Termination Costs shall be binding and conclusive on the Contractor as to the
amount of such loss or damage specified therein; and •

65.6 In the event of the completion of the Works being undertaken departmentally, allowance shall be
made, when ascertaining the amount to be certified as costs or expense incurred by the
Government, for cost of supervision, interest and depreciation on plant and all other usual
overhead charges and profit as would be incurred if the Works were completed by other
contractors or persons.

66.0 SURVIVING RIGHTS

Any termination under this Contract shall not affect the liability of either party hereto for any of its acts or
omissions during the period of the Contract and both parties shall thereafter continue to be so liable and
shall keep the other party hereto indemnified and hold harmless in respect of any claims arising
therefrom.

67.0 FORCE MAJEURE

67.1 Neither the Government nor the Contractor shall be in breach of its obligations under this
Contract if it is unable to perform its obligation under this Contract ( or any part of thereof), other
than the payment obligations as a result of the occurrence of an Event of Force Majeure.

67.2 An "Event of Force Majeure" is an event beyond the control of both parties which are: ..

(a) war (whether declared or not), hostilities, invasion, act of foreign enemies;

55
 (b) iflsurrection, revolution, rebellion, military or usurped power, civil war, terrorism;

(c) natural catastrophe including but not limited to earthquakes, floods, subterranean
spontaneous combustion or any operation of the forces of nature against which an
experienced contractor could not reasonably have been expected to take precautions;

(d) nuclear explosion, radioactive or chemical contamination or radiation (unless caused by

the negligence act, omission or default of the Contractor, its agents or personnel);

(e) pressure waves caused by aircraft or other aerial devices traveling at sonic or supersonic
speeds;and

(f) riot, commotion or disorder, unless solely restricted to employees of the Contractor or its
personnel, servants or agents.

PROVIDED THAT an Event of Force Majeure shall not include financial inability on the part of the
Contractor to perform his obligations under this Contract. •

67.3 If an Event of Force Majeure occurs by reason of which either party is unable to perform any of its
obligation under this Contract (or any part thereof), the party shall inform the other party
immediately of the occurrence of that Event of Force Majeure with full particulars thereof and the
consequences thereof.

67.4 If either party considers the Event of Force Majeure to be of such severity or to be continuing for
such period of time that it effectively frustrates the original intention of this Contract, then the
parties may agree that this Contract be terminated upon mutual agreement of the parties.

67.5 If this Contract is terminated by an Event of Force Majeure pursuant to the above clause, all
rights and obligations.of the parties under this Contract shall forthwith terminate and neither party
shall have any claim against the other party and neither party shall be liable to each other save
for any rights and liabilities accruing prior to the occurrence of the Event of Force Majeure.

67.6 Neither party shall be entitled to rely upon the provIsIons above if both parties reasonably
determine that an Event of Force Majeure has not occurred.

67.7 For avoidance of doubt, the parties shall continue to perform those parts of those obligations not
affected, delayed or interrupted by an Event of Force Majeure and such obligations shall, pending
the outcome of this clause continue in full force and effect.

68.0 ARBITRATION

68.1 If any dispute or difference shall arise between the Government and the Contractor out of or in
connection with the contract, then parties shall refer such matter, dispute or difference to the officer
named in Appendix for a decision.

68.2 The officer named in Appendix's decision shall be in writing and shall subject to clause 68.4 hereof,

56
 be binding on the Parties until the completion of the Works and shall forthwith be given effect to by
the Contractor who shall proceed with the Works with all due diligence whether or not notice of
dissatisfaction is given by him.

68.3 If the Parties -

(a) fails to receive a decision from the officer named in the Appendix within forty-five (45) days
after being requested to do so; or

(b) is dissatisfied with any decision of the officer named in the Appendix,

then such dispute or difference shall be referred to arbitration within forty-five (45) days to an
arbitrator to be agreed between the Parties and failing such agreement, to be appointed by the
Director of the Regional Centre for arbitration in Kuala Lumpur on the application of either Party
hereto. Such arbitration shall be heard at the Kuala Lumpur Regional Centre for Arbitration and shall
be conducted in accordance with the rules for arbitration of the Kuala Lumpur Regional Centre for
Arbitration using the facilities and the system available at the Centre.

68.4 Such reference, except on any difference or dispute under clause 60 hereof shall not be.
commenced until after the completion or alleged completion of the Works or determination or alleged
determination of the Contractor's employment under this Contract, or abandonment of the Works,
unless with the written consent of the Government and.the Contractor.

68.5 In the event that such consent has been obtained in accordance with clause 68.4, the reference of
any matter, dispute or difference to arbitrc;1tion pursuant to this clause and/or the continuance of any
arbitration proceedings consequent thereto shall in no way operate as a waiver of the obligations of
the parties to perform their respective obligations under this Contract.

68.6 In any arbitration proceedings conducted pursuant to clause 68.3, the Parties may make any counter
claim in relation to any dispute or difference arising from the Contract.

68. 7 Upon every or any such reference the costs of such incidental to the reference and award shall be in
the discretion of the Arbitrator who may determine the amount thereof, or direct the amount to be
taxed as between solicitor and client or as between party and party, and shall direct by whom and ·to
whom and in what manner the same be borne, award and paid.

68.8 The award of the Arbitrator shall be final and binding on the Parties.

68.9 In the event of the death-of the arbitrator or his unwillingness or inability to act, then the Government
and the Contractor upon agreement shall appoint another person to act as the arbitrator, and in the
event the Government and the Contractor fail to agree on the appointment of an arbitrator, an
arbitrator shall be appointed by the Director of the Regional Centre for Arbitration in Kuala Lumpur.

68.10 In this clause, "reference" shall be deemed to be reference to arbitration within the meaning of the
Arbitration Act 2005.

68.11 The arbitration shall be governed by the Arbitration Act 2005 and the laws of Malaysia.

69.0 SAFETY AT THE SITE

69.1 Compliance with Safety Requirements

The Contractor shall comply with all relevant laws, regulations, rules, by-laws, directive or order by the

57
 relevant authorities on the requirements of safety.:.at-work ("Safety Requirements") and shall ensure its
personnel, workmen and sub-contractors at all times during the execution of Works comply with such
Safety Requirements.

69.2 Submission of Safety Programme

(a) Within 14 days from the receipt of the Letter of Acceptance by the Government, the
Contractor shall submit to the P.D a safety programme to ensure that all construction
activities required for the execution of the Works are carried out in a safe manner and in
compliance with Safety Requirements.

(b) The safety programme shall be subject to the approval of the P.O. The submission to and
approval by the P.D of the safety programme shall not relieve the Contractor of any of its
obligations and liabilities pertaining to the safety requirement under the Contract.

69.3 Safety Officer and Personnel

(a) The Contractor shall appoint a suitably qualified and experienced person as safety officer
who shall be responsible for compliance with Safety Requirements and all safety matters
relating to the Works. The Contractors shall, from time to time, provide such other
personnel and resources as may be required to ensure the effective implementation of
the safety programme on Site.

(b) The Contractor shall conduct training programmes for all workmen including workmen of
its sub-contractors for compliance with the Safety Requirements.

69.4 Safety Measures

(a) The Contractor shall ensure that the constructional plant together with all other tools and
equipment and other items used in the execution of the Works are in a safe, sound and
good condition and capable of performing the functions for which they are intended.

(b) The Contractor is responsible for instituting a safe method of construction on site for all of
the workers and shall ensure that its subcontractors whether nominated or otherwise
institute the same method of construction for their workers.

(c) Without limiting its liability under the Contract, the Contractor shall provide all workmen
on Site with the necessary safety equipment including but not limited to safety boots,
safety helmets and protective clothing.

70.0 TECHNOLOGY TRANSFER

If the Contractor appoints foreign professionals, the Contractor shall endeavour to ensure that the
employees of the Government are trained or exposed to the expertise of such foreign professionals
pursuant to a programme for technology transfer.

71.0 ENVIRONMENTAL MATTERS

If the Contractor is required under the Environmental Quality Act 1974 to carry out an environmental
impact assessment report ("EIA Report") in relation to the Works, the Contractor shall -

58
 (a) comply with all relevant laws, in particular the Environmental Quality Act 1974 and the
Government policies as set out in the approval conditions of the EIA .. Repod. The
Government acknowledges that compliance with the approval conditions of the EIA
Report shall satisfy the noise, visual impact, aerial pollution and vibration parameters
required in respect of the Works;

(b) • ensure the incorporation of appropriate mitigative, rehabilitative, restorative and

enhancement measures in the planning, design and implementation works;

(c) give due consideration to the preservation and social implications of the water and air
quality, soil, flora and fauna within the site of the Works.

PROVIDED THAT the Government reserves the right to determine the cutting, felling or preservation of
trees or the replanting thereof on the Site and the Contractor shall comply with any direction of the
Government in this respect.

72.0 LAW GOVERNING THIS CONTRACT

This Contract shall be governed by and construed according to the laws of Malaysia and the parties
irrevocably submit to the exclusive jurisdiction of the courts of Malaysia.

73.0 COMPLIANCEWITH THE LAW

The Contractor shall comply with all applicable laws and with all guidelines, instruction, directions, orders,
requirements and instructions issued to the Contractor by any authority competent to do so under any
applicable law.

74.0 AMENDMENT

No modification, amendment or waiver of any of the provisions of this Contract shall be effective unless made
by mutual consent and made in writing by way of supplementary agreement specifically referring to this
Contract and duly signed by the Parties. The provisions in respect of such amendment, variation or
modification thereof shall be supplemental to and be read as integral part of this Contract which shall remain
in full force and effect as between both Parties. •

75.0 CONFIDENilALITY

75.1 This Contract and all such drawings, records, data, books, reports and all matters pertaining hereto
shall be considered as confidential matter and shall not be disclosed to any third party without prior
written mutual agreement, save and except where-

(a) disclosure of such information is necessary for the purposes of raising finance to undertake
the obligations of the Contractor under this Contract;

(b) disclosure of such information is made to the Contractor's consultants, auditors or advisers;

59
 (c) disclosure of such information is required by law or by any government agency or for the
performance of any obligations under this Contract; or

(d) the information has entered public domain.

75.2 Where information has been disclosed to third parties pursuant to clause 68.1, the Contractor
undertakes to ensure that such third parties shall not disclose the information to any other third party.

75.3 The restrictions contained in this clause shall survive the termination of this Contract and shall
continue to bind both Parties without limit in point of time.

76.0 STAMP DUTY

All costs for the preparation of this Contract including the stamp duty, if any, shall be borne by the
Contractor.

77.0 NOTICES

77.1 Any notice, approval, consent, request or other communication required or permitted to be given
or made under this Contract shall be in writing in Bahasa Malaysia or English language.

77.2 Such notice shall be effected by:

(a) hand delivery or courier and an acknowledgement of receipt obtained;

(b) leaving the notice at the registered office or site office of the Contractor in which case it
shall be deemed to have been duly delivered; or _
(c) registered post in which case it shall be deemed to have been received seven (7) days
after the date of posting.

77.3 The address of the Government and the Contractor is as shown below or such other address as
either party may have notified the sender:

to the Government:
Address:

to the Contractor:
Address:

77.4 It shall be the duty of the parties to notify the other if there is a change of address or entity by
giving a written notice within fourteen (14) days. In the event of the Contractor failing to notify the
P.D of such an address or any change in his address, such written notices and instructions shall
be deemed to have been served upon the Contractor if they are sent in the manner stated above

60
 to the address stated in this Contract or to the Contractor's site office.

78.0 TIME

Time whenever mentioned shall be of the essence of this Contract.

79.0 SEVERABILITY

If any provision of this Contract is held to be illegal or invalid under present or future laws or regulations
effective and applicable during the term of this Contract, such provision shall be fully severable and this
Contract shall be construed as if such illegal or invalid provision had never comprised as part of this
Contract and the remaining provisions of this Contract shall remain in full force and effect and shall not be
affected by the illegal or' invalid provision or by its severance from this Contract.

61
 IN WITNESS WHEREOF This Contract has been executed by the duly authorised representative of the
parties on the day and year first above written .

. Signed for and on behalf of

THE GOVERNMENT OF MALAYSIA
In the presence of

Witness

Signed for and on behalf of

)
)
In the presence of )

Witness

62
 APPENDIXl
APPENDIX TO THE CONDITIONS OF CONTRACT -

Clause

8.6(a) Officer empowered to approve

instructed variations according
to the limits as set out in
Treasury's Instructions No. 202
as amended

Financial Limits Officer

8.6{b) Officer(s) empowered to take

action on behalf of the
Government in respect of:

Clause 49

Clauses 60, 61, 62, 67 and 68

5.5 Date of Tender

5.6
25.1

1O Performance Bond

Amount of Guarantee ........ . RM .................................. .

Guarantor Bank/Insurance Company

Guarantee No .................. .

11 Amount to be added to full

value of Contract Sum
as the insured sum RM .............. ,..................... .

Total Amount Insured ........ . RM .... ,........................... .

Policy No ....................... .

Period of insurance .......... ..

11.2 Amount of excess RM .................................... .

63
 APPENDIXl
Clause

12 'Date for Possession' of the Site .................... .

33 SOCSO Scheme registration number

39 Minimum insurance cover for any one

accident or series of accidents
arising out of one event RM

Policy No .................... .

Period of insurance ........... .

39.2 Amount of excess RM ................................... .

43 Sectional Completion:

Identification of Date for Date for Liquidated and

Sections or parts Possession Completion Ascertained Damages
[Clause 39.3] (Clause 41.1) {Clause 42.1)

44 'Date for Completion' for whole of

the Works ................................ .

45 Liquidated and Ascertained Damages

at the rate of ............................. . RM ................ per .......... .

47 Defects Liability Period (if none stated,

then the period is twenty four (24)
months) ............................. .

53.3 Value of work to be executed including

materials and goods to be delivered before
Interim Certificate will be issued .................... . RM ................................. .

64
 APPENDIXl
Clause

53.5 Period for honouring payment

certificate (if none stated, then
within thirty (30) days of the issue
of the Certificate)

8.4, Percentage of on-cost charges 5%

11.3,
31.2,
33.4(b),
39.5.

47.4 Percentage of on-cost charges 10%

65.2(d)

65
 JKR Malaysia,
Jalan Sultan Salahuddin
50580 Kuala Lumpur